ADVERTISEMENT FOR BIDS

Minot Park District

Leopard Exhibit

420 3rd Ave SW

Minot, ND 58701

Separate Prime Sealed Bids for

General, Mechanical, and Electrical

Construction OR One Sealed Bid for

Single Prime Construction for Minot

Park District, Leopard Exhibit will be

accepted until: 2:00 PM Central

time on September 7, 2021 at:

Minot Park District

Minot Municipal Auditorium

420 3rd Ave SW

Minot, North Dakota 58701

at which time and place the bids will

be opened and read aloud. Propo-

sals received after that time will not

be accepted. Bid Proposals shall be

addressed to:

Ron Merritt,

Executive Director of Parks

Minot Park District

Minot Municipal Auditorium

420 3rd Ave SW

Minot, ND 58701

Separate Bid Proposals will be re-

ceived to include construction for the

following Bid Packages:

Separate Prime General

Construction Bid: All labor, ma-

terials and equipment associated

with the work identified as Civil and

General Construction on the Con-

struction Documents.

Separate Prime Mechanical

Construction Bid: All labor, materi-

als and equipment associated with

the work identified as Mechanical

Construction on the Construction

Documents.

Separate Prime Electrical

Construction Bid: All labor, ma-

terials and equipment associated

with the work identified as Electrical

Construction on the Construction

Documents.

Single Prime Construction Bid:

All Portions of Work – General, Civil,

Mechanical, and Electrical Construc-

tion.

The Construction Documents will be

on file and may be examined at the

Office of Ackerman-Estvold, Minot,

North Dakota and the following

Builders Exchanges: Bismarck –

Mandan, Construction Plans Ex-

change, Dickinson, Fargo, Grand

Forks, Minot, Williston, North Dako-

ta; St. Paul, and Minneapolis, Min-

nesota; Construction Industry

Center, and Sioux Falls Builders Ex-

change, South Dakota. Bidders may

obtain Plans and Specifications by

contacting Sonya Boykin at

Ackerman-Estvold by phone at

701-837-8737 or by email at

sonya.boykin@ackerman-estvold.

com and requesting a link to the pro-

ject documents. All prime contrac-

tors obtaining plans, whether

through exchanges or directly,

should direct Acker-man-Estvold to

place them on the plan holders list.

Plans and Specifications may also

be obtained by Bidders at Quest

CDN (www.questcdn.com): You

may download the digital plan docu-

ments for free by inputting Quest

project #7985091on the web-site’s

Project Search page. Please contact

QuestCDN.com at 952-233-1632 or

info@questcdn.com for assistance

in free membership registration,

downloading, and working with this

digital project information.Each Bid

must be accompanied by a separate

envelope, (attached to the Bid En-

velope) containing a Bid Bond equal

to five percent (5%) of the amount of

the Bid naming Minot Park Districtas

Obligee. The Contractor shall also

enclose within the Bid Bond En-

velope a copy of the Bidder’s North

Dakota Contractor’s License or a

copy of their latest Renewal Certifi-

cate issued by the Secretary of

State as per North Dakota Century

Code 43-07-12. All Contractors who

submit Bids must hold a North

Dakota Contractors License in the

highest amount of their Bids and

such license must have been in ef-

fect at least ten (10) days prior to the

date of the Bid Opening. Any Bid

not containing these documents

shall not be acceptable and shall be

returned to the Bidder unopened.

See AIA Document A701-1997

“Instructions to Bidders” in the Pro-

ject Manual for further information.

The Owner reserves the right to re-

ject any or all bids and to waive any

informalities in bidding. The suc-

cessful bidder will be required to fur-

nish a Payment Bond, Performance

Bond, Insurance Coverages and

other requirements stipulated in the

Project Manual. No Bidder may with-

draw his Bid within 30 days of the

actual date of the opening.

Ron Merritt

Executive Director of Parks

(August 17-24-31, 2021)

CORE FACILITY SOLUTIONS

Minot, NORTH DAKOTA

REQUEST FOR BIDS

for First District Health Unit –

Emergency Building Repairs

Core Facility Solutions of Minot, ND

requests bids to evaluate qualified

contractors for emergency repairs

at the First District Health Unit facili-

ties in Minot, North Dakota. This Re-

quest for Bids will encompass the

replacement of temperature con-

trols, boilers, furnaces, and

sealing/repair of the tunnel/crawl

space. Proposals shall be electroni-

cally received in the office of Mr.

Kristopher Schwab no later than

2:00 p.m. Friday, September 3,

2021. To receive the full details and

specifications of this request for

bids, contact Mr. Kristopher Schwab;

via e-mail at

kschwab@corefacilitysolutions.com.

