Legal Notices 3-27
ADVERTISEMENT FOR BIDS
City of Minot, North Dakota
Storm Sewer District 123
City Project # 4393
NOTICE IS HEREBY GIVEN that
the City of Minot, North Dakota will
receive sealed Bids for the con-
struction of STORM SEWER DIS-
TRICT 123, at the office of the City
Clerk, 515 Second Avenue SW
(Second Floor), Minot, North Dako-
ta, until 11:00 AM Tuesday, April 14,
2020, at which time all Bids will be
publicly opened and read in the
Council Chambers. All Bids must be
submitted, and all work shall be
done, in full and strict compliance
with: 1. The Plans & Contract Docu-
ments for this project; 2. Any Special
Conditions for this project; 3. The
2019 City of Minot Standard Specifi-
cations and Details. Project bidding
documents are available for exami-
nation and/or $100 purchase Mon-
day through Friday from 8:00 am to
12:00 pm and 1:00 pm to 5:00 pm at
the office of Ackerman-Estvold,
1907 17th Street SE, Minot ND
58701. Complete digital project bid-
ding documents are available at
www.ackerman-estvold.com/projects
or www.questcdn.com. You may
download the digital plan documents
for $50 by inputting Quest project
#6892543 on the website’s Project
Search page. Please contact
QuestCDN.com at 952-233-1632 or
info@questcdn.com for assistance
in free membership registration,
downloading, and working with this
digital project information. Potential
bidders may contact
Ackerman-Estvold at (701)
837-8737 with any questions. Gen-
erally, the Work covered by the
Plans and Specifications for Storm
Sewer District 123 consists of the
materials, labor, tools, and equip-
ment required for the construction of
storm sewer improvements and the
reconstruction of intersections along
10th Street SW. The Work includes
approximately 5,700 LF of storm
sewer along 10th Street SW, 34th
Avenue SW, 32nd Avenue SW, and
7th Street SW. The Work shall also
include the removal and replace-
ment of about 5,000 LF of curb &
gutter, 9,300 SY of cement stabil-
ized base, 3,800 Ton of asphalt
pavement, and other incidentals as
necessary to complete the project.
Details of the construction are in-
cluded in the Drawings, Project
Manual, and the 2019 City of Minot
Standard Specifications and Details.
All Bids are to be submitted on the
basis of cash payment for the Work
and Materials necessary to complete
the project. Each bid must be ac-
companied by a separate envelope
containing the contractor’s license
and bid security. The bid security
must be in a sum equal to five per-
cent of the full amount of the bid and
must be in the form of a bidder’s
bond. A bidder’s bond must be exe-
cuted by the bidder as principal and
by a surety, conditioned that if the
principal’s bid is accepted and the
contract awarded to the principal,
the principal, within ten days after
notice of the award, shall execute a
contract in accordance with the
terms of the bid and the bid bond
and any condition of the governing
body. A countersignature of a bid
bond is not required under this sec-
tion. If a successful bidder does not
execute a contract within the ten
days allowed, the bidder’s bond
must be forfeited to the Owner and
the project awarded to the next
lowest responsible bidder. Bidders
must be licensed for the full amount
of the bid as required by section
43-07-12 of the North Dakota Centu-
ry Code. No Bid may be read or con-
sidered if it does not fully comply
with the requirements of Section
48-01.2-05 of the North Dakota Cen-
tury Code. The Owner reserves the
right to hold all Bids for 30 days, to
reject any or all Bids, to waive any
informality or irregularity in any Bid,
to accept the Bid deemed in the best
interest of the Owner, and to rebid
the project until a satisfactory bid is
received. There shall be endorsed
upon the outside of the envelope
containing the Bid, the following: 1.
“City of Minot, North Dakota, Storm
Sewer District 123, Project Number
4393”. 2. The name of the person,
firm, corporation, or joint venture
submitting the Bid. 3. The Bidder’s
Contractor’s License or Contractor’s
License Renewal Number. 4. Ack-
nowledgement of the Addenda, if
any. Any deficient Bid received will
be resealed and returned to the
Bidder immediately. Milestone 1 in-
cludes storm sewer and roadway
reconstruction for Sta. 20+91 to
33+00 and 61+50 to 67+00, to
be completed by July 15, 2020. All
work shall be substantially complete
by October 16, 2020. All work shall
be completed and ready for final
payment in accordance with the
General Conditions by October 30,
2020. Should the Contractor fail to
complete its obligations under the
Contract within the time required
herein or within such extra time as
may have been granted by formal
extensions of time approved by the
Owner, there will be deducted from
any amount due to the Contractor
the sum of $1,000 per day for each
and every calendar day that the
completion of the Work is delayed.
