ADVERTISEMENT FOR BIDS

CITY OF MINOT, NORTH DAKOTA

2022 NUSIANCE ABATEMENT

CITY PROJECT 4671

NOTICE IS HEREBY GIVEN that

the City of Minot (Owner) is re-

questing Bids for the construction of

the following Project:2022 Nuisance

Abatement

Bids for the construction of the Pro-

ject will be received at theoffice of

the City Clerk located at 515 Second

Avenue SW (Second Floor), Minot,

North Dakota 58701, until Tuesday,

February 1, 2022 at 11:00am local

time. At that time the Bids received

will be publicly opened and read.

The Project includes the following

Work:Inert Debris Removal per

TON, Individual Landfill Items per

EA, and other associated items.

Complete digital project bidding do-

cuments are available at

www.questcdn.com. You may down-

load the digital plan documents for

$40by inputting eBidDoc

#8098740on the website’s Project

Search page. Please contact

QuestCDN.com at 952-233-1632 or

info@questcdn.com for assistance

in free membership registration,

downloading, and working with this

digital project information. Project

bidding documents are also avail-

able at the Issuing Office – City of

Minot Engineering Department 1025

31st St SE and are available for pur-

chase for $75. Potential bidders may

contact the Assistant City Engineer

at 701-857-4100 with any questions.

Each bid must be accompanied by a

separate envelope containing the

bid security in a sum equal to five

percent of the full amount of the bid

and must be in the form of a bidder’s

bond. A bidder’s bond must be exe-

cuted by the bidder as principal and

by a surety, conditioned that if the

principal’s bid is accepted and the

contract awarded to the principal,

the principal, within ten days after

notice of the award, shall execute a

contract in accordance with the

terms of the bid and the bid bond,

and any condition of the City of

Minot, as required by law. A counter-

signature of a bid bond is not re-

quired. If the City of Minot elects to

award a contract to the lowest

responsible bidder, and the lowest

responsible bidder does not execute

a contract within the ten days al-

lowed, the bidder’s bond must be

forfeited to the City of Minot and the

project awarded to the next lowest

responsible bidder.

Each bidder must possess a valid

North Dakota contractor’s license for

the full amount of their bid, as re-

quired by Section 43-07-07 of the

North Dakota Century Code. Each

bidder MUST enclose a copy of their

Contractor’s License or Certificate of

Renewal, issued by the North Dako-

ta Secretary of State, in their bid

bond envelope, and each license

must be valid and dated at least 10

days prior to the date set for bid

opening, as required under Section

43-07-12 of the North Dakota Centu-

ry Code.

No bid may be read or considered if

it does not fully comply with the re-

quirements of Section 48-01.2-05 of

the North Dakota Century Code, and

any deficient bid submitted will be

resealed and returned to the bidder

immediately.

All Bids submitted and all Work

completed must be as stipulated in

the Contract.

The City of Minot reserves the right

to hold all Bids for a period of 30

days after the date of the bid open-

ing, to reject any or all Bids and to

rebid the project until a satisfactory

bid is received, and to waive any in-

formality or irregularity in any Bid.

For all further requirements regard-

ing bid submittal, qualifications, pro-

cedures, and contract award, refer to

the Instructions to Bidders that are

included in the Bidding Documents.

By order of the City Council of the

City of Minot, North Dakota.

Owner: City of Minot

By: Mikayla McWilliams

Title: City Clerk

Date: January 7, 2022

(January 7-14-21, 2022)

ADVERTISEMENT FOR BIDS

CITY OF MINOT, NORTH DAKOTA

2022 PAVEMENT MARKINGS

CITY PROJECT 4628

NOTICE IS HEREBY GIVEN that

the City of Minot (Owner) is re-

questing Bids for the construction of

the following Project:2022 Pavement

Markings. Bids for the construction

of the Project will be received at

theoffice of the City Clerk located at

515 Second Avenue SW (Second

Floor), Minot, North Dakota 58701,

until Tuesday, February 1, 2022 at

11:00 AM local time. At that time the

Bids received will be publicly opened

and read. The Project includes the

following Work: Pavement Markings.

