ADVERTISEMENT FOR BID

MINOT PUBLIC SCHOOLS

MAGIC CITY CAMPUS –

FACS & VOTECH REMODEL

Kraus-Anderson Construction Com-

pany is presently soliciting competi-

tive Lump Sum Bids for the Magic

City Campus – FACS & VoTech Re-

model project. This portion of the

project consists of renovating FACS

and Lab classrooms including

demolition, drywall, installation of

new finishes & casework, fire

suppression, mechanical, electrical,

and plumbing work.

Sealed bids will be received until

1:00 PM local time on Thursday

March 31st, 2022 at the address not-

ed below. Bids received after this

time will not be considered. Bids will

be opened at the Minot Public

Schools District Office and publicly

read aloud.

Kraus-Anderson Construction Com-

pany is the only authorized agent to

receive bids.

Bids may be mailed or delivered to:

Minot Public Schools District Office

c/o Kraus Anderson

215 2nd St. SE

Minot, ND 58701

The complete bid form shall be

without alterations, additions, or

erasures. All bids shall be on a lump

sum basis. No bid may be withdrawn

for a period of 60 days after bid re-

ceipt without consent of the Owner.

Kraus-Anderson Construction Com-

pany reserves the right to reject any

or all bids and to waive any irregu-

larities in bids.

Direct all communications regarding

this Project to the office of the Con-

struction Manager: Mark Oelrich

(mark.oelrich@krausanderson.com)

612-255-2458.

Procurement of Documents for

bidders on prime contracts: Obtain

the bidding documents, including the

Bid Form, Drawings and Specifica-

tions, via iSqft.com. Contact Krystal

Burton with any planroom download-

ing or ordering questions at

krystal.burton@krausanderson.com,

or to receive an invite. Bid Docu-

ments are also available thru many

of the regional builders’ exchanges.

A pre-bid conference will be held:

Magic City Campus, 1100 11th Ave

SW, Minot, ND 58703: Thursday,

March 17th, 2022 at 1:00 PM.

(March 10-17-24-31, 2022)

ADVERTISEMENT FOR BIDS

2022 Runway Pavement

Rehabilitation

Minot International Airport

Minot, North Dakota

SEH No. MINOT 163292

Notice is hereby given that Online

Bids will be received by the City of

Minot, North Dakota, until 2pm,

Tuesday, April 5, 2022, via

QuestCDN for the furnishing of all

labor and material for the construc-

tion of 2022 Runway Pavement

Rehabilitation.

The bid opening will be conducted

via Microsoft Teams, at which time

they will be publicly opened and

read aloud:

2022 Runway Pavement Rehabilita-

tion Bid Opening

April 5, 2022, 2:00pm (CDT)

Please join my meeting from your

computer, tablet or smartphone:

https://bit.ly/3McWKxE

Or call in (audio only) +1

872-242-7640,,662902354# United

States, Chicago

Phone Conference ID: 662 902 354#

Any person monitoring the meeting

remotely may be responsible for any

documented costs. Message and

data rates may apply.

Major components of the Work in-

clude: Concrete pavement patching,

rubber removal, pavement marking,

concrete joint sealing, bituminous

joint and crack repairs.

The Bidding Documents may be

viewed for no cost at

http://www.sehinc.com by selecting

the Project Bid Information link at

the bottom of the page and the View

Plans option from the menu at the

top of the selected project page.

Digital image copies of the Bidding

Documents are available at

http://www.sehinc.com for a fee of

$30. These documents may be

downloaded by selecting this project

from the “Project Bid Information”

link and by entering eBidDocTM

Number 8145682 on the SEARCH

PROJECTS page. For assistance

and free membership registration,

contact QuestCDN at 952.233.1632

or info@questcdn.com.

For this project, bids will ONLY be

received electronically. Contractors

submitting an electronic bid will be

charged an additional $30 at the

time of bid submission via the online

electronic bid service

QuestCDN.com. To access the elec-

tronic Bid Worksheet, download the

project document and click the on-

line bidding button at the top of the

advertisement. Prospective bidders

must be on the plan holders list

through QuestCDN for bids to be ac-

cepted. Bids shall be completed ac-

cording to the Bidding Requirements

prepared by SEH dated March 8,

2022.

In addition to digital plans, paper

copies of the Bidding Documents

may be obtained from Docunet

Corp. located at 2435 Xenium Lane

North, Plymouth, MN 55441

(763.475.9600) for a fee of $120.00.

A pre-Bid conference will not be held

for this project.

Bid security in the amount of 5 per-

cent of the Bid must accompany

each Bid in accordance with the In-

structions to Bidders.

The City of Minot reserves the right

to reject any and all Bids, to waive ir-

regularities and informalities therein

and to award the Contract in the

best interests of the City of Minot.

Maria Romanick

Airport Operations Manager

Minot, North Dakota

(March 17,24,31, 2022)

2010 Chevrolet Camaro

Vin: 2G1FA1EV2A9141346

Impounded by NoDak Towing

on 1/3/22. Failure to claim vehicle

within 30 days of this notice will

result in forfeit of all rights to

said motor vehicle purusant to

ND Century Code 39-26-08

(March 24, 2022)

2005 FORD FOCUS

VIN: 1FAFP34N35W228730

IMPOUNDED BY NODAK TOWING

ON 1/19/22/. FAILURE TO CLAIM

VEHICLE WITHIN 30 DAYS OF

THIS NOTICE WILL RESULT IN

FORFEIT OF ALL RIGHTS TO

SAID MOTOR VEHICLE PUR-

SUANT TO ND CENTURY CODE

39-26-08

(March 24, 2022)

2003 Ford F350

Vin: 1FTSW31P73EC85632

Impounded by Nodak Towing

on 11/16/21. Failure to claim

vehicle within 30 days of this notice

will result in forfeit of all rights

to said motor vehicle pursuant to

ND Century Code 39-26-08

(March 24, 2022)

IN DISTRICT COURT, WARD

COUNTY, NORTH DAKOTA

Civil No. 51-2022-CV-00364

SUMMONS

The Industrial Commission of North

Dakota, acting as the North Dakota

Housing Finance Agency,

Plaintiff,

vs.

Terrance W. Decoteau Jr., a single

man; and any other person in pos-

session;

Defendants.

THE STATE OF NORTH DAKOTA

TO THE ABOVE-NAMED DEFEN-

DANTS:

1. YOU ARE HEREBY summoned

to answer the Complaint of the

Plaintiff which is herewith served

upon you and which will be filed in

the office of the Clerk of District

Court of Ward County, at Minot,

North Dakota, and to serve a copy of

your answer thereto on the under-

signed at her office at 720 Main Ave-

nue, in the City of Fargo, County of

Cass, State of North Dakota, within

twenty one (21) days after service of

this Summons upon you, exclusive

of the date of service. If you fail to

appear or answer as above directed,

judgment will be taken against you

by default for the relief demanded in

the Complaint herein.

2. MORTGAGOR IS NOTIFIED

FURTHER that this is a communi-

cation from a debt collector and this

is an attempt to collect a debt. Any

information obtained will be used for

that purpose.

Dated at Fargo, North Dakota, this

8th day of February, 2022.