The Contractor and his Surety will
be liable for any excess. Such pay-
ment will be as and for liquidated
damages and not as a penalty.
By order of the City Council of the
City of Minot, North Dakota.
Dated this 16th day of March, 2020.
Kelly Matalka, City Clerk
(March 20-27; April 3, 2020)
ADVERTISEMENT FOR BIDS
CITY OF TIOGA
TIOGA, NORTH DAKOTA
NORTHEAST TIOGA RECON-
STRUCTION – PHASE 1
SANITARY SEWER, WATER
MAIN, STORM SEWER AND
STREET IMPROVEMENTS
MOORE PROJECT NO. 21092
General Notice
Owner is requesting Bids for the
construction of the project listed
above. Bids for the construction of
the Project will be received at City
Hall located at 16 1st Street
Northeast, Tioga, ND 58852, until
April 8, 2020 at 2:00 p.m. local time.
At that time the Bids received will be
“publicly” opened and read. The Pro-
ject includes the following Work:
Replacement of the following but not
limited to infrastructure Sanitary
Sewer, Water Main, Storm Sewer,
Curb and Gutter, Asphalt Pavement,
Driveways, Sidewalk. Obtaining the
Bidding Documents. Digital project
bidding documents will be available
at www.mooreengineeringinc.com
by clicking the Bid Information tab,
or at www.questcdn.com. You may
download the complete set of digital
documents for a nonrefundable fee
of $20.00 by locating eBidDocâ€
Number 6908137 on the website.
Please contact QuestCDN.com at
952-233-1632 or
info@questcdn.com for assistance
in membership registration, down-
loading and working with this digital
project information.
The Issuing Office for the Bidding
Documents is:
Moore Engineering, Inc.
2080 36th Ave SW, Suite 215,
Minot, ND 58701
Prospective Bidders may examine
the Bidding Documents at the Issu-
ing Office Monday through Friday
between the hours of 8:00 a.m. to
5:00 p.m. Partial sets of Bidding Do-
cuments will not be available from
the Issuing Office. Neither Owner
nor Engineer will be responsible for
full or partial sets of Bidding Docu-
ments, including addenda, if any,
obtained from sources other than the
Issuing Office. Each bid must be ac-
companied by a separate envelope
containing a bidder’s bond in a sum
equal to 5% of the full amount of the
bid executed by the bidder as princi-
pal and by a surety, conditioned that
if the principal’s bid is accepted and
a contract is awarded to the princi-
pal, the principal, within ten (10)
days after the notice of the award,
shall execute a contract in accor-
dance with the terms of the bid and
the bid bond, and any conditions of
the City of Tioga, as required by law.
A countersignature of a bid bond is
not required. If the City of Tioga
elects to award a contract to the
lowest responsible bidder, and the
lowest responsible bidder does not
execute a contract within ten (10)
days, the bidder’s bond will be for-
feited to the City of Tioga, and the
City of Tioga may award the project
to the next lowest responsible
bidder. Each bidder must possess a
valid North Dakota contractor’s
license for the full amount of their
bid, as required by N.D.C.C. Å’
43-07-7. Each bidder MUST en-
close a copy of their Contractor’s
License or Certificate of Renewal, is-
sued by the North Dakota Secretary
of State, in their bid bond envelope,
and each license must be valid and
dated at least 10 days prior to the
date set for bid opening, as required
under N.D.C.C. Å’ 43-07-12. The City
of Tioga will not read or consider
any bid that does not fully comply
with the requirements above, or the
requirements of N.D.C.C. Å’
48-01.2-05. The City of Tioga will
reseal any deficient bid submitted
and return it to the bidder immedi-
ately. Instructions to Bidders. For
all further requirements regarding
bid submittal, qualifications, pro-
cedures, and contract award, refer to
the Instructions to Bidders that are
included in the Bidding Documents.