Complete digital project bidding do-

cuments are available at

www.questcdn.com. You may down-

load the digital plan documents for

$40by inputting eBidDoc #8102973

on the website’s Project Search

page. Please contact

QuestCDN.com at 952-233-1632 or

info@questcdn.com for assistance

in free membership registration,

downloading, and working with this

digital project information. Project

bidding documents are also avail-

able at the Issuing Office – City of

Minot Engineering Department 1025

31st St SE and are available for pur-

chase for $75. Potential bidders may

contact the Assistant City Engineer

at 701-857-4100 with any questions.

Each bid must be accompanied by a

separate envelope containing the

bid security in a sum equal to five

percent of the full amount of the bid

and must be in the form of a bidder’s

bond. A bidder’s bond must be exe-

cuted by the bidder as principal and

by a surety, conditioned that if the

principal’s bid is accepted and the

contract awarded to the principal,

the principal, within ten days after

notice of the award, shall execute a

contract in accordance with the

terms of the bid and the bid bond,

and any condition of the City of

Minot, as required by law. A counter-

signature of a bid bond is not re-

quired. If the City of Minot elects to

award a contract to the lowest

responsible bidder, and the lowest

responsible bidder does not execute

a contract within the ten days al-

lowed, the bidder’s bond must be

forfeited to the City of Minot and the

project awarded to the next lowest

responsible bidder. Each bidder

must possess a valid North Dakota

contractor’s license for the full

amount of their bid, as required by

Section 43-07-07 of the North Dako-

ta Century Code. Each bidder MUST

enclose a copy of their Contractor’s

License or Certificate of Renewal, is-

sued by the North Dakota Secretary

of State, in their bid bond envelope,

and each license must be valid and

dated at least 10 days prior to the

date set for bid opening, as required

under Section 43-07-12 of the North

Dakota Century Code. No bid may

be read or considered if it does not

fully comply with the requirements of

Section 48-01.2-05 of the North

Dakota Century Code, and any de-

ficient bid submitted will be resealed

and returned to the bidder immedi-

ately. All Bids submitted and all

Work completed must be as stipulat-

ed in the Agreement. The City of

Minot reserves the right to hold all

Bids for a period of 30 days after the

date of the bid opening, to reject any

or all Bids and to rebid the project

until a satisfactory bid is received,

and to waive any informality or irre-

gularity in any Bid. For all further re-

quirements regarding bid submittal,

qualifications, procedures, and con-

tract award, refer to the Instructions

to Bidders that are included in the

Bidding Documents. By order of the

City Council of the City of Minot,

North Dakota.

Owner:City of Minot

By:Mikayla McWilliams

Title:City Clerk

Date:January 7, 2022

(January 7-14-21, 2022)

ADVERTISEMENT FOR BIDS

SOURIS RIVER JOINT WATER

RESOURCES BOARD MOUSE

RIVER ENHANCED FLOOD

PROTECTION PROJECT PHASE

MI-5A, 4TH AVENUE NE LEVEE

EXTENSION

MINOT, WARD COUNTY, NORTH

DAKOTA

NOTICE IS HEREBY GIVEN that

the Souris River Joint Water

Resources Board will receive sealed

Bids for the construction of the

Mouse River Enhanced Flood Pro-

tection Project Phase MI-5, 4th Ave-

nue NE Levee Extension, at Minot

City Hall in the Council Chambers,

515 2nd Avenue Southwest, Minot,

North Dakota, 58702, until 11:00AM

CDT, February 16, 2022, at which

time all Bids will be publicly opened

and read aloud. All Bids must be

submitted, and all work shall be

done, in full and strict compliance

with the Plans and Specifications for

this Project. Complete digital project

bidding documents are available at

www.questcdn.com. You may down-

load the digital plan documents for

$100.00 by inputting Quest project

#8097075 on the website’s Project

Search page. Please contact

QuestCDN.com at (952) 233-1632

or info@questcdn.com for assis-

tance in a free membership registra-

tion, downloading, and working with

this digital project information. An

optional paper set of project docu-

ments is also available for a nonre-

fundable price of $500 per set. Make

checks payable to Houston En-

gineering, Inc. and send to 1401

21st Avenue North, Fargo, ND

58102. Potential bidders may con-

tact Bjorn Berg of Houston En-

gineering, Inc. at (701) 237-5065

with any questions. Copies of the

documents are available for viewing

at the following locations during nor-

mal business hours of 8:00 am to

4:30 pm, Monday through Friday,

excluding holidays:

Houston Engineering, Inc.

1401 21st Avenue North

Fargo, ND

Houston Engineering, Inc.

