Legal Notices 7-27
ADVERTISEMENT FOR BIDS
CITY OF MINOT, NORTH DAKOTA
10 Street NW Storm Sewer
Rehabilitation
CITY PROJECT 4616
NOTICE IS HEREBY GIVEN that
the City of Minot (Owner) is re-
questing Bids for the construction of
the following Project: 10th Street
NW Storm Sewer Rehabilitation.
Bids for the construction of the Pro-
ject will be received at the office of
the City Clerk located at 515 Second
Avenue SW (Second Floor), Minot,
North Dakota 58701, until Thursday,
August 19, 2021 at 11:00 AM local
time. At that time the Bids received
will be publicly opened and read.
The Project includes the following
Work: 500 LF storm sewer replace-
ment, asphalt removal, asphalt pav-
ing, installing catch basins, installing
manholes, concrete sidewalk re-
placement, concrete driveway re-
placement, ADA ramps, concrete
curb & gutter, traffic control,
landscaping, and other related work.
Complete digital project bidding do-
cuments are available at
www.questcdn.com. You may down-
load the digital plan documents for
$40 by inputting eBidDoc #7958852
on the website’s Project Search
page. Please contact
QuestCDN.com at 952-233-1632 or
info@questcdn.com for assistance
in free membership registration,
downloading, and working with this
digital project information. Project
bidding documents are also avail-
able at the Issuing Office – City of
Minot Engineering Department 1025
31st St SE and are available for pur-
chase for $75. Potential bidders may
contact the Assistant City Engineer
at 701-857-4100 with any questions.
Each bid must be accompanied by a
separate envelope containing the
bid security in a sum equal to five
percent of the full amount of the bid
and must be in the form of a bidder’s
bond. A bidder’s bond must be exe-
cuted by the bidder as principal and
by a surety, conditioned that if the
principal’s bid is accepted and the
contract awarded to the principal,
the principal, within ten days after
notice of the award, shall execute a
contract in accordance with the
terms of the bid and the bid bond,
and any condition of the City of
Minot, as required by law. A counter-
signature of a bid bond is not re-
quired. If the City of Minot elects to
award a contract to the lowest
responsible bidder, and the lowest
responsible bidder does not execute
a contract within the ten days al-
lowed, the bidder’s bond must be
forfeited to the City of Minot and the
project awarded to the next lowest
responsible bidder.
Each bidder must possess a valid
North Dakota contractor’s license for
the full amount of their bid, as re-
quired by Section 43-07-07 of the
North Dakota Century Code. Each
bidder MUST enclose a copy of their
Contractor’s License or Certificate of
Renewal, issued by the North Dako-
ta Secretary of State, in their bid
bond envelope, and each license
must be valid and dated at least 10
days prior to the date set for bid
opening, as required under Section
43-07-12 of the North Dakota Centu-
ry Code.
No bid may be read or considered if
it does not fully comply with the re-
quirements of Section 48-01.2-05 of
the North Dakota Century Code, and
any deficient bid submitted will be
resealed and returned to the bidder
immediately.
All Bids submitted and all Work
completed must be as stipulated in
the Agreement.
The City of Minot reserves the right
to hold all Bids for a period of 30
days after the date of the bid open-
ing, to reject any or all Bids and to
rebid the project until a satisfactory
bid is received, and to waive any in-
formality or irregularity in any Bid.
For all further requirements regard-
ing bid submittal, qualifications, pro-
cedures, and contract award, refer to
the Instructions to Bidders that are
included in the Bidding Documents.
By order of the City Council of the
City of Minot, North Dakota.
Owner: City of Minot
By: Kelly Matalka
Title: City Clerk
Date: July 22, 2021
(July 27; August 3-10, 2021)
ADVERTISEMENT FOR BIDS
CITY OF MINOT, NORTH DAKOTA
10 Street NW Storm Sewer
Rehabilitation
CITY PROJECT 4616
NOTICE IS HEREBY GIVEN that
the City of Minot (Owner) is request-
ing Bids for the construction of the
following Project: 10th Street NW
Storm Sewer Rehabilitation.
Bids for the construction of the Pro-
ject will be received at the office of
the City Clerk located at 515 Second
Avenue SW (Second Floor), Minot,
North Dakota 58701, until Thursday,
August 19, 2021 at 11:00 AM local
time. At that time the Bids received
will be publicly opened and read.
The Project includes the following
Work: 500 LF storm sewer replace-
ment, asphalt removal, asphalt pav-
ing, installing catch basins, installing
manholes, concrete sidewalk re-
placement, concrete driveway re-
placement, ADA ramps, concrete
curb & gutter, traffic control,
landscaping, and other related work.