/s/ Sarah A. Aaberg

Sarah A. Aaberg (ND ID #08393)

Special Assistant Attorney General

for the

Industrial Commission of North

Dakota acting as the

North Dakota Housing

Finance Agency

Attorney for Plaintiff

720 Main Avenue

Fargo, North Dakota 58103

701.235.8000

sarah@okeeffeattorneys.com

3. This action relates to the foreclo-

sure of a real estate mortgage

owned by above-named Plaintiff

upon the following described pro-

perty situated in the County of Ward,

State of North Dakota, to-wit:

West 116 Feet of Lot 1, Block 9,

Charlebois Addition to the City of

Minot, Ward County, North Dakota.

APN #: M124.037.090.0010

(Street Address: 1001 4th Street SE,

Minot, ND 58701)

/s/ Sarah A. Aaberg

Sarah A. Aaberg (ND ID #08393)

Special Assistant Attorney

General for the

Industrial Commission of North

Dakota acting as the North Dakota

Housing

Finance Agency

Attorney for Plaintiff

720 Main Avenue

Fargo, North Dakota 58103

701.235.8000

sarah@okeeffeattorneys.com

(March 24,31; April 7, 2022)

IN THE STATE OF NORTH DAKO-

TA, COUNTY OF WARD

IN THE DISTRICT COURT, NORTH

CENTRAL JUDICIAL DISTRICT

Lakeview Loan Servicing, LLC,

Plaintiff,

v.

Patrick R. Friley and Unknown

Spouse of Patrick R. Friley and all

persons unknown, claiming any

estate or interest in, or lien or en-

cumbrance upon, the real estate

described in the complaint, and any

person in possession,

Defendants.

SUMMONS

CIVIL NUMBER: 51-2022-CV-0035

THE STATE OF NORTH DAKOTA

TO THE ABOVE-NAMED DEFEN-

DANTS:

1. To the above-mentioned Defen-

dants including all persons unk-

nown, claiming any estate or interest

in, or lien or encumbrance upon, the

real estate described in the com-

plaint.

2. You are hereby summoned and

required to appear and defend

against the Complaint in this action,

which is herewith served upon you,

by serving upon the undersigned a

copy of an Answer or other proper

response within twenty-one (21)

days after the service of this Sum-

mons upon you, exclusive of the day

of service.

3. If you fail to do so, Judgment by

default will be taken against you for

the relief demanded in the Com-

plaint.

4. This Summons and Complaint will

be filed with the Clerk of this Court.

5. This action relates to the foreclo-

sure of a mortgage upon the follow-

ing described real property in the

County of Ward, State of North

Dakota:

Original Kenmare N2 L2 & all L1

B15 Kenmare City-S28.

MORE CORRECTLY DESCRIBED

AS FOLLOWS:

Lot 1 and the N1/2 of Lot 2, Block

15, Original Townsite of the City of

Kenmare, Ward County, North

Dakota.

Property Address: 521 N Central

Ave, Kenmare, ND 58746

6. The Plaintiff is not seeking a per-

sonal judgment against the

above-named Defendants.

Dated this 18th day of January,

2022

/s/ Zachary Nesbit

Zachary Nesbit

376 East 400 South, Suite 300

Salt Lake City, UT 84111

Tel: 801-355-2886

Email: zach@hwmlawfirm.com

Bar Number: 07552

HWM: ND10777

(March 24, 31, April 7, 2022)

INVITATION TO BID

PROJECT. Broadway Circle

BIDS CLOSE. April 12, 2022 at 2PM

CST

EAPC PROJECT #. 20204441

DATE OF ISSUE. March 15, 2022

BY.

EAPC Architects Engineers

2080 36th Ave SW, Suite 210

Minot, ND 58701

PHONE: (701) 839 – 4547

OUTLINE OF PROJECT. The pro-

ject consists of a new 6 unit one sto-

ry wood construction family shelter,

a new 2 story wood construction low

income housing building and remo-

del of an existing building on site

into a food pantry and homeless

meal center.

TYPE OF BIDS. Single prime bids

or one combined bid at the

contractor’s choice.

THE OWNER.

Project BEE

400 E Central Ave, Suite 302

Minot, ND 58701

BID PLACE.

EAPC Architects Engineers

2080 36th Ave SW, Suite 210

Minot, ND 58701

Bids received after the designated

time will not be accepted. All in-

terested parties are invited to attend.

Bids will be opened and publicly

read aloud. It is the Bidder’s respon-

sibility to see that mailed or

delivered Bids are in the hands of

the Owner prior to the time of the

Bid opening.

OBTAINING DOCUMENTS. Draw-

ings and Specifications may be ex-

amined at the Architect/Engineer’s

office, and the Owner’s office at the

address shown above and:

QuestCDN (www.questcdn.com),

CMD (Construction Market Data),

Dodge Plan Room and SCAN in

Minneapolis, Minnesota Builders Ex-

changes at Duluth, St. Cloud, Min-

nesota Builders Exchange in Min-

neapolis. North Dakota Builders Ex-

changes at Bismarck, Dickinson,

Fargo, Grand Forks, Minot, Willis-

ton. Montana Builders Exchange at

Billings.

If Contractor receives the bidding

documents from a plans exchange,

it is the Contractors responsibility to

contact EAPC Architects Engineers

to be added to the plan holders list.

Complete digital project bidding do-

cuments are available at

www.questcdn.com. You may

download the digital plan documents

for $15.00 by inputting Quest project

# 8111278 on the website’s Project

Search page. Please contact

QuestCDN.com at 952-233-1632 or

info@questcdn.com for assistance

in free membership registration,

downloading, and working with this

digital project information. An option-

al paper set of project documents is

also available for a refundable price

of $150.00 per set from EAPC Archi-

tects Engineers, 2080 36th Ave SW,

Suite 210, Minot, ND 58701. If the

Bidder returns the set of documents,

in good condition, within 10 days fol-

lowing the Bid Date, the deposit will

be refunded.If the Bidder does not

return the set of documents within

the designated time, none of the

deposit will be refunded. Please al-

low 2 days for printing. Partial or

complete sets of prints and specifi-

cations may be obtained from EAPC

by other than the above. The sets or

partial sets will be distributed upon

receipt of payment for the informa-

tion charged at the current reproduc-

tion rate. None of this payment will

be refunded. Completeness and

adequacy of the list of documents

requested shall be the responsibility

of the person making the request.

FEDERAL REGULATIONS. This

contract is Federally assisted. The

Contractor must comply with the

Davis Bacon Act, the Anti Kickback

Act, and the Contract Work Hours

Standards. Contracts for work under

this bid will obligate the Contractor

and Subcontractors not to discrim-

inate in employment practices.

Bidders must submit a compliance

report in conformity with the

President’s Executive Order No.

11246.

BID SECURITY. Bid Security in the

amount of five (5%) percent of the

Bid including all add alternates, must

accompany each Bid in accord with

00 1000 – Instructions to Bidders.

Cash, Bidders Bond, cashier’s

checks or certified checks will not be

accepted.

NORTH DAKOTA LAW. All bidders

must be licensed for the highest

amount of their bids, as provided by

North Dakota Century Code Section

43 07-07; and no bid will be read or

considered which does not fully

comply with the above provisions as

to bond and licenses, and any bid

deficient in these respects submitted

will be re sealed and returned to the

bidder immediately.