(August 19-20-21-23-24-25-26-27-

28-30-31; September 1-2, 2021)

INVITATION NO: IFB 21-23

GENERAL CONSTRUCTION

IFB 21-24 ELECTRICAL

CONSTRUCTION

IFB 21-25 TOTAL COMBINED

CONSTRUCTION

INVITATION TO BID

ACCESS CONTROL

IMPROVEMENTS

Fargo AFRC / FMS Complex

Fargo, North Dakota

Sealed bids for Access Control Im-

provements, Fargo AFRC / FMS

Complex, Fargo, North Dakota will

be received by the Adjutant General

of the State of North Dakota at

Fraine Barracks, Building 30,

Bismarck, North Dakota, until 2:00

PM, September 16, 2021, and will

be publicly read that date and hour

in the location designated. All bids

received after the scheduled open-

ing time will be returned to the

bidders unopened. The deadline for

receipt of technical questions is no

later than September 9, 2021.

Electronic bidding documents may

be requested. Emails must be ac-

companied by a copy of your current

North Dakota Contractor’s License

or Certificate of Renewal and your

request must be written on business

letterhead. No requests will be ack-

nowledged without receipt of both

documents. Requests for bidding

documents must be submitted to:

ng.nd.ndarng.list.dfe-contract-mana

gement@mail.mil.

Due to COVID 19, the bid opening

will not be open to the public. The

front gate entrance to Fraine Bar-

racks is closed to the general public.

A representative from the Facilities

Engineering Division will be at the

gate from 12:00 Noon until 1:30 p.m.

CST on September 16, 2021.

Bidders may hand deliver their bids

during that time ONLY. Delivery by

courier service or U.S. Mail are the

preferred methods for delivery.

Modifications to bids are allowed in

accordance with the instructions in

AGND Document 411, Subpara-

graph 4.4.2. All bid modifications

must be received by the Contract

Management Office no later than

2:00 p.m. CST. Be advised, the re-

ceipt of emails and faxed transmis-

sions have a delay time due to data

security restrictions and military

firewalls. Allow adequate time for

emailed and faxed transmissions to

travel through our security system.

The OWNER is not responsible for

bid modifications received by the

Contract Management Office later

than 2:00 p.m. CST on the day of

the bid opening. Modifications to

bids must be emailed to:

ng.nd.ndarng.list.dfe-contract-mana

gement@mail.mil.

To listen to the bid opening, you

may dial in:

701-333-2840

ID No. 32068#

Pin No. 32068#

Bidders may submit separate bids

for General Construction work (IFB

21-23), and/or Electrical Construc-

tion work (IFB 21-24). In addition,

the Office of the Adjutant General

will allow the submission of a Total

Combined Construction Bid (single

prime) for the complete project (IFB

21-25). In compliance with NDCC

48-01.2-06, the combined bid (from

a single prime) will not be accepted

unless that bid is lower than the

combined total of the lowest respon-

sible, multiple bids for the project.

OWNER

Office of the Adjutant General

Contract Management Branch

P.O. Box 5511

Bismarck, North Dakota 58506-5511

Telephone: (701) 333-2068

Copies of the bidding documents are

on file at the Construction Plans Ex-

change in Bismarck; Builders Ex-

changes in Dickinson, Fargo, Grand

Forks, Mandan, Minot, Rapid City,

Impact Procurement Technical As-

sistance Center in Fargo, North

Dakota and Minnesota Builders Ex-

change in Minneapolis, Minnesota.

Each bid shall be submitted in dupli-

cate using the bid response forms

provided by the Owner, enclosed in

a sealed opaque envelope and la-

beled with the necessary information

as required by the Supplementary

Instructions to Bidders.

Each bid shall be accompanied by a

separate sealed opaque envelope

containing a bidder’s bond made

payable to The Adjutant General,

State of North Dakota, and executed

by the bidder as principle and by a

surety company authorized to con-

duct business in North Dakota, in a

sum equal to five percent (5%) of

the bidder’s highest total bid combi-

nation, including all add alternates to

the bid items; conditioned that if the

bid is accepted and the contract

awarded, the bidder within ten (10)

days after notice of such award, will

effect and execute a contract in ac-

cordance with the terms of his bid

and provide payment and perfor-

mance bonds as required by law

and the regulations and determina-

tions of the Owner. AIA Document

A310, Bid Bond, is provided in the

electronic project manual and should

be used to execute the bid guaran-

tee.

In compliance with Section 43-07-12

of the North Dakota Century Code,

each contractor submitting a bid

must have a copy of their North

Dakota Contractor’s License or certi-

ficate of renewal issued by the

Secretary of State enclosed in the

bid bond envelope; must be licensed

for the highest amount of their total

bid combination including add alter-

nates; and such license must have

been in effect at least ten (10) days

prior to the date of the bid opening.

No bid will be read or considered

which does not fully comply with the

provisions herein as to bid bond and

contractor license, and any deficient

bid submitted will be resealed and

returned to the bidder immediately.