This Advertisement is issued by:
Owner: City of Tioga
By: Abby Salinas
Title: Auditor
Date: March 18, 2020
TIOGA TRIBUNE
March 19, 2020 MINOT DAILY
NEWS
(March 20-27; April 3, 2020)
Call for Bids Food Service at
Rolette County Jail
Rolette County is requesting bids for
Food Service at the Rolette County
Jail. The bid shall provide for:
Breakfast, Lunch and Dinner, seven
days a week. If you are interested in
submitting a bid, please contact the
Rolette County Auditor for detailed
specs by calling 477-5665 or at the
Rolette County Auditor’s office, 102
2nd ST NE, Rolla, ND. Bids must
be submitted by 4:30 P.M. on March
22nd, 2019, to the Rolette County
Auditor’s office. Dated this 6th day of
March, 2019
Valerie McCloud
Rolette County Auditor
(March 11-15, 2019)
CALL FOR BIDS
Harrison Township will accept bids
for chip seal on Whitetail Ridge, Del
Nor Drive, Rolling Hills & Country
Club Heights. Written & sealed bids
should be submitted by April 17,
2020, to Harrison Twp Clerk at 4520
46th St. NW, Minot ND 58703.
Harrison Twp reserves the right to
refuse any and all bids.
(March 25-26-27-28, 2020)
NOTICE OF EXECUTION SALE
Civil No. 51-2019-CV-01195
IN DISTRICT COURT, WARD
COUNTY, NORTH DAKOTA
WELLS FARGO BANK, N.A.,
Plaintiff,
vs.
DON K. CALDWELL, et al,
Defendant.
NOTICE IS HEREBY GIVEN, that
by virtue of a judgment and decree
of foreclosure rendered and given in
the District Court in and for the
County of Ward, North Dakota,
North Central Judicial District, en-
tered and docketed in the Office of
the Clerk of said Court on February
06, 2020, in Ward County civil case
number 51-2019-CV-01195; on
which day it was adjudged that there
was due and owing the Plaintiff from
the Defendant, Don K. Caldwell, an
unmarried man, together with costs
and disbursements of said action,
the sum of $80,214.23, and by virtue
of a Special execution issued to me
by the Clerk of said Court, I will sell
the real property described in said
judgment and hereafter described to
the highest bidder for cash at public
auction at the front door of the Ward
County Courthouse,North Dakota,
on April 29, 2020, at the hour of
10:00 AM(CT) of that dayto satisfy
the amount due with accrued costs
and interest at the date of sale, or so
much thereof as the proceeds of
said sale applicable thereto will
satisfy. The premises to be sold as
aforesaid are situated in the County
of Ward,State of North Dakota, and
are more particularly described as
follows:
LOT 16, REARRANGEMENT OF
GREEN VALLEY ADDITION TO
THE CITY OF MINOT, WARD
COUNTY, NORTH DAKOTA
(Street Address: 218 Souris Dr.,
Minot, ND 58701-5068)
IN TESTIMONY WHEREOF, I have
hereunto set my hand and seal the
10th day of March, 2020.
For: Robert Roed
Sheriff of Ward County,
North Dakota
By:/s/ Jamie Williams
Jamie Williams, Deputy Sheriff
Janelle G. Ewing
The Sayer Law Group, P.C.
Attorneys for Plaintiff
925 E. 4th St.
Waterloo, IA 50703
(319)234-2530
Attorney ID No.: 08611
generalupdates@sayerlaw.com
(March 20-27; April 3, 2020)
NOTICE TO BIDDERS
The City Clerk of the City of Minot
will receive cost proposals from
qualified manufacturers or their
representatives at her office at City
Hall until 11:00 a.m. on Tuesday,
April 14, 2020 for furnishing the City
of Minot the following: Automated
Brine Production System. Project
#4409. Specifications and general
instructions to bidders are available
in the Public Works Office at 1025
31st St. SE, on the City of Minot
webpage www.minotnd.org under
City Clerk department, or by calling
701-857-4140. The bid envelope
shall be plainly marked: “Automated
Brine Production System”. Project
#4409. The City Council of the City
of Minot reserves the right to reject
any or all bids and to award the con-
tract as it deems to be in the best in-
terest of the City of Minot. Each bid
must be accompanied by a bidder’s
bond, a certified check, or a
cashier’s check in the amount of five
percent (5%) of the bid and must be
in a separate envelope marked “bid
bond” and attached to the outsideof
the bid. Bidders are invited to be
present at the City Clerk office, 515
2nd Ave. SW for the opening of bids.
