Legal Notices 1-3
ADVERTISEMENT FOR BIDS
FOR THE CITY OF MINOT 2019
BANK REPAIRS & OUTFALL PIPE
REHABILITATION PROJECT
MINOT SWIF ACTION E
CITY OF MINOT, WARD COUNTY,
NORTH DAKOTA
CITY OF MINOT PROJECT
3135.2E
NOTICE IS HEREBY GIVEN that
the City of Minot, North Dakota, in-
vites and will receive sealed propo-
sals (bids) up to the hour of 11.00
a.m., local time, on January 21,
2020, for the furnishing to the City of
Minot of all transportation, labor, ma-
terials, tools, equipment, services,
permits, utilities, and other items
necessary for said work, in accor-
dance with the drawings and con-
tract documents on file in the office
of the City Clerk, Minot, North Dako-
ta. At said time, said proposals will
be publicly opened and read aloud
at Council Chambers at City Hall of
the City of Minot, North Dakota lo-
cated at 515 2nd Ave SW, Minot,
ND 58701. Bids shall conform to and
be responsive to the Contract Docu-
ments for the work. The Contract
Documents will be available after
December 20, 2019 at the following
locations:
Houston Engineering, Inc.
18 3rd Street SE, Suite 100
Minot, ND 58701-3700
Telephone (701) 852-7931
Fax (701) 858-5655
Houston Engineering, Inc.
1401 21st Avenue North
Fargo, ND 58102
Telephone (701) 237-5065
Fax (701) 237-5101
City of Minot Public Works
1025 31st St. SE
Minot, ND 58701
Telephone (701) 857-4140
Major items for City of Minot Project
3135.2E include, but are not limited
to:
¯Mobilization
7,000 CY – Excavation
¯16,000 TON -Granular Riprap
Bedding
¯16,000 TON – NDDOT Grade I
Riprap
¯1 LS – Concrete Outfall Structure
w/ Flap Gate and Stop Logs (60″
RCP)
¯400 LF – Remove Storm Sewer
(60″ RCP)
¯360 LF 60″ RCP Storm Sewer
¯450 SY – Concrete
Pavement/Sidewalk
¯EA – Salvage and Reinstall Hy-
drant w/ 6″ Gate Valve
¯19,500 SY – Seed and Hydromulch
Erosion Control
Copies of plans and specifications
may be obtained following receipt of
payment of $100.00 per set,
non-refundable, or a CD may be ob-
tained with the documents in elec-
tronic (pdf) format following receipt
of payment of $25 per set, nonre-
fundable, from the following:
Houston Engineering, Inc.
18 3rd Street SE Suite 100
Minot, ND 58701-3700
Complete digital project bidding do-
cuments, the Advertisement for
Bids, Planholders List, Addenda,
and Bid Results will be available for
download for $25 from the Bid Info
page at www.houstoneng.com or at
www.questcdn.com (search eBid-
Doc# 6622585). Each bid shall be
submitted on a form furnished as
part of the contract documents and
must be accompanied by a separate
envelope containing a Bidder’s Bond
with Acknowledgement of Surety in
an amount not less than 5% of the
full amount of the bid made payable
to the order of or for the benefit of
the City of Minot, North Dakota. The
bid bond shall be executed by the
bidder as principal and by a surety
company authorized to do business
in the State of North Dakota, condi-
tioned that if the principal’s Bid be
accepted and the contract awarded
to the principal, within ten (10) days
after Notice of Award, the Principal
shall execute a contract in accor-
dance with the terms of the bid and
contractor’s performance and pay-
ment bonds as required by law and
the regulations and determinations
of the City of Minot. A bid submitted
without this information properly en-
closed in the bid bond envelope
shall not be read nor considered and
the envelope shall be resealed and
bid returned to the bidder immedi-
ately. Each bid shall be sealed and
delivered to the City of Minot at the
location designated in this notice for
the opening of proposals at or before
the time in this notice provided. All
Bidders shall hold a valid North
Dakota Contractor’s license of the
proper class and shall enclose a
copy of the license or Certificate of
Renewal of the license in the same
envelope as the Bidder’s Bond.
Bidders shall submit proof of qualifi-
cations to perform the Work as
described in the Instructions to
Bidders. Substantial Completion for
all Work shall be September 4,
2020. Final completion shall be Oc-
tober 2, 2020. The City of Minot will
award the contract to the lowest
responsive and responsible
Bidder(s). The City of Minot
reserves the right to reject any and
all bids, and to waive any and all ir-
regularities in any bid. BY THE
ORDER OF THE CITY COUNCIL
OF THE CITY OF MINOT, NORTH
DAKOTA.
Kelly Matalka, City Clerk
(December 20-27, 2019; January 3,
2020)
NOTICE OF SALE
United States v. David A. Thompson
and Gina L. Thompson, a/k/a Gina
L. Derreberry, Case No.
1:19-cv-083. Notice is hereby given
that by virtue of a Judgment entered
and given in the United States Dis-
trict Court for the District of
North Dakota, on October 17, 2019,
in favor of the United States of
America, as plaintiff, and against
DAVID A. THOMPSON and GINA L.
THOMPSON, a/k/a GINA L. DER-
REBERRY, as defendants, it has
been adjudged that there is due and
owing to plaintiff by defendant DA-
VID A. THOMPSON and GINA L.
THOMPSON, a/k/a GINA L. DER-
REBERRY, principal in the sum of
$165,926.57 and interest through
July 3, 2019, of $18,014.06, with in-
terest accruing thereafter until the
date of judgment at the rate of 2.563
percent per annum, together with
costs and disbursements of this ac-
tion in the sum of $466.45 making a
total of $184,407.08, with interest
accruing after entry of judgment at
the legal rate until paid in full. The
United States Marshal received a
copy of the Judgment, duly certified
by the Clerk of said Court, which
directs the United States Marshal to
sell the mortgaged property
described in the Judgment at public
auction to the highest and best
bidder for cash on the date of the
sale and all the right, title and in-
terest of the defendants in the pro-
perty described in the aforemen-
tioned Judgment (and as described
below) subject to all outstanding
liens and mortgages, assignments
on record, known and unknown.
The purchaser of the property may
be liable for outstanding mortgages,
liens and assignments. The plaintiff
has a paramount and subsisting lien
on the following described real
estate situated in the County of
Ward, State of North Dakota, which
will be sold by the United States
Marshal:
Lot 9, Block 7, Eastwood Park Ad-
dition to the City of Minot, Ward
County, North Dakota.
The sale will be held on January 15,
2020, at the front door of the Ward
County Courthouse, Minot, North
Dakota at 10:00 A.M. (Central
Time). Any individual who is in-
terested in obtaining the amount that
will be bid at the sale by United
States Small Business Administra-
tion should contact Stacey Dawes at
(303) 844-0529. Personal checks
will not be accepted. Payment must
be in the form of a cashier’s check
or money order available within two
hours after the sale. In the event
that the United States is compelled
to reschedule the sale because the
highest bidder cannot pay the bid
price in the manner and time re-
quired, said bidder will be liable for
the costs of resale.
Dated: December 9, 2019.
Dallas Carlson, United States
Marshal for the District of
North Dakota.
(December 13-20-27, 2019; January
3, 2020)