The Owner reserves the right to hold

all legitimate bids for a period of thir-

ty (30) days following the date fixed

for the bid opening. It is the intent of

the Owner to award a contract to the

lowest and best bidder. The Owner

further reserves the right to reject

any and all bids and to waive irregu-

larities, and shall incur no legal liabil-

ity for the State for the payment of

any monies until the contract is

awarded and approved by the prop-

er authorities.

In compliance with Section

48-01.2-10 of the North Dakota Cen-

tury Code, the successful bidder

shall be required to furnish payment

and performance bonds covering the

faithful performance of the contract

award and the payment of all obliga-

tions thereunder, and all additional

obligations required by the laws of

the State of North Dakota. Each

bond shall be in an amount equal to

the full contract award amount.

DATED: 23 August 2021

OFFICE OF THE ADJUTANT

GENERAL

Bismarck, North Dakota

By: /s/ JACKIE A. HUBER

Brigadier General, NDNG

Deputy Adjutant General

Contracting Officer

(August 24-31; September 7, 2021)

INVITATION NO: IFB 21-22 TOTAL

CONSTRUCTION

INVITATION TO BID

INTERIOR LIGHTING

REPLACEMENT

Grand Forks Readiness Center,

Bldg. 1501

Grand Forks, North Dakota

Sealed bids for Interior Lighting Re-

placement, Grand Forks Readiness

Center, Bldg. 1501, Grand Forks,

North Dakota will be received by the

Adjutant General of the State of

North Dakota at Fraine Barracks,

Building 30, Bismarck, North Dako-

ta, until 2:00 PM, September 14,

2021, and will be publicly read that

date and hour in the location desig-

nated. All bids received after the

scheduled opening time will be re-

turned to the bidders unopened. The

deadline for receipt of technical

questions is no later than September

7, 2021.

Electronic bidding documents may

be requested. Emails must be ac-

companied by a copy of your current

North Dakota Contractor’s License

or Certificate of Renewal and your

request must be written on business

letterhead. No requests will be ack-

nowledged without receipt of both

documents. Requests for bidding

documents must be submitted to:

ng.nd.ndarng.list.dfe-contract-mana

gement@mail.mil.

Due to COVID 19, the bid opening

will not be open to the public. The

front gate entrance to Fraine Bar-

racks is closed to the general public.

A representative from the Facilities

Engineering Division will be at the

gate from 12:00 Noon until 1:30 p.m.

CST on September 14, 2021.

Bidders may hand deliver their bids

during that time ONLY. Delivery by

courier service or U.S. Mail are the

preferred methods for delivery.

Modifications to bids are allowed in

accordance with the instructions in

AGND Document 411, Subpara-

graph 4.4.2. All bid modifications

must be received by the Contract

Management Office no later than

2:00 p.m. CST. Be advised, the re-

ceipt of emails and faxed transmis-

sions have a delay time due to data

security restrictions and military

firewalls. Allow adequate time for

emailed and faxed transmissions to

travel through our security system.

The OWNER is not responsible for

bid modifications received by the

Contract Management Office later

than 2:00 p.m. CST on the day of

the bid opening. Modifications to

bids must be emailed to:

ng.nd.ndarng.list.dfe-contract-mana

gement@mail.mil.

To listen to the bid opening, you

may dial in:

701-333-2840

ID No. 32068#

Pin No. 32068#

A single bid will be received for Total

Construction work (IFB 21-22).

OWNER

Office of the Adjutant General

Contract Management Branch

P.O. Box 5511

Bismarck, North Dakota 58506-5511

Telephone: (701) 333-2068

Copies of the bidding documents are

on file at the Construction Plans Ex-

change in Bismarck; Builders Ex-

changes in Dickinson, Fargo, Grand

Forks, Mandan, Minot, Rapid City,

Impact Procurement Technical As-

sistance Center in Fargo, North

Dakota and Minnesota Builders Ex-

change in Minneapolis, Minnesota.

Each bid shall be submitted in dupli-

cate using the bid response forms

provided by the Owner, enclosed in

a sealed opaque envelope and la-

beled with the necessary information

as required by the Supplementary

Instructions to Bidders.

Each bid shall be accompanied by a

separate sealed opaque envelope

containing a bidder’s bond made

payable to The Adjutant General,

State of North Dakota, and executed

by the bidder as principle and by a

surety company authorized to con-

duct business in North Dakota, in a

sum equal to five percent (5%) of

the bidder’s highest total bid combi-

nation, including all add alternates to

the bid items; conditioned that if the

bid is accepted and the contract

awarded, the bidder within ten (10)

days after notice of such award, will

effect and execute a contract in ac-

cordance with the terms of his bid

and provide payment and perfor-

mance bonds as required by law

and the regulations and determina-

tions of the Owner. AIA Document

A310, Bid Bond, is provided in the

electronic project manual and should

be used to execute the bid guaran-

tee.