Kelly Matalka, City Clerk
(March, 27; April 3, 2020)
NOTICE TO CREDITORS
Probate No. 51-2020-PR-51
IN THE DISTRICT COURT,
STATE OF NORTH DAKOTA,
COUNTY OF WARD,
NORTH CENTRAL
JUDICIAL DISTRICT
In the matter of the Estate of
Jeanice L. Officer, Deceased
NOTICE IS HEREBY GIVEN that
Bruce G. Peterson has been ap-
pointed personal representative of
the Estate of Jeanice L. Officer. All
persons having claims against Jean-
ice L. Officer are required to present
their claims within three (3) months
after the date of the first publica-
tion of this notice or said claims
will be forever barred. Claims
must either be presented to the Per-
sonal Representative, Bruce G.
Peterson, at P.O. Box 998, Minot,
ND 58702-0998, or filed with the
Court.
Dated this 23rd day of March, 2020.
/s/Bruce G. Peterson
Bruce G. Peterson,
Personal Representative
(March 27; April 3-10, 2020)
REQUEST FOR PROPOSAL
The Fort Berthold Housing Authority
is requesting proposals for (32) 2, 3
and 4 bedroom modular homes will
be approximately 1400-1700 square
feet and 16 split entry homes will be
approximately 1000 upper to replace
48 homes on the Fort Berthold Indi-
an Reservation. Proposals must in-
clude complete construction of new
homes hauled and set on new Foun-
dations. Proposals should not in-
clude foundations. Proposals will be
for turn-key homes including, all
stitching and seaming of exterior
and interior, all HVAC, plumbing and
electrical except for electrical tie in,
water and sewer connections. No
proposal for Manufactured homes or
homes built on metal I-beams will be
considered. Deadline for proposal
will be March 29, 2020. For more
detailed information please contact
FBHA.
Contact: Forest Mandan
Cell: 701-421-7272
Office: 701-627-4731 Ext. 228
Email: forest@fbha.org
Contact: Toni Parisien
Cell: 701-421-0479
Office: 701-627-4131 Ext. 240
Email: toni@fbha.org
FBHA has the right to reject any and
all proposals and / or solicitations.
(February 26-27-28-29; March
2-3-4-5-6-7-9-10-11-12-13-14-16-17-18-19-20-21-23-24-25-26-27-28,
2020)
SECTION 00 01 11
ADVERTISEMENT FOR BIDS
SOURIS RIVER JOINT WATER
RESOURCES BOARD
MOUSE RIVER ENHANCED
FLOOD PROTECTION PROJECT
PHASE BU-1B BURLINGTON
BURLINGTON, WARD COUNTY,
NORTH DAKOTA
NOTICE IS HEREBY GIVEN that
the Souris River Joint Water
Resources Board will receive sealed
Bids for the construction of the
Mouse River Enhanced Flood Pro-
tection Project Phase BU- 1B Bur-
lington, at Burlington City Hall 225
Wallace Street, PO Box 159, Bur-
lington, ND 58722 until 10:00 AM
CST, April 16, 2020, at which time
all Bids will be publicly opened and
read aloud. All Bids must be submit-
ted, and all work shall be done, in
full and strict compliance with the
Plans and Specifications for this
Project. Complete digital project bid-
ding documents are available at
www.questcdn.com. You may down-
load the digital plan documents for
$100 by inputting Quest project
#6558890 on the website’s Project
Search page. Please contact
QuestCDN.com at (952) 233-1632
or info@questcdn.com for assis-
tance in a free membership registra-
tion, downloading, and working with
this digital project information. An
optional paper set of project docu-
ments is also available for a nonre-
fundable price of $500 per set. Make
checks payable to Barr Engineering
Co. and send to 4300 MarketPointe
Drive, Minneapolis, MN, 55435. Po-
tential bidders may contact Barr En-
gineering Co. at (952) 832-2600 with
any questions. Copies of the docu-
ments are available for viewing at
the following locations during normal
business hours, Monday through Fri-
day, excluding holidays:
Ackerman-Estvold Engineering: 1907
17th Street SE, Minot, ND
Barr Engineering Co.:
234 West Century Avenue,
Bismarck, ND
Barr Engineering Co.:
4300 MarketPointe Drive, Minneap-
olis, MN
A mandatory pre-Bid conference for
interested bidders will be held on
April 2, 2020 at Burlington City Hall
225 Wallace Street, PO Box 159,
Burlington, ND 58722 at 10:00 AM
CST. Any companies/teams/joint
ventures planning to submit a bid for
any Contract No. 1 – 3 must have at
least one representative present at
the mandatory pre-Bid conference.