PRE-BID MEETING. There will be a

meeting of prospective Bidders at

10:00 AM, Friday, March 25, 2022 at

1901 S Broadway Ave, Minot, North

Dakota All those with questions for

the Owner and A/E are invited to at-

tend. Attendance by prospective

Bidders is not a mandatory prere-

quisite for submitting a Bid for this

project

BID SUBMISSION: Bids shall be

submitted to the person and place,

and by the time indicated in the In-

structions to Bidders. Bids shall be

packaged in accordance with 00

1000 – Instructions to Bidders.

THE OWNER reserves the right to

waive irregularities, to reject Bids

and to hold all Bids for a period of 30

days after the date fixed for the

opening thereof.

By order of: Elizabeth Larsen, Exe-

cutive Director

(March 17, 24, 31, 2022)

March 7, 2022 Regular City

Council Meeting

MINOT CITY COUNCIL –

SCHEDULED MEETING –

March 7, 2022 AT 5:30 P.M.

Members Present: Evans, Jantzer,

Olson, Pitner, Podrygula, Ross,

Sipma

Members Absent: None

Mayor Sipma presiding and led the

City Council in the Pledge of Allegi-

ance.

February Meetings & Activities

8th – Souris Valley United Way

Annual Meeting

8th – Virtual Reading to Children for

Minot Public Schools

9th – ND Land Surveyor’s Annual

Convention in Minot

11th – MACEDC Monthly Board

Meeting

14th – Task Force 21 Monthly

Meeting

15th – City Comprehensive Focus

Group

18th – State of the City Luncheon

22nd – Team Minot Breakfast at

Minot Air Force Base

22nd – MACEDC Executive Session

Meeting

22nd – Regular City Council

Meeting

23rd – Minot Comprehensive Plan

Focus Group

23rd – Citizen of the Year Check

Presentation at Project Bee

23rd – Task Force 21, US Air Force

Global Strike Commander General

Anthony Cotton

25th – MC Northern Plains

Children’s Advocacy Center Gala

March Meeting & Activities

1st – Community & Economic

Development Meeting

1st – Podcast Interview, Mental

Health/Wellness

3rd – Military Affairs Committee Lun-

cheon

4th – Minotauros Ceremonial 1st

Puck Drop

Along with 14 other meetings re-

garding City Business and

numerous phone calls, e-mails, so-

cial media, and staff interactions.

Mayor Sipma also congratulated the

Minot High Boys Swim and Dive

Team on their win at State, the

Minot High Boys Basketball team for

being the WDA Champions, and the

Minot High Girls Basketball team for

placing 2nd at WDA. In closing, he

introduced Lance Meyer, City En-

gineer, and presented him with a

plaque from FEMA for our Category

6 rating.

The City Manager provided a written

update describing events and activi-

ties for various departments. Harold

also mentioned to council that they

should look for invitations for a Trini-

ty and City Hall Renovation Tour.

The City Attorney submitted a writ-

ten report.

Chief John Klug reported on the de-

nial by stating the applicant has

been denied due to previous domes-

tic violence charge and the ordi-

nance reads this charge should

result in a denial of this type of

licensing.

Alderman Pitner moved the City

Council ratify the decision to deny a

City of Minot Taxi Driver’s License to

Michael Pace based on his disquali-

fying criminal record.

Motion seconded by Alderwoman

Olson and carried by the following

roll call vote: ayes: Evans, Jantzer,

Olson, Pitner, Podrygula, Ross, Sip-

ma; nays: none.

Alderman Pitner moved the City

Council approve a minor revision to

the City of Minot Renaissance Zone

Development Plan and authorize

staff to submit the revised develop-

ment plan to the North Dakota

Department of Community Services

for final approval.

Motion seconded by Alderman

Jantzer and carried by the following

roll call vote: ayes: Evans, Jantzer,

Olson, Pitner, Podrygula, Ross, Sip-

ma; nays: none.

Alderman Ross moved the City

Council approve the minutes of

February 22, 2022 Regular City

Council Meeting and the minutes of

the February 18, 2022 State of the

City Address.

Motion seconded by Alderman

Pitner and carried by the following

roll call vote: ayes: Evans, Jantzer,

Olson, Pitner, Podrygula, Ross, Sip-

ma; nays: none.

Alderman Ross moved the City

Council approve payroll for the

period of January 16, 2022 through

February 12, 2022 in the amount of

$2,222,029.19 and bills and

transfers for February in the amount

of $6,515,940.04 as follows:

4 ACRES WELDING & FABRICA-

TION, INC $75.00 AAAE $150.00

ACKERMAN ESTVOLD $18,926.46

ACME TOOLS $316.57 AD-

VANCED BUSINESS METHODS

$752.43 ADVANCED ENGINEER-

ING & ENVIRONMENTAL

$1,325.50AMERICAN PUBLIC

WORKS ASSN. $3,515.00 AMERI-

CAN TRUCK & TRAILER, LLC

$209.00 AMERICAN WATER

WORKS ASSN. $3,877.00 AMERI-

TAS LIFE INSURANCE CORP

$332.89 AQUA-PURE, INC.

$4,515.00 ARAMARK $173.06

AT&T $91.54 BALCO UNIFORM

COMPANY, INC.$1 88.92 BERT’S

TRUCK EQUIPMENT INC

$16,330.00 BLUE CROSS BLUE

SHIELD OF ND $40.00 BLUE-

STONE CONSTRUCTION, INC.

($123,531.69) BMI GENERAL

LICENSING $391.00 BORDER

STATES INDUSTRIES, INC.

$1,053.50 BROADWAY PRINTING

COMPANY $738.70 BUTLER

MACHINERY CO. $90.92 CAISEE

SANDUSKY $25.00 CITY OF

MINOT $300.00 CIVICPLUS

$1,914.42 COLONIAL LIFE

$2,291.76 CUSTOM TRUCK

EQUIPMENT INC $5,091.21 DACO-

TAH PAPER CO. $3,356.08 DAKO-

TA FLUID POWER, INC. $871.87

DAKOTA SUPPLY GROUP $435.00

DARREN ZUCK $112.10 DAVID

RODMAN $587.20 DIVISION OF

CHILD SUPPORT $102.00

DOMESTIC VIOLENCE CRISIS

CENTER $1,034.54 DOMINIC

GUNSCH $1,722.96 DR TRAN-

SPORT, INC. $14,122.40 DUCK’S

TOWING $80.00 EAPC $10,000.00

ECOLAB PEST ELIMINATION DIVI-

SION $393.60 ELDORADO NA-

TIONAL – CALIFORNIA $167.66

EMERGENCY AUTOMOTIVE

TECHNOLOGIES $1,703.00 Harold

Stewart $134.40 Harold Stewart

$10.00 Nathan Derr $53.10 ENER-

BASE $16,762.68 FACTORY MO-

TOR PARTS $2,479.10 FARSTAD

OIL CO $56,589.78 FASTENAL

COMPANY $222.43 FIRST INTER-

NATIONAL BANK & TRUST

$660.00 FIRST WESTERN IN-

SURANCE $103,851.00 FLEXIBLE

PIPE TOOL COMPANY $1,680.15

FORUM INDUSTRIES, INC

$1,085.00 GALLS, LLC $1,992.32

Ashley Flagstad ($275.45) Georgine

Walsh $10.00 Jacob Hundley

$1,025.50 Marie Miller $476.06 Sa-

mantha Chitwood-Reyes $75.00

Texas Department of Public Safety

$20.00 GENERAL TRADING $82.66

GOOSENECK IMPLEMENT COM-

PANY $29.50 GRAYBAR $1,215.60

GREAT PLAINS TECHNICAL SER-

VICES $1,380.00 H.A. THOMPSON

& SONS, INC. $1,380.00 HAW-

KINS, INC. $30,276.02 HOBBY

LOBBY $50.00 HOME OF ECONO-

MY $500.90 HOUSTON EN-

GINEERING, INC. $7,907.98 HUWE

THE HOUSE MOVER, INC.