In compliance with Section 43-07-12

of the North Dakota Century Code,

each contractor submitting a bid

must have a copy of their North

Dakota Contractor’s License or certi-

ficate of renewal issued by the

Secretary of State enclosed in the

bid bond envelope; must be licensed

for the highest amount of their total

bid combination including add alter-

nates; and such license must have

been in effect at least ten (10) days

prior to the date of the bid opening.

No bid will be read or considered

which does not fully comply with the

provisions herein as to bid bond and

contractor license, and any deficient

bid submitted will be resealed and

returned to the bidder immediately.

The Owner reserves the right to hold

all legitimate bids for a period of thir-

ty (30) days following the date fixed

for the bid opening. It is the intent of

the Owner to award a contract to the

lowest and best bidder. The Owner

further reserves the right to reject

any and all bids and to waive irregu-

larities, and shall incur no legal liabil-

ity for the State for the payment of

any monies until the contract is

awarded and approved by the prop-

er authorities.

In compliance with Section

48-01.2-10 of the North Dakota Cen-

tury Code, the successful bidder

shall be required to furnish payment

and performance bonds covering the

faithful performance of the contract

award and the payment of all obliga-

tions thereunder, and all additional

obligations required by the laws of

the State of North Dakota. Each

bond shall be in an amount equal to

the full contract award amount.

DATED: 23 August 2021

OFFICE OF THE ADJUTANT

GENERAL

Bismarck, North Dakota

By: /s/ JACKIE A. HUBER

Brigadier General, NDNG

Deputy Adjutant General

Contracting Officer

(August 24-31; September 7, 2021)

INVITATION NO: IFB 21-26 TOTAL

CONSTRUCTION

INVITATION TO BID

CONDENSING UNIT

REPLACEMENT

Barracks Complex

Camp Gilbert C. Grafton

Devils Lake, North Dakota

Sealed bids for Condensing Unit Re-

placement, Barracks Complex,

Camp Gilbert C. Grafton, Devils

Lake, North Dakota will be received

by the Adjutant General of the State

of North Dakota at Fraine Barracks,

Building 30, Bismarck, North Dako-

ta, until 2:30 PM, September 16,

2021, and will be publicly read that

date and hour in the location desig-

nated. All bids received after the

scheduled opening time will be re-

turned to the bidders unopened. The

deadline for receipt of technical

questions is no later than September

9, 2021.

Electronic bidding documents may

be requested. Emails must be ac-

companied by a copy of your current

North Dakota Contractor’s License

or Certificate of Renewal and your

request must be written on business

letterhead. No requests will be ack-

nowledged without receipt of both

documents. Requests for bidding

documents must be submitted to:

ng.nd.ndarng.list.dfe-contract-mana

gement@mail.mil.

Due to COVID 19, the bid opening

will not be open to the public. The

front gate entrance to Fraine Bar-

racks is closed to the general public.

A representative from the Facilities

Engineering Division will be at the

gate from 12:00 Noon until 1:30 p.m.

CST on September 16, 2021.

Bidders may hand deliver their bids

during that time ONLY. Delivery by

courier service or U.S. Mail are the

preferred methods for delivery.

Modifications to bids are allowed in

accordance with the instructions in

AGND Document 411, Subpara-

graph 4.4.2. All bid modifications

must be received by the Contract

Management Office no later than

2:30 p.m. CST. Be advised, the re-

ceipt of emails and faxed transmis-

sions have a delay time due to data

security restrictions and military

firewalls. Allow adequate time for

emailed and faxed transmissions to

travel through our security system.

The OWNER is not responsible for

bid modifications received by the

Contract Management Office later

than 2:30 p.m. CST on the day of

the bid opening. Modifications to

bids must be emailed to:

ng.nd.ndarng.list.dfe-contract-mana

gement@mail.mil.

To listen to the bid opening, you

may dial in:

701-333-2840

ID No. 32068#

Pin No. 32068#

A single bid will be received for Total

Construction work (IFB 21-26).

OWNER

Office of the Adjutant General

Contract Management Branch

P.O. Box 5511

Bismarck, North Dakota 58506-5511

Telephone: (701) 333-2068

Copies of the bidding documents are

on file at the Construction Plans Ex-

change in Bismarck; Builders Ex-

changes in Dickinson, Fargo, Grand

Forks, Mandan, Minot, Rapid City,

Impact Procurement Technical As-

sistance Center in Fargo, North

Dakota and Minnesota Builders Ex-

change in Minneapolis, Minnesota.

Each bid shall be submitted in dupli-

cate using the bid response forms

provided by the Owner, enclosed in

a sealed opaque envelope and la-

beled with the necessary information

as required by the Supplementary

Instructions to Bidders.