3900 13th Avenue SE

Minot, ND

A mandatory pre-bid conference for

interested bidders will be held on

January 26, 2022, from 9:00 AM

CDT until 10:30 AM CDT on Micro-

soft Teams, and will also be acces-

sible via a call-in conference line.

All bidders planning on attending the

meeting by Microsoft Teams or

conference line shall send an invite

request, via email, with the subject

“MI-5A Pre-Bid” to Bjorn Berg at

bberg@houstoneng.com prior to

Noon on January 25th, 2022.

Any companies/teams/joint ventures

planning to submit a bid are required

to have at least one representative

present at the pre-bid conference. In

general, the Work included in the

Project includes the labor, materials,

tools and equipment required to con-

struct MREFPP Phase MI-5A 4th

Avenue NE Levee Extension as fully

depicted in the Drawings and Project

Manual for the Project. The Project

is located within the City of Minot

and Ward County, North Dakota. All

Bids are to be submitted on the

basis of cash payment for the Work,

and are to be enclosed in a sealed

envelope addressed to the under-

signed Chairman, endorsed as re-

quired below. The bid security must

be in a sum equal to five percent

(5%) of the full amount of the Bid

and must be in the form of a bidder’s

bond. A bidder’s bond must be exe-

cuted by the bidder as principal and

by a surety, conditioned that if the

principal’s bid is accepted and the

contract awarded to the principal,

the principal, within ten days after

notice of the award, shall execute a

contract in accordance with the

terms of the Bid and the bid bond

and any condition of the governing

body. A countersignature of a bid

bond is not required. If a successful

bidder does not execute a contract

within the ten days allowed, the

bidder’s bond must be forfeited to

the governing body and the project

awarded to the next lowest responsi-

ble bidder. The bidder must be

licensed for the full amount of the

bid as required by Section 43-07-12

of the North Dakota Century Code.

The outside of the sealed envelope

containing the bid and other required

items shall be endorsed with the fol-

lowing verbiage:

1.”Souris River Joint Water

Resource Board, Mouse River

Enhanced Flood Protection Project,

Phase MI-5A 4th Avenue NE Levee

Extension”

2.The name of the person, firm, cor-

poration, or joint venture submitting

the Bid.

3.The Bidder’s Contractor’s License

or Contractor’s License Renewal

Number.

4.Acknowledgement of Addenda.

A copy of the Bid Bond and Bidder’s

Contractor’s License or Contractor’s

License Renewal shall be included a

separate envelope from the bid. No

Bid may be read or considered if it

does not fully comply with the re-

quirements of Section 48-01.2-05 of

the North Dakota Century Code.

Any deficient Bid received will be

resealed and returned to the Bidder

immediately. The Owner reserves

the right to hold all bids for 75 days,

to reject any or all Bids and to waive

any informality or irregularity in any

Bid and to accept the Bid deemed in

the best interest of the Owner. The

Owner reserves the right to rebid the

project until a satisfactory Bid is re-

ceived. The Work shall be substan-

tially complete by October 1, 2024.

All Work shall be complete and

ready for final payment in accor-

dance with the General Conditions

by May 1, 2025. Should the Contrac-

tor fail to complete its obligations

under the Contract within the time

required herein or within such extra

time as may have been granted by

formal extensions of time approved

by the Owner, there will be deducted

from any amount due to the Con-

tractor the sum of $5,000 per calen-

dar day (with no suspension for

winter work) for each and every

calendar day that the substantial or

final completion of the Work is de-

layed. The Contractor and its Surety

will be liable for any excess. Such

payment will be as and for liquidated

damages and not as a penalty.

By order of the Souris River Joint

Water Resources Board,

Dated this 14 Day of November,

2021

Souris River Joint Water Resources

Board

David Ashley, Chairman

(January 14-21-28; February 4,

2022)

NOTICE

Notification is given that Bremer

Bank, National Association, Lawson

Building, 372 St. Peter Street, St.

Paul, MN 55102, has filed an appli-

cation with the Office of the Comp-

troller of the Currency on January

10, 2022, as specified in 12 CFR 5

for permission to relocate a branch

office currently located at 20 1st

Street Southwest, Minot, ND 58701,

to its new location at 1615 36th Ave-

nue Southwest, Minot, ND 58701.