In general, the Work included in the
Project includes the labor, materials,
tools, and equipment required to
construct MREFPP Phase BU- 1B
Burlington as fully depicted in the
Drawings and Technical Specifica-
tions for the Project. The project is
located within the City of Burlington,
North Dakota. All Bids are to be
submitted on the basis of cash pay-
ment for the Work, and are to be en-
closed in a sealed envelope ad-
dressed to the undersigned Chair-
man, endorsed as required below.
Each bid must be accompanied by a
separate envelope containing the
contractor’s license and bid
security.The bid security must be in
a sum equal to five percent (5%) of
the full amount of the Bid and must
be in the form of a bidder’s bond. A
bidder’s bond must be executed by
the bidder as principal and by a
surety, conditioned that if the
principal’s bid is accepted and the
contract awarded to the principal,
the principal, within ten days after
notice of the award, shall execute a
contract in accordance with the
terms of the Bid and the bid bond
and any condition of the governing
body. A countersignature of a bid
bond is not required. If a successful
bidder does not execute a contract
within the ten days allowed, the
bidder’s bond must be forfeited to
the governing body and the project
awarded to the next lowest responsi-
ble bidder. The bidder must be
licensed for the full amount of the
bid as required by Section 43-07-12
of the North Dakota Century Code.
The outside of the sealed envelope
containing the bid and other required
items shall be endorsed with the fol-
lowing verbiage: 1. “Souris River
Joint Water Resource Board, Mouse
River Enhanced Flood Protection
Project, Phase BU- 1B Burlington” 2.
The name of the person, firm, cor-
poration, or joint venture submitting
the Bid. 3. The Bidder’s Contractor’s
License or Contractor’s License
Renewal Number. 4. Acknowledge-
ment of Addenda. No Bid may be
read or considered if it does not fully
comply with the requirements of
Section 48-01.2-05 of the North
Dakota Century Code. Any deficient
Bid received will be resealed and re-
turned to the Bidder immediately.
The Owner reserves the right to hold
all bids for 75 days, to reject any or
all Bids and to waive any informality
or irregularity in any Bid and to ac-
cept the Bid deemed in the best in-
terest of the Owner. The Owner
reserves the right to rebid the project
until a satisfactory Bid is received.
The Work shall be substantially
complete by August 7, 2021. All
Work shall be complete and ready
for final payment in accordance with
the General Conditions by Sep-
tember 25, 2021. Should the Con-
tractor fail to complete its obligations
under the Contract within the time
required herein or within such extra
time as may have been granted by
formal extensions of time approved
by the Owner, there will be deducted
from any amount due to the Con-
tractor the sum of $5,000.00 per day
(with no suspension for winter work)
for each and every calendar day that
the substantial or final completion of
the Work is delayed. The Contractor
and his Surety will be liable for any
excess. Such payment will be as
and for liquidated damages and not
as a penalty.
By order of the Souris River Joint
Water Resources Board,
Dated this March 16, 2020
Souris River Joint Water Resources
Board
David Ashley, Chairman
(March 20-27; April 3, 2020)
SUMMONS
Employer Account No. 1292433
IN DISTRICT COURT, STATE OF
NORTH DAKOTA, COUNTY OF
WARD, NORTH CENTRAL
JUDICIAL DISTRICT
State of North Dakota by
Workforce Safety & Insurance,
Plaintiff,
v.
Todd Ferm Construction LLC, and
Todd Ferm, Individually,
Defendants.
THE STATE OF NORTH DAKOTA
TO THE ABOVE NAMED DEFEN-
DANTS:
You are hereby summoned and re-
quired to appear and defend against
the attached complaint which is
herewith served upon you, by serv-
ing upon the plaintiff an answer
within twenty-one (21) days after the
service of this summons upon you,
exclusive of the date of service. If
you fail to serve an answer, judg-
ment by default will be taken against
you for the relief demanded in the
complaint.
Dated this 19th day of March, 2020.
/s/ Anne Jorgenson Green
Anne Jorgenson Green
Special Assistant Attorney General
State Bar ID No. 05691
Workforce Safety & Insurance
PO Box 5585, Bismarck, North
Dakota 58506-5585
(701) 328-3800/ agreen@nd.gov
Attorney for Plaintiff
(March 27; April 3-10, 2020)