Each bid shall be accompanied by a

separate sealed opaque envelope

containing a bidder’s bond made

payable to The Adjutant General,

State of North Dakota, and executed

by the bidder as principle and by a

surety company authorized to con-

duct business in North Dakota, in a

sum equal to five percent (5%) of

the bidder’s highest total bid combi-

nation, including all add alternates to

the bid items; conditioned that if the

bid is accepted and the contract

awarded, the bidder within ten (10)

days after notice of such award, will

effect and execute a contract in ac-

cordance with the terms of his bid

and provide payment and perfor-

mance bonds as required by law

and the regulations and determina-

tions of the Owner. AIA Document

A310, Bid Bond, is provided in the

electronic project manual and should

be used to execute the bid guaran-

tee.

In compliance with Section 43-07-12

of the North Dakota Century Code,

each contractor submitting a bid

must have a copy of their North

Dakota Contractor’s License or certi-

ficate of renewal issued by the

Secretary of State enclosed in the

bid bond envelope; must be licensed

for the highest amount of their total

bid combination including add alter-

nates; and such license must have

been in effect at least ten (10) days

prior to the date of the bid opening.

No bid will be read or considered

which does not fully comply with the

provisions herein as to bid bond and

contractor license, and any deficient

bid submitted will be resealed and

returned to the bidder immediately.

The Owner reserves the right to hold

all legitimate bids for a period of thir-

ty (30) days following the date fixed

for the bid opening. It is the intent of

the Owner to award a contract to the

lowest and best bidder. The Owner

further reserves the right to reject

any and all bids and to waive irregu-

larities, and shall incur no legal liabil-

ity for the State for the payment of

any monies until the contract is

awarded and approved by the prop-

er authorities.

In compliance with Section

48-01.2-10 of the North Dakota Cen-

tury Code, the successful bidder

shall be required to furnish payment

and performance bonds covering the

faithful performance of the contract

award and the payment of all obliga-

tions thereunder, and all additional

obligations required by the laws of

the State of North Dakota. Each

bond shall be in an amount equal to

the full contract award amount.

DATED: 23 August 2021

OFFICE OF THE ADJUTANT

GENERAL

Bismarck, North Dakota

By: /s/ JACKIE A. HUBER

Brigadier General, NDNG

Deputy Adjutant General

Contracting Officer

(August 24-31; September 7, 2021)

MINOT PARK DISTRICT

REQUEST FOR PROPOSAL

Bid – 72″ Mower

Notice is hereby given that sealed

bids will be received by Jarrod A. Ol-

son, Director of Operations, at the

Minot Park District Office, 420 3rd

Ave SW, PO Box 538, Minot, ND

58702, until 2pm September 16th,

2021at which times proposals will be

opened and then presented to the

Board of Park Commissioners on

September 21st at 6:30pm. En-

velope containing the proposal shall

be plainly marked on the outside –

“Bid -72″ Mower”

Copies of Specifications may be ob-

tained from the Park District Office

at above address or at

www.minotparks.com The Board of

Park Commissioners reserves the

right to reject any and all Bids, waive

any irregularities therein, and to

award the contract as they deem to

be the best interest of the Minot

Park District. Bidders are invited to

be present at the above -mentioned

time and place for the opening of the

bids. Proposals will be presented to

the Minot Park Board on September

21st at 6:30pm.

Technical Questions Contact

Shawn Schafer

Senior Equipment Mechanic

mechanic@minotparks.com

(701) 822-3281

Bid Questions

Jarrod A. Olson

Director of Operations

Minot Park District

jarrod@minotparks.com

(701) 857-4136 Office

(701) 833-7021 Cell

(August 31; September 7-14, 2021)

MINOT PARK DISTRICT

REQUEST FOR PROPOSAL

Bid – Garden Tractor &

Accessories

Notice is hereby given that sealed

bids will be received by Jarrod A. Ol-

son, Director of Operations, at the

Minot Park District Office, 420 3rd

Ave SW, PO Box 538, Minot, ND

58702, until 2pm September 16th,

2021at which times proposals will be

opened and then presented to the

Board of Park Commissioners on

September 21st at 6:30pm. En-

velope containing the proposal shall

be plainly marked on the outside –

“Bid – Garden Tractor &

Accessories”

Copies of Specifications may be ob-

tained from the Park District Office

at above address or at

www.minotparks.com The Board of

Park Commissioners reserves the

right to reject any and all Bids, waive

any irregularities therein, and to

award the contract as they deem to

be the best interest of the Minot

Park District. Bidders are invited to

be present at the above -mentioned

time and place for the opening of the

bids. Proposals will be presented to

the Minot Park Board on September

21st at 6:30pm.