$10,000.00 HYLAND SOFTWARE,

INC. $10,750.12 INFORMATION

TECHNOLOGY DEPARTMENT

$3,525.60 INTERSTATE BATTERY

SYSTEM $577.90 JEFF BEHRENS

$53.10 JOE DEGENSTEIN $53.10

JOHNSON CONTROLS $412.60

KLJ ENGINEERING, LLC $9,743.47

KYLE SCHILL $375.30 LANCE

LENTON $28,000.00 LANDRUM

AND BROWN, INC. $7,830.00

LHOIST NORTH AMERICA OF

MISSOURI $33,333.94 MACEY

WANTZ $112.10 MAIN ELECTRIC

CONSTRUCTION $3,190.78 MAR-

CO, INC. $259.84 MARCO, INC.

$216.64 MEGAN SCHMIDT

$300.00 MIDWEST TAPE $224.40

MINOT AREA CHAMBER EDC

$674.20 MINOT AUTO $3,814.45

MINOT DAILY NEWS $2,889.03

MINOT EMPLOYEE DONATIONS

$775.89 MINOT LIONS CLUB

$90.00 MINOT PARK DISTRICT

$44,621.02 MOTOROLA $3,540.55

MOWBRAY & SONS $162.41 MUN-

ICODE $492.66 NAPA AUTO

PARTS $2,945.65 ND FRATERNAL

ORDER OF POLICE $650.00 ND

HOUSING FINANCE AGENCY

$916.12 ND ONE CALL, INC.

$494.10 ND WATER EDUCATION

FOUNDATION $150.00 NDDEQ

$18.54 NEBRASKA CHILD SUP-

PORT PAYMENT $563.08 NORTH-

ERN BRAKE $368.95 NORTHERN

PLAINS EQUIPMENT CO., INC.

$169.33 NORTHERN TESTING

$1,295.00 NORTHWEST TIRE AND

RETREAD $4,175.05 OK AUTO-

MOTIVE $1,480.00 OLSON’S TOW-

ING $946.40 OTIS ELEVATOR

COMPANY $25,086.00 OVER-

HEAD DOOR CO. OF MINOT

$175.00 PRAIRIE SUPPLY $344.04

PROCOLLECT $345.62 PROTECH

INTEGRATIONS, LLC $179.94

PROVIDENT LIFE & ACC INS CO

$579.20 RALPH’S PLUMBING

$587.92 RDO EQUIPMENT

$3,927.57 RHI SUPPLY $4,541.08

ROBBIE BOUCHER $112.10 SANI-

TATION PRODUCTS $3,860.16

SHAUN SIPMA $220.41 SHERWIN

WILLIAMS $70.72 SOURIS RIVER

JOINT WATER RESOURCE

$3,202.50 SOUTH DAKOTA CHILD

SUPPORT $188.31 SRF CON-

SULTING GROUP $1,924.15 SRT

COMMUNICATIONS $34,324.40

STATE WATER COMMISSION

$11,062.95 STEIN’S, INC.

$1,623.83 STRATA CORPORA-

TION $63,334.82 SWANSON &

WARCUP, LTD $13,221.27

SWANSTON EQUIPMENT COM-

PANIES $2,074.68 TERMINAL

SUPPLY CO. $29.36 TERRENCE

MATTHEW BRACK $300.00

TRAFFIC CONTROL CORPORA-

TION $3,325.00 TRINITY HEALTH

$1,651.50 TUFF TRUCKS

($1,539.98) UNITED MAILING SER-

VICE $412.91 UNUM LIFE IN-

SURANCE $8,643.43 UNUM LIFE

INSURANCE $4,173.29 UPS

STORE #1423 $36.42 VAN-

TAGEPOINT TRANSFER — 10###

$552.03 VESSCO, INC. $4,903.27

VISIT MINOT $32,996.97 WALL-

WORK TRUCK CENTER $3,078.61

WARD COUNTY RECORDER

$20.00 BREMER BANK $281.25

BRENTRUP, KAYLA $4.08 CRAIG,

MICHAEL $50.00 GOHL, RUSS

$548.88 GUYNN, BRYAN $50.00

KEIFFER, SHANIKA $40.00 Ni-

cholle Morlano $50.00 TUCKER,

CORRYN $16.31 WINDISCH, MAR-

CELLA $15.56 WAYNE MOE

$770.00 WESTLIE FORD $398.03

WESTLIE TRUCK CENTER

$4,536.08 WORKFORCE SAFETY

& INSURANCE $250.00 MDU

$25,083.03 XCEL $191,949.62 DA-

VID MYERS $1,666.00 WARD

COUNTY TREASURER $36,102.41

CHRISTINE DIRCKS $400.00 MDU

$11,832.67 4 ACRES WELDING &

FABRICATION, INC $3,735.66

AARON PETERSON $147.50 ACK-

ERMAN ESTVOLD $8,385.00 AD-

VANCED BUSINESS METHODS

$3,099.33 ADVANCED ENGINEER-

ING & ENVIRONMENTAL $603.25

AMANO MCGANN, INC. $2,080.99

AMAZON $22.94 AMERICAN

WELDING & GAS, INC. $9,157.75

AMERITAS LIFE INSURANCE

CORP $1,140.67 ANDRES

CASAREZ JR $76.70 ANTHONY

HUGG $117.60 APEX ENGINEER-

ING GROUP $19,906.69 ARAMARK

$86.53 ASSETWORKS $5,073.75

AXON ENTERPRISE, INC.

$32,508.00 BETHKE, LLOYD H.

$300.00 BISHOP RYAN HIGH

SCHOOL $100.00 BLUESTONE

CONSTRUCTION, INC.

$117,721.61 BLUETARP FINAN-

CIAL, INC. $5.99 BRANDON

TRONDSON $1,000.00 BREAD OF

LIFE LUTHERAN CHURCH

$1,150.72 BULLARD-WOLF,

CHRISTINA $77.22 BUTLER

MACHINERY CO. $1,351.26 CASH-

WISE $20.00 CITY OF MINOT

$25.00 COMPUTER STORE

$562.50 CORRPRO COMPANIES

$705.00 CPS, LTD $42,856.50

CROSSCOUNTRY FREIGHT

SOLUTIONS, INC. $369.37 CUM-

MINS POWER, LLC $274.80

DACOTAH PAPER CO. $940.87

DAKOTA FLUID POWER, INC.