Any person desiring to comment on

this application may file comments

in writing with the Director of District

Licensing at 425 South Financial

Place, Suite 1700, Chicago, Illinois

6060 or CE.Licensing@

occ.treas.gov within 30 days of the

date of this publication.

(January 14, 2022)

NOTICE

Notification is given that Bremer

Bank, National Association, Lawson

Building, 372 St. Peter

Street, St. Paul, MN 55102, has filed

an application with the Office of the

Comptroller of the Currency on

January 10, 2022, as specified in 12

CFR 5 for permission to relocate a

branch office currently located at

925 31st Avenue Southwest, Minot,

ND 58701, to its new location at 15

South Broadway, Minot, ND 58701.

Any person desiring to comment on

this application may file comments

in writing with the Director of District

Licensing at 425 South Financial

Place, Suite 1700, Chicago, Illinois

6060 or CE.Licensing@

occ.treas.gov within 30 days of the

date of this publication.

(January 14, 2022)

Notice of Annual Meeting

Kenmare Rural Fire Protection Dis-

trict Annual Meeting, January 24,

2022 at 7:00 pm at the Kenmare

Fire Station (use West door). Elec-

tion of one officer, vote on mill levy

and any business brought before the

meeting. Please bring voter identifi-

cation. In case of inclement weath-

er, meeting will be held the following

Monday at the same time and place.

Everyone welcome.

Layne O’Neill

Secretary/Treasurer

(January 14, 2022)

NOTICE OF HEARING PETITION

FOR ADJUDICATION OF

INTESTACY, APPOINTMENT OF

PERSONAL REPRESENTATIVES

AND FOR DETERMINATION OF

HEIRS

Probate No. 51-2021-PR-00203

IN THE DISTRICT COURT OF

WARD COUNTY, STATE OF

NORTH DAKOTA

In the Matter of the Estate of

Lloyd Herbert Emmel, Deceased.

NOTICE IS HEREBY GIVEN that

Mitchel L. Emmel has filed herin a

Petition for adjudication of Intestacy,

Appointment of Personal Represen-

tative, and for Determination of Heirs

of the estate of Lloyd Herbert Em-

mel, deceased. Hearing has been

set upon said petition on the 16th

day of February, 2022 at 9:00

o’clock a.m., at the Courtroom of the

above-named Court in the City of

Minot, County of Ward, State of

North Dakota.

Dated january 4, 2022

/s/Mitchel L. Emmel

Mitchel L. Emmel, Petitioner

10665 59th Ave. NW

Kenmare, ND 58746

Peter B. Hankla (ID #04919)

McGEE, HANKLA & BAKES, P.C.

2400 E. Burdick Expy.,

P.O. Box 998

Minot, ND 58702-0998

(701) 852-2544

(January 7-14-21, 2022)

NOTICE OF REAL ESTATE SALE

CIVIL NUMBER: 51-2020-CV-01722

IN THE STATE OF NORTH

DAKOTA, COUNTY OF WARD

IN THE DISTRICT COURT, NORTH

CENTRAL JUDICIAL DISTRICT

Freedom Mortgage Corporation

Plaintiff,

v.

Jean P. Chegwidden; Michael

Chegwidden; Unknown Spouse of

Jean P. Chegwidden; Elda Evenson

Living Trust; Evenson Properties,

L.L.P.; Mitchell B. Evenson; Syn-

chrony Bank; any person in posses-

sion, and all persons unknown,

claiming any estate or interest in, or

lien or encumbrance upon, the real

estate described in the complaint;

any person in possession,

Defendants.

Judgment in the amount of

$232,530.89 having been entered in

favor of Plaintiff and against Defen-

dants, which Judgment was filed

with the Clerk of Courts of Ward

County, North Dakota, on November

1, 2021, for the foreclosure of a real

estate mortgage. Notice is hereby

given pursuant to said Judgment

that the real property described as:

Lot 2, Clock 3, Valli Hai Addition

to the City of Minot, Ward County

North Dakota. Real Property

address: 1209 12th St. NW, Minot,

ND 58703

The above real property is the sub-

ject of the Mortgage dated June 24,

2013, which Mortgagor, Jean P.

Chegwidden, executed and

delivered to Mortgage Electronic

Registration Systems, Inc., as Mort-

gagee, as nominee for Mortgage

Research Center, LLC DBA

Veterans United Home Loans, its

successors and assigns, and record-

ed in the office of the Clerk and

Recorder of Ward County, North

Dakota, on June 26, 2013, as Instru-

ment Number 2960023, which is

subject to the entered Judgment.