Technical Questions Contact:

Shawn Schafer

Senior Equipment Mechanic

mechanic@minotparks.com

(701) 822-3281

Bid Questions:

Jarrod A. Olson

Director of Operations

Minot Park District

jarrod@minotparks.com

(701) 857-4136 Office

(701) 833-7021 Cell

(August 31; September 7-14, 2021)

MINOT PARK DISTRICT

REQUEST FOR PROPOSAL

Bid – Utility Tractor

Notice is hereby given that sealed

bids will be received by Jarrod A. Ol-

son, Director of Operations, at the

Minot Park District Office, 420 3rd

Ave SW, PO Box 538, Minot, ND

58702, until 2pm September 16th,

2021at which times proposals will be

opened and then presented to the

Board of Park Commissioners on

September 21st at 6:30pm. En-

velope containing the proposal shall

be plainly marked on the outside –

“Bid -Utility Tractor”

Copies of Specifications may be ob-

tained from the Park District Office

at above address or at

www.minotparks.com The Board of

Park Commissioners reserves the

right to reject any and all Bids, waive

any irregularities therein, and to

award the contract as they deem to

be the best interest of the Minot

Park District. Bidders are invited to

be present at the above -mentioned

time and place for the opening of the

bids. Proposals will be presented to

the Minot Park Board on September

21stat 6:30pm.

Technical Questions Contact:

Mike Chrest – Souris Valley Golf

Course Superintendent

701-833-7035 Mike@minotparks.

com

Bid Questions:

Jarrod A. Olson

Director of Operations

Minot Park District

jarrod@minotparks.com

(701) 857-4136 Office

(701) 833-7021 Cell

(August 31; September 7-14, 2021)

MINOT PARK DISTRICT

REQUEST FOR PROPOSAL

Bid – Utility Cart Quote

Notice is hereby given that sealed

bids will be received by Jarrod A. Ol-

son, Director of Operations, at the

Minot Park District Office, 420 3rd

Ave SW, PO Box 538, Minot, ND

58702, until 2pm September 16th,

2021 at which times bids will be

opened and read for furnishing to

the Board of Park Commissioners

September 21st at 6:30pm. En-

velope containing Quote shall be

plainly marked on the outside.

“Quote – Utility Cart”

Copies of Specifications may be ob-

tained from the Park District Office

at above address or at

www.minotparks.com The Board of

Park Commissioners reserves the

right to reject any and all bids, waive

any irregularities therein, and to

award the contract as they deem to

be the best interest of the Minot

Park District. Bidders are invited to

be present at the above -mentioned

time and place for the opening of the

Quotes. Quotes will be presented to

the Minot Park Board on September

21st at 6:30pm at the Minot Park

Board February Meeting.

Technical Questions Contact

Tom Landsiedel- Recreation

Manager & Auditorium

701-857-4136 Tom@minotparks

.com

Quote Questions

Jarrod A. Olson

Director of Operations

Minot Park District

jarrod@minotparks.com

(701) 857-4136 Office

(August 31; September 7-14, 2021)

NOTICE

All land owners must have ditches

mowed to a minimum 4 inch stubble

height and a minimum 9 food mower

width between Sept. 15 – Oct 1st,

2021. Sundre Township will contract

mowing for ditches not completed by

October 1, 2021 and expenses will

be levied as taxes against land own-

er.

Cari Morey, Sundre Township Clerk

(August 28-30-31; September 1-2-3-

4, 2021)

NOTICE OF REAL ESTATE SALE

CIVIL NUMBER: 51-2019-CV-00586

IN THE STATE OF NORTH

DAKOTA, COUNTY OF WARD

IN THE DISTRICT COURT, NORTH

CENTRAL JUDICIAL DISTRICT

U.S. Bank National Association,

Plaintiff,

v.

Jeremy Jason Osborn; Kalena R.

Osborn; and all persons unknown,

claiming any estate or interest in, or

lien or encumbrance upon, the real

estate described in the complaint;

any person in possession,

Defendants,

Judgment in the amount of

$261,707.41, having been entered in

favor of Plaintiff and against Defen-

dants, which Judgment was filed

with the Clerk of Courts of Ward

County, North Dakota, on July 21,

2021, for the foreclosure of a real

estate mortgage. Notice is hereby

given pursuant to said Judgment

that the real property described as:

Lot 7, Foutz Subdivision of Lot 2

and W1/2 of Lots 3 and 4,

Moorland Addition and the East

30 feet of Lots 7, 8, 9 and 10,

Block 4, Home Acres Addition to

the City of Minot, Ward County,

North Dakota.

Real Property address: 1727 1st

Street Southeast, Minot, ND 58701

The above real property is the sub-

ject of the Mortgage dated February

13, 2015, which Mortgagors, Jeremy

Jason Osborn and Kalena R. Os-

born, executed and delivered to

Mortgage Electronic Registration

Systems, Inc. as nominee for

Cornerstone Bank, a Corporation, its

successors and assigns, and record-

ed in the office of the Clerk and

Recorder of Ward County, North

Dakota, on February 17, 2015, In-

strument Number 2982936, which is

subject to the entered Judgment.