$2,261.88 DAKOTALAND AUTO-

GLASS $150.00 DEERE CREDIT,

INC. $89,855.08 DELL FINANCIAL

SERVICES $13,354.97 DIVISION

OF CHILD SUPPORT $102.00

DOMESTIC VIOLENCE CRISIS

CENTER $13,911.51 DR TRAN-

SPORT, INC. $5,578.40 ECOLAB

PEST ELIMINATION DIVISION

$111.67 EILEEN BEAN $10.53 EM-

ERGENCY AUTOMOTIVE TECH-

NOLOGIES $11,907.78 Aaron Zab-

ka $375.30 Alex Coleman $236.00

Chad Sickles $236.00 Justin Smes-

tad $118.00 Shawn Reis $117.60

ENERBASE $24,714.58 ETSYS-

TEMS $132.00 FACTORY MOTOR

PARTS $1,463.64 FARSTAD OIL

CO $27,586.28 FASTENAL COM-

PANY $301.53 FIRST INTERNA-

TIONAL BANK & TRUST ($660.00)

FIRST INTERNATIONAL BANK &

TRUST $660.00 FIRST WESTERN

INSURANCE $612,303.00 FLEET-

MIND SOLUTIONS, INC. $2,746.25

FLEXIBLE PIPE TOOL COMPANY

$1,348.95 FORCE AMERICA

$921.93 G & P COMMERCIAL

SALES $382.14 Dave Leite $20.00

DINA GOODMAN $50.00 EZ Money

$10.00 Jennifer Baker $50.00 Karlee

Schmidt $25.00 Karlee Schmidt

$25.00 LAVAUN MACKEY $25.00

Marie Miller ($105.00) Nite Train

Pizza $21.25 Shanlya M. Van Hill

$200.00 Treasurer, State of Iowa

$5.50 GENERAL TRADING

$1,041.77 GILLIG, LLC $597.80

GOETTLE LAW, PLLC $3,500.00

GOOSENECK IMPLEMENT COM-

PANY $2,387.87 H.A. THOMPSON

& SONS, INC. $500.00 HAWKINS,

INC. $17,710.97 HOLOPHANE

$3,050.00 HOME OF ECONOMY

$17.97 INTERSTATE BATTERY

SYSTEM $1,557.90 JASON SUND-

BAKKEN $15.00 JASON WEST

$463.70 JEREMY CROXALL

$463.70 JOB SERVICES OF

NORTH DAKOTA $10,552.50 JOHN

ZAKIAN $1,900.00 KALIX $365.49

KRYSTA BECKER $76.70 LACAL

EQUIPMENT $951.06 LANDMARK

STRUCTURES $40,270.00 LEXI-

POL, LLC $1,080.00 LHOIST

NORTH AMERICA OF MISSOURI

$36,622.19 LINDE GAS & EQUIP-

MENT INC $4.78 LOWES PRINT-

ING, INC. ($320.80) MAGIC CITY

DISCOVERY CENTER $638,417.37

MAGIC CITY GARAGE DOOR

COMPANY $1,485.00 MAIN ELEC-

TRIC CONSTRUCTION $11,382.90

MARIA ROMANICK $25.00 MDU

$1,556.54 MELANIE MOORE

$70.00 MESSERLI & KRAMER PA

$589.46 MIDSTATES WIRELESS,

INC. $202.50 MINOT AREA

CHAMBER EDC $37,884.74 MINOT

AREA COUNCIL OF THE ARTS,

INC $6,666.66 MINOT AUTO

$1,805.76 MINOT DAILY NEWS

$989.37 MINOT ELECTRIC

$3,264.33 MINOT EMPLOYEE DO-

NATIONS $767.66 MOWBRAY &

SONS $464.56 MUNICODE

$950.00 NAPA AUTO PARTS

$1,504.12 NATIONAL PAYMENT

CORPORATION $529.69 ND

FRATERNAL ORDER OF POLICE

$650.00 ND ONE CALL, INC.

$85.60 ND STATE FAIR $400.00

ND STATE RADIO COMM.

$3,000.00 NDBOA $735.00 NDDEQ

$18.54 NEBRASKA CHILD SUP-

PORT PAYMENT $563.08 NEX-

TREQUEST CO $8,682.71 NORTH

COUNTRY SPORTSWEAR

$976.04 NORTHERN PLAINS

EQUIPMENT CO., INC. $80.64

NORTHWEST TIRE AND RE-

TREAD $7,591.49 O’DAY EQUIP.,

INC. $885.76 OK AUTOMOTIVE

$37.00 OLSON’S TOWING

$5,193.00 ONE CALL CONCEPTS,

INC. $25.70 PITNEY BOWES

RESERVE ACCOUNT $3,250.00

PRAIRIE SUPPLY $353.48 PRIN-

GLE & HERIGSTAD, P.C. $828.45

PROCOLLECT $1,015.90 PRO-

CONTROLS MIDWEST $600.00

PROTECH INTEGRATIONS, LLC

$154.99 PROVIDENT LIFE & ACC

INS CO $579.20 RAPID FIRE PRO-

TECTION, INC. $4,639.00 ROXI

MATHIS $200.00 SANITATION

PRODUCTS $3,955.54 SOURIS

BASIN PLANNING COUNCIL

$1,250.00 SOURIS RIVER JOINT

WATER RESOURCE $309,547.28

SOUTH DAKOTA CHILD SUP-

PORT $188.31 SRF CONSULTING

GROUP $3,342.10 STATE WATER

COMMISSION $1,378,454.20

STERNBERG LANTERNS, INC

$1,120.00 STRATA CORPORA-

TION $885.79 SUNDRE SAND &

GRAVEL, INC. $3,508.50 SWANS-

TON EQUIPMENT COMPANIES

$554.48 THE RETAIL COACH, LLC

$15,000.00 THOMSON

REUTERS-WEST PAYMENT

CENTER $351.00 TIMMONS

GROUP $30,843.20 TRACTOR

SUPPLY CREDIT PLAN $19.99

TUFF TRUCKS $464.89 U.S. POST

OFFICE $5,000.00 UNITED MAIL-

ING SERVICE $363.94 VAN-

TAGEPOINT TRANSFER — 10###

$552.03 VISIT MINOT $31,042.21

COOL, CRYSTAL $43.72 HARRIS,

SHARON $5.44 LAHTONEN,

MATTHEW $17.41 MCNAIR,

CHRISTINE $14.79 RUIZ, VIN-

CENT $13.25 VIGNASSI, JOSEF

$8.67 WESTLIE FORD $1,709.96

WESTLIE TRUCK CENTER

$13,753.91 WILL, JARED T.

$1,028.46 WILLIAM DECOTEAU

$383.50 XCEL $1,738.65

Motion seconded by Alderman

Pitner and carried by the following

roll call vote: ayes: Evans, Jantzer,

Olson, Pitner, Podrygula, Ross, Sip-

ma; nays: none.

Alderman Ross moved the City

Council approve the following ad-

ministrative approval requests:

1. Taube Museum of Art to conduct

a raffle on March 5, 2022 at the

Taube Museum (2 N. Main St.).

2. Valley of Minot Scottish Rite to

conduct a raffle on June 30, 2022 at

the Minot Masonic Center (2524

Burdick Expwy East).

3. Minot Area Chamber EDC to con-

duct a raffle on April 2, 2022 at the

Clarion Hotel (2200 East Burdick

Expwy).

4. Optimist Club of Minot to conduct

a raffle August 3, 2022 at the Grand

Hotel (1505 N Broadway).

5. Edison Elementary PTA to con-

duct a raffle on March 31, 2022 at

Edison Elementary (701 17th Ave

SW).

