Legal Notices 4-25
ADVERTISEMENT FOR BIDS
SOURIS RIVER JOINT WATER
RESOURCES BOARD
MOUSE RIVER ENHANCED
FLOOD PROTECTION PROJECT
PHASE BU-1E BURLINGTON
BRUNELLE HOME RAISE
BURLINGTON, NORTH DAKOTA
NOTICE IS HEREBY GIVEN that
the Souris River Joint Water
Resources Board will receive sealed
Bids for the construction of the
Mouse River Enhanced Flood Pro-
tection Project Phase BU-1E Bur-
lington Brunelle Home Raise at the
office of Ackerman-Estvold, 1907
17th Street SE, Minot, North Dakota,
58701, until 11:00 AM CDT, Mon-
day, May 2, 2022, at which time all
Bids will be publicly opened and
read aloud. All Bids must be submit-
ted, and all work shall be done, in
full and strict compliance with the
Plans and Technical Specifications
for this Project. Complete digital pro-
ject bidding documents are available
at www.questcdn.com. You may
download the digital plan documents
for $50 by inputting Quest project
#8167465 on the website’s Project
Search page. Please contact
QuestCDN.com at (952) 233-1632
or info@questcdn.com for assis-
tance in a free membership registra-
tion, downloading, and working with
this digital project information. An
optional paper set of project docu-
ments is also available for a nonre-
fundable price of $50 per set. Make
checks payable to
Ackerman-Estvold and send to 1907
17th Street SE Minot, ND, 58701.
Potential bidders may contact
Ackerman-Estvold at (701)
837-8737 with any questions. In
general, the Work included in the
Project includes the labor, materials,
tools and equipment required to re-
move a residential home from its
foundation, demolish existing foun-
dation, bring fill material to raise lot,
construct a residential foundation,
install residential services, move a
residential house back onto the
foundation, and other items as fully
depicted in the Drawings and Techn-
ical Specifications. All Bids are to be
submitted on the basis of cash pay-
ment for the Work and are to be en-
closed in a sealed envelope ad-
dressed tot the undersigned Chair-
man, accompanied by a separate
envelope containing the contractor’s
license and bid security. The bid
security must be in a sum equal to
five percent (5%) of the full amount
of the Bid and must in the form of a
bidder’s bond. A bidder’s bond must
be executed by the bidder as princi-
pal and by a surety, conditioned that
if the principal’s bid is accepted and
the contract awarded to the princi-
pal, the principal, within ten days
after notice of the award, shall exe-
cute a contract in accordance with
the terms of the Bid and the bid
bond and any condition of the
governing body and the project
awarded to the next lowest responsi-
ble bidder. The bidder must be
licensed for the full amount of the bis
as required by Section 43-07-12 of
the North Dakota Century Code.
The outside of the sealed envelope
containing the bid and other required
items shall be endorsed with the fol-
lowing verbiage:
1.“Bid Enclosed”
2.”Souris River Joint Water
Resources Board, MREFPP –
Phase BU-1E “Brunelle Home
Raise”
3.The name of the person, firm, cor-
poration, or joint venture submitting
the Bid.
4.Acknowledgement of Addenda.
No bid may be read or considered if
it does not fully comply with the re-
quirements of Section 48-01.2-05 of
the North Dakota Century Code. Any
deficient Bid received will be
resealed and returned to the Bidder
immediately. The Owner reserves
the right to hold all bids for 30 days,
to reject any or all Bids and to waive
any informality or irregularity in any
Bid and to accept the Bid deemed in
the best interest of the Owner. The
Owner reserves the right to rebid the
project until a satisfactory Bid is re-
ceived. The work shall be substan-
tially complete by August 31st, 2022.
All work shall be complete and ready
for final payment in accordance with
the General Conditions by Sep-
tember 30, 2022. Should the Con-
tractor fail to complete its obligations
under the Contract within the time
required herein or within such extra
time as may have been granted by
formal extensions of time approved
by the Owner, there will be deducted
from any amount due to the Con-
tractor the sum of $1,500.00 per day
for each and every calendar day that
the Work is delayed. The Contractor
and his Surety will be liable for any
excess. Such payment will be as
and for liquidated damages and not
as a penalty.
By order of the Souris River Joint
Water Resources Board,
Dated this 7th Day of April 2022
Souris River Joint Water Resources
Board
David Ashley, Chairman
(April 11-18-25, 2022)
NOTICE TO CREDITORS
Probate No. 51-2022-PR-00065
IN THE DISTRICT COURT OF
WARD COUNTY, STATE OF
NORTH DAKOTA
In the Matter of the Estate of
Susan H. Stewart, Deceased.
NOTICE IS HEREBY GIVEN that
the undersigned has been appointed
personal representative of the above
estate. All persons having claims
against the said deceased are re-
quired to present their claims within
three months after the date of the
first publication of this notice or said
claims will be forever barred. Claims
must either be presented to John D.
Stewart, personal representative of
the estate, at P.O. Box 998, Minot,
ND 58702-0998, or filed with the
Court.
Dated this 7th day of April, 2022.
John D. Stewart
Personal Representative
(April 11, 18, 25, 2022)
NOTICE TO CREDITORS
Probate No. 51-2022-PR-00069
IN THE DISTRICT COURT OF
WARD COUNTY, STATE OF
NORTH DAKOTA
In the Matter of the Estate of Shirley
J. Newbury, Deceased.
NOTICE IS HEREBY GIVEN that
the undersigned have been appoint-
ed Personal Representatives of the
above estate. All persons having
claims against the said deceased
are required to present their claims
within three (3) months after the date
of the first publication of this Notice
or said claims will be forever barred.