Said Mortgage was assigned to

Plaintiff, its successors or assigns,

by Assignment of Mortgage record-

ed May 28, 2021, Instrument

Number 3052902 MTGASS. In order

to realize the amount of

$232,530.89, as of November 1,

2021, plus interest accruing

thereafter on said amount at the rate

of 3.37500% per year together with

the costs and expenses of sale, will

be sold subject to redemption as

provided by law as one parcel of

land at public auction, subject to the

lien for unpaid real estate taxes and

assessments of Ward County, North

Dakota, and easements and restric-

tions of record, to the highest bidder

for cash under the direction of the

Sheriff of Ward County, North Dako-

ta, at the main entrance of the Ward

County Courthouse located at 315

3rd Street SE, Minot, North Dakota

58701, on February 9, 2022 (“Sale

Date”), at 10:00 AM. If the sale is set

aside for reason, the Purchaser at

the sale shall be entitled only to a re-

turn of the deposit paid. The pur-

chaser shall have no further

recourse against the Mortgagor, the

Mortgagee or the Mortgagee’s attor-

ney.

DATED this 3rd day of January

2022.

SHERIFF OF WARD COUNTY

For:Robert Roed

By:Jamie Williams

Sheriff/Deputy Sheriff of Ward

Halliday, Watkins & Mann, P.C.

By:Zachary Nesbit

Zachary Nesbit

Attorneys for Plaintiff

376 East 400 South, Suite 300

Salt Lake City, UT 84111

Tel: 801-355-2886

Email: zach@hwmlawfirm.com

Bar: 07552

(January 7-14-21, 2022)

N O T I C E T O B I D D E R S

The City Clerk of the City of Minot

will receive sealed bids at her office

at City Hall until 11:00 a.m. on Tues-

day, January 25, 2022, for furnishing

the City of Minot the following:

“Remote Controlled 60” Rotary

Mower with Tracks”

Project #4638

Specifications and general instruc-

tions to bidders are available in the

Public Works Office at 1025 31st St

SE, on the City of Minot webpage

www.minotnd.orgunder City Clerk

department, or by calling

701-857-4140. The bid envelope

shall be plainly marked:

“Bid for One (1) RC Mower”

Project #4638

The City Council of the City of Minot

reserves the right to reject any or all

bids and to award the contract as it

deems to be in the best interest of

the City of Minot. Each bid must be

accompanied by a bidder’s bond, a

certified check, or a cashier’s check

in the amount of five percent (5%) of

the bid and must be in a separate

envelope marked “bid bond” and at-

tached to the outside of the bid.

Bidders are invited to be present at

the above-mentioned time and place

for the opening of bids.

Mikayla McWilliams

City Clerk

(January 7-14, 2021)

SECTION 00 01 11

ADVERTISEMENT FOR BIDS

SOURIS RIVER JOINT WATER

RESOURCES BOARD

MOUSE RIVER ENHANCED

FLOOD PROTECTION PROJECT

PHASE MI-5B.1, EQUIPMENT

STORAGE BUILDING

RELOCATION

MINOT, WARD COUNTY,

NORTH DAKOTA

NOTICE IS HEREBY GIVEN that

the Souris River Joint Water

Resources Board will receive sealed

Bids for the construction of the

Mouse River Enhanced Flood Pro-

tection Project Phase MI-5B.1,

Equipment Storage Building Reloca-

tion, at Minot City Hall in the Council

Chambers, 515 2nd Avenue

Southwest, Minot, North Dakota,

58702, until 10:00 AM CDT, January

31, 2022, at which time all Bids will

be publicly opened and read aloud.

All Bids must be submitted, and all

work shall be done, in full and strict

compliance with the Plans and

Specification for this Project. Com-

plete digital project bidding docu-

ments are available at

www.questcdn.com. You may down-

load the digital plan documents for

$100.00 by inputting Quest project

#8098185 on the website’s Project

Search page. Please contact

QuestCDN.com at (952) 233-1632

or info@questcdn.com for assis-

tance in a free membership registra-

tion, downloading, and working with

this digital project information. An

optional paper set of project docu-

ments is also available for a nonre-

fundable price of $500 per set.