Said Mortgage was assigned to

Plaintiff, its successors or assigns,

by Assignment of Mortgage record-

ed April 23, 2018, Instrument

Number 3017860. In order to realize

the amount of $261,707.41, as of

July 21, 2021, plus interest accruing

thereafter on said amount at the rate

of 3.375% per year together with the

costs and expenses of sale, the pro-

perty will be sold subject to redemp-

tion as provided by law as one par-

cel of land at public auction, subject

to any lien for unpaid real estate

taxes and assessments of Ward

County, North Dakota, and ease-

ments and restrictions of record, to

the highest bidder for cash under the

direction of the Sheriff of Ward

County, North Dakota, at the main

entrance of the Ward County Court-

house located at 315 SE 3rd Street,

Minot, North Dakota 58701, on Oc-

tober 20, 2021 (“Sale Date”), at

10:00 AM. If the sale is set aside for

reason, the Purchaser at the sale

shall be entitled only to a return of

the deposit paid. The purchaser

shall have no further recourse

against the Mortgagor, the Mort-

gagee or the Mortgagee’s attorney.

DATED this 26th day of August,

2021.

SHERIFF OF WARD COUNTY

For: Robert Roed

By: Jamie Williams

Sheriff/Deputy Sheriff of Ward

Halliday, Watkins & Mann, P.C.

/s/ Scott S. Skeen

Attorneys for Plaintiff

376 East 400 South, Suite 300

Salt Lake City, UT 84111

801-355-2886

Email: scott@hwmlawfirm.com

ND Bar No.: 09334

(August 31; September 7-14, 2021)

NOTICE OF REAL ESTATE SALE

CIVIL NUMBER: 51-2021-CV-00431

IN THE STATE OF NORTH

DAKOTA, COUNTY OF WARD

IN THE DISTRICT COURT, NORTH

CENTRAL JUDICIAL DISTRICT

Wells Fargo Bank, N.A.,

Plaintiff,

v.

Lisa M. Kersten; ProCollect Ser-

vices, L.L.C.; any person in posses-

sion,

Defendants,

Judgment in the amount of

$190,745.10, having been entered in

favor of Plaintiff and against Defen-

dants, which Judgment was filed

with the Clerk of Courts of Ward

County, North Dakota, on June 22,

2021, for the foreclosure of a real

estate mortgage. Notice is hereby

given pursuant to said Judgment

that the real property described as:

Lot 19, Block 3, less Sublot A

thereof, South Park Terrace Fifth

Addition to the City of Minot,

Ward County, North Dakota

Real Property address: 1724 5th

Street Southeast, Minot, ND 58701

The above real property is the sub-

ject of the Mortgage dated March

25, 2013, which Mortgagor, Lisa M.

Kersten, executed and delivered to

Wells Fargo Bank, N.A., and record-

ed in the office of the Clerk and

Recorder of Ward County, North

Dakota, on April 1, 2013, Instrument

Number 2955954, which is subject

to the entered Judgment. In order to

realize the amount of $190,745.10,

as of June 22, 2021, plus interest

accruing thereafter on said amount

at the rate of 4.0% per year together

with the costs and expenses of sale,

the property will be sold subject to

redemption as provided by law as

one parcel of land at public auction,

subject to any lien for unpaid real

estate taxes and assessments of

Ward County, North Dakota, and

easements and restrictions of

record, to the highest bidder for cash

under the direction of the Sheriff of

Ward County, North Dakota, at the

main entrance of the Ward County

Courthouse located at 315 SE 3rd

Street, Minot, North Dakota 58701,

on October 6, 2021 (“Sale Date”), at

10:00 AM. If the sale is set aside for

reason, the Purchaser at the sale

shall be entitled only to a return of

the deposit paid. The purchaser

shall have no further recourse

against the Mortgagor, the Mort-

gagee or the Mortgagee’s attorney.

DATED this 26th day of August,

2021.

SHERIFF OF WARD COUNTY

For: Robert Roed

By: Jamie Williams

Sheriff/Deputy Sheriff of Ward

Halliday, Watkins & Mann, P.C.

/s/ Scott S. Skeen

Attorneys for Plaintiff

376 East 400 South, Suite 300

Salt Lake City, UT 84111

801-355-2886

Email: scott@hwmlawfirm.com

ND Bar No.: 09334

(August 31; September 7-14, 2021)

NOTICE OF SALE

Civil No. 51-2021-CV-00385

STATE OF NORTH DAKOTA,

COUNTY OF WARD, IN DISTRICT

COURT, NORTH CENTRAL

JUDICIAL DISTRICT

Habitat for Humanity,

Plaintiff,

vs.

Howard Edwardson, Linda Edward-

son, and all persons unknown,

claiming any estate or interest in or

lien or encumbrance upon the real

estate described in the Complaint,

Defendants.