6. Magic City Figure Skating Club to

conduct a raffle on April 8, 2022 at

the Armory (420 3rd Ave SW).

7. Northern Plains Children’s Advo-

cacy Center to conduct a raffle on

July 12, 2022 at Minot Oak Park

(1300 4th Ave NW).

8. Boy Scout Troop 425 to conduct a

raffle on March 19, 2022 at the

Congregational United Church of

Christ (430 N Broadway).

9. Special Event Permit for Der

Blaue, LLC dba Blue Rider (105 2nd

Ave SE).

10. Special Event Permit for Der

Blaue, LLC dba Blue Rider (500

University Ave West).

11. Special Event Permit for Sports

on Tap, Inc dba Sports on Tap (220

S Broadway).

Motion seconded by Alderman

Pitner and carried by the following

roll call vote: ayes: Evans, Jantzer,

Olson, Pitner, Podrygula, Ross, Sip-

ma; nays: none.

Alderman Ross moved the City

Council place ordinance no. 5704 on

second reading amending the 2022

annual budget to increase the Fire

Department Capital equipment fund

contribution and donations revenue

and capital equipment expenditure

for the purchase of an air compres-

sor with a grant awarded by Hess.

Motion seconded by Alderman

Pitner and carried by the following

roll call vote: ayes: Evans, Jantzer,

Olson, Pitner, Podrygula, Ross, Sip-

ma; nays: none.

Alderman Ross moved the City

Council place ordinance no. 5706 on

second reading amending the 2021

annual budget to adjust the depart-

ment budgets for funds approved by

City Council for the following

year-end transfers and grants.

Motion seconded by Alderman

Pitner and carried by the following

roll call vote: ayes: Evans, Jantzer,

Olson, Pitner, Podrygula, Ross, Sip-

ma; nays: none.

Alderman Ross moved the City

Council place ordinance no. 5707 on

second reading amending the 2022

annual budget to increase the gar-

bage collection capital equipment

expenses for the purchase of new

roll-off truck and approve the use of

sanitation cash reserves.

Motion seconded by Alderman

Pitner and carried by the following

roll call vote: ayes: Evans, Jantzer,

Olson, Pitner, Podrygula, Ross, Sip-

ma; nays: none.

Alderman Ross moved the City

Council place ordinance no. 5708 on

second reading amending the 2022

annual budget to increase the capi-

tal infrastructure engineering and en-

gineering sidewalk curb and gutters

expenditures for the additional ex-

pense and permanent easement for

the Edison Safe Routes to School

project # 4505 and approve the

transfer of the sales tax improve-

ment and general fund revenue.

Motion seconded by Alderman

Pitner and carried by the following

roll call vote: ayes: Evans, Jantzer,

Olson, Pitner, Podrygula, Ross, Sip-

ma; nays: none.

Alderman Ross moved the City

Council place ordinance no. 5709 on

second reading amending the 2022

annual budget to increase the capi-

tal infrastructure fire department ex-

penditures for the NW Fire Station

#5 construction, project # FD0024

using capital infrastructure reserves.

Motion seconded by Alderman

Pitner and carried by the following

roll call vote: ayes: Evans, Jantzer,

Olson, Pitner, Podrygula, Ross, Sip-

ma; nays: none.

Alderman Ross moved the City

Council place ordinance no. 5710 on

second reading amending the 2022

annual budget to increase the airport

airside runway maintenance for the

design engineering of runway 13/31

and 8/26 rehabilitation using airport

cash reserves, grant funding will be

applied for to reimburse 95% of the

expense.

Motion seconded by Alderman

Pitner and carried by the following

roll call vote: ayes: Evans, Jantzer,

Olson, Pitner, Podrygula, Ross, Sip-

ma; nays: none.

Alderman Ross moved the City

Council place ordinance no. 5711 on

second reading amending the 2022

annual budget to increase the airport

capital equipment budget for the en-

gineering portion of the snow remo-

val equipment, using airport cash

reserves, grant funding will be ap-

plied for to reimburse 95% of the ex-

pense.

Motion seconded by Alderman

Pitner and carried by the following

roll call vote: ayes: Evans, Jantzer,

Olson, Pitner, Podrygula, Ross, Sip-

ma; nays: none.

Alderman Ross moved the City

Council place ordinance no. 5712 on

second reading amending the 2022

annual budget to increase the vehi-

cle maintenance capital equipment

expenditures for the purchase of a

vehicle diagnostic system and ap-

prove the use of capital equipment

cash reserves.

Motion seconded by Alderman

Pitner and carried by the following

roll call vote: ayes: Evans, Jantzer,

Olson, Pitner, Podrygula, Ross, Sip-

ma; nays: none.

Alderman Ross moved the City

Council approve final payment in the

amount of #348,149.02 to be paid to

Blu on Broadway, LLC for the Blu on

Broadway Project.

Motion seconded by Alderman

Pitner and carried by the following

roll call vote: ayes: Evans, Jantzer,

Olson, Pitner, Podrygula, Ross, Sip-

ma; nays: none.

Alderman Ross moved the City

Council approve the bid award to

Wagner Construction in the amount

of $3,883,810.00 and recommend

approval of award to the SRJB. It

was also motioned the City Council

approve the Reimbursement Reso-

lution for this phase.

Motion seconded by Alderman

Pitner and carried by the following

roll call vote: ayes: Evans, Jantzer,

Olson, Pitner, Podrygula, Ross, Sip-

ma; nays: none.

Alderman Ross moved the City

Council approve award to Swingen

Construction in the amount of

$5,538,432.55 and recommend ap-

proval to the SRJB for bidding of the

Sawyer replacement, Phase SA-1 of

the MREFPP.

Motion seconded by Alderman

Pitner and carried by the following

roll call vote: ayes: Evans, Jantzer,

Olson, Pitner, Podrygula, Ross, Sip-

ma; nays: none.

Alderman Ross moved the City

Council concur with the SJRB bid

award of BU-1D to Bluestone Con-

struction in the amount of

$6,433,492.22.

Motion seconded by Alderman

Pitner and carried by the following

roll call vote: ayes: Evans, Jantzer,

Olson, Pitner, Podrygula, Ross, Sip-

ma; nays: none.

Alderman Ross moved the City

Council approve the low bidder of

Wagner Construction in the amount

of $54,149,125.18 and forward ap-

proval to SRJB for award.

Motion seconded by Alderman

Pitner and carried by the following

roll call vote: ayes: Evans, Jantzer,

Olson, Pitner, Podrygula, Ross, Sip-

ma; nays: none.

Alderman Ross moved the City

Council approve the Department of

the Army Permit

NWO-2004-60610-BIS for work to

be completed in accordance with the

preliminary plans entitled Construc-

tion Drawings for Drainage and

Stormwater Improvements at Minot

International Airport, Minot, North

Dakota, A.I.P.

#3-38-0037-054-2018; and authorize

the Mayor to sign the permit and any

applicable documentation.

Motion seconded by Alderman

Pitner and carried by the following

roll call vote: ayes: Evans, Jantzer,

Olson, Pitner, Podrygula, Ross, Sip-

ma; nays: none.

Alderman Ross moved the City

Council approve the plans and

specification and authorize a call for

bids.

Motion seconded by Alderman

Pitner and carried by the following

roll call vote: ayes: Evans, Jantzer,

Olson, Pitner, Podrygula, Ross, Sip-

ma; nays: none.