Makes checks payable to Houston

Engineering, Inc. and send to 1401

21st Avenue North, Fargo, ND

58102. Potential bidders may con-

tact Rusten Roteliuk at Houston En-

gineering, Inc. at (701) 852-7931, or

by email at

rroteliuk@houstoneng.com, with any

questions. Copies of the documemts

are available for viewing at the fol-

lowing locations during normal busi-

ness hours of 8:00 am to 4:30 pm,

Monday through Friday, excluding

holidays:

Houston Engineering, Inc.

3900 13th Avenue SE

Minot, ND

Houston Engineering, Inc.

1401 21st Avenue North

Fargo, ND

A pre-Bid conference for interested

bidders will be held on January 13,

2022, from 10:00 AM CDT until

11:00 AM CDT. The conference will

be hosted in person at the office of

Houston Engineering at 3900 13th

Avenue SE, Minot, ND and on Mi-

crosoft Teams, and will also be ac-

cessible via a call-in conference line.

All bidders planning on attending

the meeting by Microsoft Teams

shall send an invite request, via

email, with the subject “MI-5B.1

Pre-Bid” to Rusten Roteliuk at

rroteliuk@houstoneng.com prior to

Noon on January 12th, 2022. The

Engineer will also be available, if re-

quested, to meet any prospective

bidders at the project site immedi-

ately following the pre-Bid meeting.

In general, the Work included in the

Project includes the labor, materials,

tools and equipment required to con-

struct MREFPP Phase MI-5B.1

Equipment Storage Building Relo-

cation as fully depicted in the Draw-

ings and Project Manual for the Pro-

ject. The Project is located within

the City of Minot, North Dakota.

All Bids are to be submitted on the

basis of cash payment for the Work,

and are to be enclosed in a sealed

envelope addressed to the under-

signed Chairman, endorsed as re-

quired below. The bid security must

be in a sum equal to five percent

(5%) of the full amount of the Bid

and must be in the form of a bidder’s

bond. A bidder’s bond must be exe-

cuted by the bidder as principal and

by a surety, conditioned that if the

principal’s bid is accepted and the

contract awarded to the principal,

the principal, within ten days after

notice of the award, shall execute a

contract in accordance with the

terms of the Bid and the bid bond

and any condition of the governing

body. A countersignature of a bid

bond is not required. If a successful

bidder does not execute a contract

within the ten days allowed, the

bidder’s bond must be forfeited to

the governing body and the project

awarded to the next lowest responsi-

ble bidder. The bidder must be

licensed for the full amount of the

bid as required by Section 43-07-12

of the North Dakota Century Code.

The outside of the sealed envelope

containing the bid and other required

items shall be endorsed with the fol-

lowing verbiage:

1.”Souris River Joint Water

Resource Board, Mouse River

Enhanced Flood Protection Project,

Phase MI-5B.1 Equipment Storage

Building Relocation”

2.The name of the person, firm, cor-

poration, or joint venture submitting

the Bid.

3.The Bidder’s Contractor’s License

or Contractor’s License Renewal

Number.

4.Acknowledgement of Addenda.

A copy of the Bid Bond and Bidder’s

Contractor’s License or Contractor’s

License Renewal shall be included a

separate envelope from the bid. No

Bid may be read or considered if it

does not fully comply with the re-

quirements of Section 48-01.2-05 of

the North Dakota Century Code. Any

deficient Bid received will be

resealed and returned to the Bidder

immediately. The Owner reserves

the right to hold all bids for 60 days,

to reject any or all Bids and to waive

any informality or irregularity in any

Bid and to accept the Bid deemed in

the best interest of the Owner. The

Owner reserves the right to rebid the

project until a satisfactory Bid is re-

ceived. All Work shall be complete

and ready for final payment in accor-

dance with the General Conditions

by July 1, 2022. Should the Contrac-

tor fail to complete its obligations

under the Contract within the time

required herein or within such extra

time as may have been granted by

formal extensions of time approved

by the Owner, there will be deducted

from any amount due to the Con-

tractor the sum of $500 per day (with

no suspension for winter work) for

each and every calendar day that

the substantial or final completion of

the Work is delayed. The Contractor

and its Surety will be liable for any

excess. Such payment will be as

and for liquidated damages and not

as a penalty. By order of the Souris

River Joint Water Resources Board,

Dated this 8th Day of December,

2021

Souris River Joint Water

Resources Board

David Ashley, Chairman

(January 7-14-21, 2022)