Claims must either be presented to
Tammy Moffitt or Todd Newbury,
Co-Personal Representatives of the
above-named estate, in care of Max-
son Law Office, P.C., at 320 – 16th
Street NW, Minot, ND 58703, or
filed with the Court.
Dated this 18th day of April, 2022.
/s/ Tammy Moffitt
Tammy Moffitt, Co-Personal
Representative
/s/ Todd Newbury
Todd Newbury, Co-Personal
Representative
Jacob C. Maxson (ID #06747)
MAXSON LAW OFFICE, P.C.
320 – 16th Street NW
Minot, ND 58703
Attorneys for Personal
Representatives
(April 25, May 2, 9, 2022)
STATE OF NORTH DAKOTA
COUNTY OF WARD
IN DISTRICT COURT
NORTH CENTRAL
JUDICIAL DISTRICT
State of North Dakota, by and
through the Office of State Tax
Commissioner,
Plaintiff,
vs.
Travis S. Fisher,
Defendant.
Civil No. 51-2022-CV-00474
SUMMONS
THE STATE OF NORTH DAKOTA
TO THE ABOVE NAMED
DEFENDANT:
YOU ARE HEREBY SUMMONED
and required to appear and defend
against the Complaint in this action,
which is herewith served upon you
and has been filed with the Clerk of
the District Court in the county in
which this action is commenced, by
serving upon the undersigned with
an Answer or other proper response
within twenty-one (21) days after the
service of this Summons upon you,
exclusive of the day of service. If
you fail to do so, judgment by default
will be taken against you for the re-
lief demanded in the Complaint.
Dated this 11th day of April, 2022, at
Bismarck, North Dakota.
/s/ Charles Dendy
Charles Dendy
(State Bar Board Id. 05877)
Special Assistant Attorney General
Office of State Tax Commissioner
600 East Boulevard Avenue
Bismarck, North Dakota 58505-0599
(701)328-2776
Fax (701) 328-3700
Email cdendy@nd.gov
Attorney for Plaintiff
(April 18, 25, May 2, 2022)
SUMMONS
Civil No. 51-2022-CV-00519
STATE OF NORTH DAKOTA IN
DISTRICT COURT
COUNTY OF WARD NORTH
CENTRAL JUDICIAL DISTRICT
ProCollect Services, LLC,
Plaintiff,
vs.
Twyann C. Johnson,
Defendant.
THE STATE OF NORTH DAKOTA
TO THE ABOVE-NAMED DEFEN-
DANT:
YOU ARE HEREBY SUMMONED
and required to appear and defend
against the Complaint in this action,
which is herewith served upon you,
by serving on the undersigned an
Answer or other proper response
within twenty-one days after service
of this Summons upon you, ex-
clusive of the day of service. If you
fail to do so, judgment by default will
be taken against you for the relief
demanded in the complaint.
Dated April 21, 2022.
/s/ Christopher A. Carlson
Christopher A. Carlson (id #03378)
PO Box 1097
Bismarck ND 58502-1097
701-258-4800
carlsonlaw@qwestoffice.net
Attorney for the Plaintiff
(April 25, May 2, 9, 2022)
SUMMONS
Civil No. 51-2022-CV-00524
STATE OF NORTH DAKOTA IN
DISTRICT COURT
COUNTY OF WARD NORTH
CENTRAL JUDICIAL DISTRICT
ProCollect Services, LLC,
Plaintiff,
vs.
Preston C. Flemming,
Defendant.
THE STATE OF NORTH DAKOTA
TO THE ABOVE-NAMED DEFEN-
DANT:
YOU ARE HEREBY SUMMONED
and required to appear and defend
against the Complaint in this action,
which is herewith served upon you,
by serving on the undersigned an
Answer or other proper response
within twenty-one days after service
of this Summons upon you, ex-
clusive of the day of service. If you
fail to do so, judgment by default will
be taken against you for the relief
demanded in the complaint.
Dated April 21, 2022.
/s/ Christopher A. Carlson
Christopher A. Carlson (id #03378)
PO Box 1097
Bismarck ND 58502-1097
701-258-4800
carlsonlaw@qwestoffice.net
Attorney for the Plaintiff
(April 25, May 2, 9, 2022)
SUMMONS
Civil No. 51-2022-CV-00520
STATE OF NORTH DAKOTA IN
DISTRICT COURT
COUNTY OF WARD NORTH
CENTRAL JUDICIAL DISTRICT
ProCollect Services, LLC,
Plaintiff,
vs.
Stacey M. Farrell,
Defendant.
THE STATE OF NORTH DAKOTA
TO THE ABOVE-NAMED DEFEN-
DANT:
YOU ARE HEREBY SUMMONED
and required to appear and defend
against the Complaint in this action,
which is herewith served upon you,
by serving on the undersigned an
Answer or other proper response
within twenty-one days after service
of this Summons upon you, ex-
clusive of the day of service. If you
fail to do so, judgment by default will
be taken against you for the relief
demanded in the complaint.
Dated April 21, 2022.
/s/ Christopher A. Carlson
Christopher A. Carlson (id #03378)
PO Box 1097
Bismarck ND 58502-1097
701-258-4800
carlsonlaw@qwestoffice.net
Attorney for the Plaintiff
(April 25, May 2, 9, 2022)