Alderman Ross moved the City

Council approve the specifications

and authorize a call for bids.

Motion seconded by Alderman

Pitner and carried by the following

roll call vote: ayes: Evans, Jantzer,

Olson, Pitner, Podrygula, Ross, Sip-

ma; nays: none.

Alderman Podrygula questioned

Stephen Joersz, Traffic Engineer,

about the attention to these particu-

lar areas and the impact to traffic the

road diet will have. Stephen dis-

cussed the timeframe due to the

Chip Seal project. Stephen also

mentioned that 16th Street showed it

has 9,000-12,000 vehicles traveling

it daily. There has actually been a

decrease over the years on the

usage of 16th St. most likely due to

the North Bypass completion and

the opening back up of Broadway

after the bridge construction.

Stephen also mentioned that the

road diet might not work for all of

16th St. but these areas specified

would be a good fit for this process.

This will help unify the speed of traff-

ic. Alderman Podrygula questioned

whether it would uniform the speed

to be faster or slower in these areas.

Stephen thought it would slow down

the speed just a bit making it safer

for traveling. Lastly, Alderman Po-

drygula, proposed the idea of doing

the all-in-one process change or

phasing the road diet in process.

Stephen said that it would have a

significant cost factor to do it all at

once due to diamond grinding in

some areas. The process of dia-

mond grinding could cause some

confusion on the markings in the

change to the road diet as well.

Alderman Jantzer addressed the

bike lane and if it would be an all

year bike lane that would be clear in

the winter. Stephen said that the in-

tent is to keep the bike lane clear but

depends on the snow events if it will

be accessible all year round. Alder-

man Jantzer wanted Stephen to dis-

cuss the center turn lane. Stephen

said that most traffic would do North

left turns due to the destinations in

the area.

Alderman Ross inquired about if the

NW development was considered in

the study. Stephen believed that

21st Ave would have more of an im-

pact with the new high school and

that this has been a thought in the

back of his mind. He mentioned that

the boundaries for the new high

school might make a difference for

the NW development. Mayor Sipma

mentioned that with the elementary

school on 16th it will make more

sense for people accessing the new

high school to use the bypass.

Alderwoman Evans asked Stephen

to explain what would happen if the

road diet is a hated change. Stephen

just said it would be an easy change

of pavement markings. Alderman

Pitner spoke on how this traffic

change makes sense and how he is

happy to see this change for the

areas involved. Mayor Sipma men-

tioned that this will also help for

Perkett Elementary traffic 2 times a

day and how this will help with ac-

cident reduction. The Mayor and

Alderman Podrygula also mentioned

that it will be important to educate

the public about this traffic change.

Alderwoman Evans lastly asked

Stephen Joersz about how he will

study the impact after the project is

complete. Stephen mentioned that it

would take a couple years to do a

study so that he could get the proper

sample size to study the traffic

accidents/incidents in these areas.

Alderman Pitner moved the City

Council approve to convert 16th St.

W from 4th Ave NW to 2nd Ave SW

from a four/five-lane roadway to a

three-lane roadway with bicycle

lanes as part of the 2022 City of

Minot Street Seal maintenance pro-

ject; and approve to convert 16th St.

W from 2nd Ave SW to Burdick Ex-

pressway W from a four/five-lane

roadway to a three-lane roadway

with bicycle lanes as part of the

2025 North Dakota Department of

Transportation Urban Roads project.

Motion seconded by Alderwoman

Evans and carried by the following

roll call vote: ayes: Evans, Jantzer,

Olson, Pitner, Podrygula, Ross, Sip-

ma; nays: none.

Alderman Jantzer moved the City

Council award the bid for the 2022

Nuisance Abatement Rebid project

to the low bidder, Hanson’s Excavat-

ing, Inc., in the amount of

$66,550.00; approve the budget

amendment ordinance; and author-

ize the Mayor to sign the agreement.

Motion seconded by Alderman

Pitner and carried by the following

roll call vote: ayes: Evans, Jantzer,

Olson, Pitner, Podrygula, Ross, Sip-

ma; nays: none.

Alderwoman Olson moved the City

Council approve award the bid for

the construction portion of the 2022

Signal Cabinet Improvement project

to the low bidder, Main Electric Con-

struction, Inc. in the amount of

$322,543.00; approve the budget

amendment ordinance; and author-

ize the Mayor to sign the agreement.

Motion seconded by Alderman

Pitner and carried by the following

roll call vote: ayes: Evans, Jantzer,

Olson, Pitner, Podrygula, Ross, Sip-

ma; nays: none.

Alderman Pitner asked if the new

K-9 would be just for narcotics or

also trained on explosives. Chief

Klug said the new K-9 would only be

for narcotics. The City Manager,

Harold Stewart, commented further

on the topic proposing the question

on if the new K-9 would be trained

on marijuana. Chief Klug mentioned

that Mace is not trained on marijua-

na and neither will this new K-9.

Alderman Jantzer moved the City

Council approve the proposed ordi-

nance to amend the 2022 Police

Department annual budget.

Motion seconded by Alderwoman

Olson and carried by the following

roll call vote: ayes: Evans, Jantzer,

Olson, Pitner, Podrygula, Ross, Sip-

ma; nays: none.

Alderman Ross moved the City

Council approve the plans and

specifications and authorize a call

for bids; and approve the budget

amendment to allocate funds for

procurement and construction.

Motion seconded by Alderman

Pitner and carried by the following

roll call vote: ayes: Evans, Jantzer,

Olson, Pitner, Podrygula, Ross, Sip-

ma; nays: none.

There were no personal appear-

ances.

There were no miscellaneous and

discussion items.

There being no further business,

Alderman Pitner moved the City

Council meeting be adjourned. Mo-

tion seconded by Alderman Ross

and carried unanimously. Meeting

adjourned at 6:15 pm.

APPROVED: Shaun Sipma, Mayor;

ATTEST: Mikayla McWilliams, City

Clerk – PURSUANT TO NDCC

40-01-09.1, THESE MINUTES PUB-

LISHED SUBJECT TO THE COUN-

CIL’S REVIEW AND REVISION.

(March 24, 2022)

1990 Nissan 240SX

VIN: JN1HD36P3LW107390

Impounded by NoDak Towing

12/4/2021. Failure to claim vehicle

within 30 days this notice will result

in forfeit of all rights to said motor

vehicle pursuant to ND Century

Code 39-26-08

(March 24, 2022)

NOTICE

Freedom Township will have a spe-

cial meeting, Monday, April 4, 2022

at 7 pm to provide for a public hear-

ing for amendment changes to our

Freedom Township Ordinances.

Amendments include Road Stan-

dards and design, fence definitions

and requirements, and setbacks. Also, rezoning Peterson plat Section 19.

(March 24, 2022)

NOTICE OF HEARING

Probate No. 51-2022-PR-00034

IN THE DISTRICT COURT OF

WARD COUNTY, STATE OF

NORTH DAKOTA

In the Matter of the Estate of

Robert S. Willert

PLEASE TAKE NOTICE that a

hearing on the Application for Infor-

mal Appointment of a Personal

Representative in Intestacy in the

above referenced matter will be

heard in the Ward County District

Court, North Central Judicial District,

Minot, North Dakota, before the

Honorable Gary Lee Judge of the

District Court, on the 18th day of

April, 2022, at 11:30 o’clock a.m., or

as soon thereafter as counsel may

be heard.