NOTICE IS HEREBY GIVEN that by

virtue of a Judgment and decree in

foreclosure, rendered by the District

Court of the North Central Judicial

District, in and for the County of

Ward, State of North Dakota, and

entered and docketed in the office of

the Clerk of the District Court, in and

for said County, on the 28th Day of

June, 2021, in an action wherein Ha-

bitat for Humanity was Plaintiff, and

Howard Edwardson, Linda Edward-

son, and all persons unknown,

claiming any estate or interest in or

lien or encumbrance upon the real

estate described in the Complaint

were Defendants, in favor of the

Plaintiff and against the Defendants

for the sum of $42,155.00, plus in-

terest, costs, and expenses of the

sale, which Judgment and decree,

among other things, directs the sale

of the real estate hereinafter

described, and by virtue of a writ is-

sued to me by the Clerk of said

Court, in and for Ward County, and

under the seal of said Court, direct-

ing me to sell said real property, pur-

suant to said Judgment and decree,

I, Robert Roed, Sheriff of Ward

County will sell the hereinafter

described real estate to the highest

bidder for cash, at public auction at

the front door of the courthouse in

the City of Minot, Ward County,

North Dakota, on the 15th day of

September, 2021, at 10:00 a.m. of

that day, to satisfy the said Judg-

ment with interest and costs

thereon, and the costs and ex-

penses of such sale, or so much

thereof as the proceeds of such sale

applicable thereto will satisfy. The

premises to be sold pursuant to said

Judgment and decree and to said

writ and to this notice, are described

in said Judgment, decree and writ as

follows:

HENDRECKSONS THIRD

ADDITION LOT 2 BLOCK 2

City of Minot, Ward County, North

Dakota.

Dated this 12th day of August, 2021.

For:Robert Roed,

Sheriff of Ward County

/s/Jamie Williams

Lt. Jamie Williams

OLSON & BURNS P.C.

P.O. Box 1180

Minot, ND 58702-1180

(701) 839-1740

(August 17-24-31, 2021)

NOTICE TO CREDITORS

Probate No. 51-2021-PR-00070

IN THE DISTRICT COURT OF

WARD COUNTY, STATE OF

NORTH DAKOTA

In the Matter of the Estate of

Alice Queirolo, Deceased.

NOTICE IS HEREBY GIVEN that

the undersigned has been appointed

personal representative of the above

estate. All persons having claims

against the said deceased are re-

quired to present their claims within

three months after the date of the

first publication or mailing of this no-

tice or said claims will be forever

barred. Claims must either be

presented to Abby Lyons, Personal

Representative of the estate, at

2525 Elk Drive, P.O. Box 1000,

Minot, ND 58702-1000, or filed with

the Court.

Dated this 5th day of April, 2021.

/s/Abby Lyons

Abby Lyons

Reed A. Soderstrom – #04759

PRINGLE & HERIGSTAD, P.C.

2525 Elk Drive

P.O. Box 1000

Minot, ND 58702-1000

rsoderstrom@pringlend.com

(August 17-24-31, 2021)

NOTICE TO CREDITORS

Probate No. 51-2021-PR-00143

IN THE DISTRICT COURT OF

WARD COUNTY, STATE OF

NORTH DAKOTA

In the Matter of the Estate of

Rick E. Demchuk, Deceased.

NOTICE IS HEREBY GIVEN that

the undersigned has been appointed

personal representative of the above

estate. All persons having claims

against the said deceased are re-

quired to present their claims within

three months after the date of the

first publication or mailing of this no-

tice or said claims will be forever

barred. Claims must either be

presented to Aimee D. Demchuk,

Personal Representative of the

estate, at 2525 Elk Drive, P.O. Box

1000, Minot, ND 58702-1000, or

filed with the Court.

Dated this 17th day of April, 2021.

/s/Aimee D. Demchuk

Aimee D. Demchuk

Ryan D. Sandberg – #05999

PRINGLE & HERIGSTAD, P.C.

2525 Elk Drive

P.O. Box 1000

Minot, ND 58702-1000

rsandberg@pringlend.com

Attorneys for Personal

Representative

(August 24-31; September 7, 2021)

NOTICE TO CREDITORS

Probate No. 51-2021-PR-00138

IN THE DISTRICT COURT OF

WARD COUNTY, STATE OF

NORTH DAKOTA

In the Matter of the Estate of

Jerald Lance Burtman, a/k/a Jerald

L. Burtman, Deceased.

NOTICE IS HEREBY GIVEN that

the undersigned have been appoint-

ed co-personal representatives of

the above estate. All persons having

claims against the said deceased

are required to present their claims

within three months after the date of

the first publication or mailing of this

notice or said claims will be forever

barred. Claims must either be

presented to Paul Burtman and

Mark Burtman, Co-Personal

Representatives of the estate, at

2525 Elk Drive, P.O. Box 1000,

Minot, ND 58702-1000, or filed with

the Court.

Dated this 24th day of August, 2021.

/s/Paul Burtman

Paul Burtman

/s/Mark Burtman

Mark Burtman

Brent M. Olson – #05593

PRINGLE & HERIGSTAD, P.C.

2525 Elk Drive

P.O. Box 1000

Minot, ND 58702-1000

bolson@pringlend.com

Attorneys for Co-Personal

Representatives

(August 31; September 7-14, 2021)