Complete digital project bidding do-
cuments are available at
www.questcdn.com. You may down-
load the digital plan documents for
$40 by inputting eBidDoc #7958852
on the website’s Project Search
page. Please contact
QuestCDN.com at 952-233-1632 or
info@questcdn.com for assistance
in free membership registration,
downloading, and working with this
digital project information. Project
bidding documents are also avail-
able at the Issuing Office – City of
Minot Engineering Department 1025
31st St SE and are available for pur-
chase for $75. Potential bidders may
contact the Assistant City Engineer
at 701-857-4100 with any questions.
Each bid must be accompanied by a
separate envelope containing the
bid security in a sum equal to five
percent of the full amount of the bid
and must be in the form of a bidder’s
bond. A bidder’s bond must be exe-
cuted by the bidder as principal and
by a surety, conditioned that if the
principal’s bid is accepted and the
contract awarded to the principal,
the principal, within ten days after
notice of the award, shall execute a
contract in accordance with the
terms of the bid and the bid bond,
and any condition of the City of
Minot, as required by law. A counter-
signature of a bid bond is not re-
quired. If the City of Minot elects to
award a contract to the lowest
responsible bidder, and the lowest
responsible bidder does not execute
a contract within the ten days al-
lowed, the bidder’s bond must be
forfeited to the City of Minot and the
project awarded to the next lowest
responsible bidder.
Each bidder must possess a valid
North Dakota contractor’s license for
the full amount of their bid, as re-
quired by Section 43-07-07 of the
North Dakota Century Code. Each
bidder MUST enclose a copy of their
Contractor’s License or Certificate of
Renewal, issued by the North Dako-
ta Secretary of State, in their bid
bond envelope, and each license
must be valid and dated at least 10
days prior to the date set for bid
opening, as required under Section
43-07-12 of the North Dakota Centu-
ry Code.
No bid may be read or considered if
it does not fully comply with the re-
quirements of Section 48-01.2-05 of
the North Dakota Century Code, and
any deficient bid submitted will be
resealed and returned to the bidder
immediately.
All Bids subMitted and all Work
completed must be as stipulated in
the Agreement.
The City of Minot reserves the right
to hold all Bids for a period of 30
days after the date of the bid open-
ing, to reject any or all Bids and to
rebid the project until a satisfactory
bid is received, and to waive any in-
formality or irregularity in any Bid.
For all further requirements regard-
ing bid submittal, qualifications, pro-
cedures, and contract award, refer to
the Instructions to Bidders that are
included in the Bidding Documents.
By order of the City Council of the
City of Minot, North Dakota.
Owner: City of Minot
By: Kelly Matalka
Title: City Clerk
Date: July 22, 202
(July 27; August 3-10, 2021)
INVITATION NO: IFB 21-12 TOTAL
CONSTRUCTION
INVITATION TO BID
MILITARY PARKING LOT
SURFACING
Aviation Readiness Center
Complex
Bismarck, North Dakota
Sealed bids for Military Parking Lot
Surfacing, Aviation Readiness
Center Complex, Bismarck, North
Dakota will be received by the Adju-
tant General of the State of North
Dakota at Fraine Barracks, Building
30, Bismarck, North Dakota, until
2:00 PM, August 5, 2021, and will be
publicly read that date and hour in
the location designated. All bids re-
ceived after the scheduled opening
time will be returned to the bidders
unopened. The deadline for receipt
of technical questions is no later
than July 29, 2021.
Electronic bidding documents may
be requested. Emails must be ac-
companied by a copy of your current
North Dakota Contractor’s License
or Certificate of Renewal and your
request must be written on business
letterhead. No requests will be ack-
nowledged without receipt of both
documents. Requests for bidding
documents must be submitted to:
ng.nd.ndarng.list.dfe-contract-
management@mail.mil.
Due to COVID 19, the bid opening
will not be open to the public. The
front gate entrance to Fraine Bar-
racks is closed to the general public.
A representative from the Facilities
Engineering Division will be at the
gate from 12:00 Noon until 1:30 p.m.
CST on August 5, 2021. Bidders
may hand deliver their bids during
that time ONLY. Delivery by courier
service or U.S. Mail are the pre-
ferred methods for delivery.
Modifications to bids are allowed in
accordance with the instructions in
AGND Document 411, Subpara-
graph 4.4.2. All bid modifications
must be received by the Contract
Management Office no later than
2:00 p.m. CST. Be advised, the re-
ceipt of emails and faxed transmis-
sions have a delay time due to data
security restrictions and military
firewalls. Allow adequate time for
emailed and faxed transmissions to
travel through our security system.
The OWNER is not responsible for
bid modifications received by the
Contract Management Office later
than 2:00 p.m. CST on the day of
the bid opening. Modifications to
bids must be emailed to:
ng.nd.ndarng.list.dfe-contract-
management@mail.mil.