Dated this 7th day of March, 2022.

OLSON & BURNS, P.C.

Jessica L. Merchant (ID 06169)

Attorney for Personal

Representative

17 First Avenue SE

P.O. Box 1180

Minot, ND 58702-1180

(701) 839-1740 jmerchant@srt.com

(March 17,24, 31, 2022)

NOTICE OF PETITION FOR

NAME CHANGE

IN THE MATTER OF THE

PETITION FOR NAME CHANGE

OF SARAH MARIE ROSALES

1. PLEASE TAKE NOTICE that a

Petition in the above – entitled matter

will be filed with the Clerk of District

Court for Ward County, North

Dakota, requesting an Order

changing the of Sarah Marie Ro-

sales to Sarah Marie Weidner.

2. Pursuant to N.D.C.C. 32-28-02,

thirty days previous notice of the

intended application must be given

the official newspaper printed in this

county. You are hereby notified that

thirty days after publication,

petitioner intends to file a petition

requesting entry of the Court’s Order

changing the name of Sarah Marie

Rosales to Sarah Marie Weidner.

Any objection to granting this name

change must be given in writing to

the address listed below within 30

days of the date of this publication.

The written objection must also be

filed with the Court. If no objections

are given, the Court may respond to

the Petition without further hearing.

Dated this 24th day of January,

2022

Sarah Rosales

400 Marcks St

Douglas, ND 58735

( March 24, 2022)

NOTICE OF PUBLIC SALE OF

LIENED PROPERTY

Notice is hereby given that a lien

sale will be held at Woodridge

Mobile Home Park, 405 SE 31st

Ave, #24 Minot, ND 58701, on April,

05, 2022 at 1:00 PM to satisfy the

lien on the property stored at the ad-

dress above. All units must be paid

for at the time of sale. Only cash

payments will be accepted. No one

under the age of 18 is allowed to at-

tend the sale. Each person attending

must sign in and agree to follow all

Rules and Regulations of the sale.

The Owner reserves the right to bid

at the sale. All purchased goods are

sold “as is” and must be removed

within 48 hours following the sale.

Buyers must provide a current, origi-

nal or a photocopy of their original

resale permit at time of sale in lieu of

sales tax. This sale is subject to can-

cellation in the event of settlement

between Owner and obligated party.

(March 17-24, 2022)

NOTICE TO CREDITORS

Case No. 51-2022-PR-00041

IN THE DISTRICT COURT OF

WARD COUNTY, STATE OF

NORTH DAKOTA

In the Matter of the Estate of

Richard A. Johnson, Deceased.

NOTICE IS HEREBY GIVEN that

the undersigned has been appointed

Personal Representative of the

above estate. All persons having

claims against the said deceased

are required to present their claims

within three (3) months after the date

of first publication or mailing of this

notice or said claims will be forever

barred. Claims must be presented to

Jayson Bexell, Personal Represen-

tative, in care of Reierson Law Of-

fice, P.C., Northland Professional

Building, 600 22nd Avenue N.W.,

Minot, North Dakota 58703, or filed

with the Court.

Dated this 18th day of March, 2022.

/s/ Jayson Bex-

ell__________________________

Jayson Bexell, Personal Represen-

tative

Christene A. Reierson (ID 06176)

REIERSON LAW OFFICE, P.C.

600 – 22nd Avenue N.W.

Minot, ND 58703-0986

(701) 839-7585

E-serve: reiersonlaw@gmail.com

Attorney for the Personal Represen-

tative

(March 24, 31, April 7, 2022)

NOTICE TO CREDITORS

51-2022-PR-00037

IN THE DISTRICT COURT OF

WARD COUNTY, STATE OF

NORTH DAKOTA

IN THE MATTER OF THE ESTATE

OF ANTHONY B. SCHNEIDER,

DECEASED.

NOTICE IS HEREBY GIVEN that

the undersigned has been appointed

Personal Representative of the

above estate. All persons having

claims against the deceased are re-

quired to present their claims within

three months after the date of the

first publication of this notice or said

claims will be forever barred.

Claims must be presented to Ann M.

Mueller, in care of Thomas Law

Firm, 114 South Main Street, P.O.

Box 2298, Minot, North Dakota

58702, or filed with the Court.

/s/Ann M. Mueller

Ann M. Mueller

c/o THOMAS LAW FIRM

114 South Main Street

P.O. Box 2298

Minot, North Dakota 58702

(March 10-17-24, 2022)

NOTICE TO CREDITORS

Probate No. 51-2022-PR-00051

STATE OF NORTH DAKOTA IN

DISTRICT COURT

COUNTY OF WARD NORTH

CENTRAL JUDICIAL DISTRICT

In the Matter of the Estate of Donna

M. Schmidt, Deceased

NOTICE IS HEREBY GIVEN that

the undersigned have been appoint-

ed Co-Personal Representatives of

the above Estate. All persons having

claims against the said deceased

are required to present their claims

within three months after the date of

the first publication of this Notice or

said claims will be forever barred.

Claims must either be presented to

Denise R. Rubbelke and Sandra L.

Schmidt, Co-Personal Representa-

tives of the Estate of Donna M.

Schmidt, c/o Olson & Burns P.C., P.

O. Box 1180, Minot, ND

58702-1180, or filed with the Court.

Dated this 21st day of March, 2022.

/s/ Denise R. Rubbelke

Denise R. Rubbelke,

Co-Personal Representative

/s/ Sandra L. Schmidt

Sandra L. Schmidt,

Co-Personal Representative

Richard P. Olson (ID # 03183)

OLSON & BURNS P.C.

P. O. Box 1180

Minot, ND 58702-1180

Attorneys for Personal

Representative

(March 24, 31; April 7, 2022)

PUBLIC NOTICE

The following units are unpaid at this

time. Located at Klassic Storage 11

28th Avenue SW, Minot, ND

Unite 29 & 34 B. Whitfield

Unit 46 T. Johnson

Unit 48 J. Miard

(March 24, 2022)

SUMMONS

51-2022-DM-00085

STATE OF NORTH DAKOTA,

COUNTY OF WARD, IN DISTRICT

COURT, NORTH CENTRAL

JUDICIAL DISTRICT

Luis Gonzalez,

Plaintiff,

vs.

Karla Rosario Suazo Suazo,

Defendant.

THE STATE OF NORTH DAKOTA

TO THE ABOVE-NAMED DEFEN-

DANT:

You are hereby summoned and re-

quired to appear and defend against

the Complaint in this action which

has been filed with the Ward County

Clerk of District Court, Minot, North

Dakota, and to serve a copy of your

answer or other proper response

upon the undersigned attorney

within twenty-one (21) days after the

completion of service of this Sum-

mons upon you. Service is complete

upon the expiration of fifteen (15)

days after the date of the first publi-

cation. If you fail to appear or

answer, judgment by default will be

taken against you for the relief

demanded in the Complaint.

Dated at Minot, North Dakota, this

7th day of March, 2022.

THOMAS LAW FIRM

/s/Robert S. Thomas ID #04421

Attorney for Plaintiff

114 S. Main Street

P.O. Box 2298

Minot, North Dakota 58702

(701)852-1602

thomaslawyers@gmail.com

(March 10-17-24, 2022)