To listen to the bid opening, you
may dial in:
701-333-2840
ID No. 32076#
Pin No. 32076#
A single bid will be received for Total
Construction work (IFB 21-12).
OWNER
Office of the Adjutant General
Contract Management Branch
P.O. Box 5511
Bismarck, North Dakota 58506-5511
Telephone: (701) 333-2068
Copies of the bidding documents are
on file at the Construction Plans Ex-
change in Bismarck; Builders Ex-
changes in Dickinson, Fargo, Grand
Forks, Mandan, Minot, Rapid City,
Impact Procurement Technical As-
sistance Center in Fargo, North
Dakota and Minnesota Builders Ex-
change in Minneapolis, Minnesota.
Each bid shall be submitted in dupli-
cate using the bid response forms
provided by the Owner, enclosed in
a sealed opaque envelope and la-
beled with the necessary information
as required by the Supplementary
Instructions to Bidders.
Each bid shall be accompanied by a
separate sealed opaque envelope
containing a bidder’s bond made
payable to The Adjutant General,
State of North Dakota, and executed
by the bidder as principle and by a
surety company authorized to con-
duct business in North Dakota, in a
sum equal to five percent (5%) of
the bidder’s highest total bid combi-
nation, including all add alternates to
the bid items; conditioned that if the
bid is accepted and the contract
awarded, the bidder within ten (10)
days after notice of such award, will
effect and execute a contract in ac-
cordance with the terms of his bid
and provide payment and perfor-
mance bonds as required by law
and the regulations and determina-
tions of the Owner. AIA Document
A310, Bid Bond, is provided in the
electronic project manual and should
be used to execute the bid guaran-
tee.
In compliance with Section 43-07-12
of the North Dakota Century Code,
each contractor submitting a bid
must have a copy of their North
Dakota Contractor’s License or certi-
ficate of renewal issued by the
Secretary of State enclosed in the
bid bond envelope; must be licensed
for the highest amount of their total
bid combination including add alter-
nates; and such license must have
been in effect at least ten (10) days
prior to the date of the bid opening.
No bid will be read or considered
which does not fully comply with the
provisions herein as to bid bond and
contractor license, and any deficient
bid submitted will be resealed and
returned to the bidder immediately.
The Owner reserves the right to hold
all legitimate bids for a period of thir-
ty (30) days following the date fixed
for the bid opening. It is the intent of
the Owner to award a contract to the
lowest and best bidder. The Owner
further reserves the right to reject
any and all bids and to waive irregu-
larities, and shall incur no legal liabil-
ity for the State for the payment of
any monies until the contract is
awarded and approved by the prop-
er authorities.
In compliance with Section
48-01.2-10 of the North Dakota Cen-
tury Code, the successful bidder
shall be required to furnish payment
and performance bonds covering the
faithful performance of the contract
award and the payment of all obliga-
tions thereunder, and all additional
obligations required by the laws of
the State of North Dakota. Each
bond shall be in an amount equal to
the full contract award amount.
DATED: 12 July 2021
OFFICE OF THE ADJUTANT GEN-
ERAL
Bismarck, North Dakota
By: /s/ JACKIE A. HUBER
Brigadier General, NDNG
Deputy Adjutant General
Contracting Officer
(July 13-20-27, 2021)
Minot Park District
Request for Proposal Bid –
Compact Tractor- Snow Blower &
Broom
Notice is hereby given that sealed
bids will be received by Jarrod A. Ol-
son, Director of Operations, at the
Minot Park District Office, 420 3rd
Ave SW, PO Box 538, Minot, ND
58702, until 2pm August 12th, 2021
at which times proposals will be
opened and read for furnishing to
the Board of Park Commissioners.
Envelope containing the proposal
shall be plainly marked on the out-
side – “Bid – Compact Tractor –
Snow Blower & Broom”
Copies of Specifications may be ob-
tained from the Park District Office
at above address or at
www.minotparks.com
The Board of Park Commissioners
reserves the right to reject any and
all Bids, waive any irregularities
therein, and to award the contract as
they deem to be the best interest of
the Minot Park District.
Bidders are invited to be present at
the above -mentioned time and
place for the opening of the bids.
Proposals will be presented to the
Minot Park Board on August 17th at
6:30pm.
Technical Questions Contact:
Shawn Schafer
Senior Equipment Mechanic
mechanic@minotparks.com
(701) 822-3281
Bid questions contact:
Jarrod A. Olson
Director of Operations
Minot Park District
jarrod@minotparks.com
(701) 857-4136 Office
(701) 833-7021 Cell
(July 27; August 3-10, 2021)
NOTICE OF EXECUTION SALE
Case No. 51-2019-CV-02150
STATE OF NORTH DAKOTA, IN
DISTRICT COURT, COUNTY OF
WARD, NORTH CENTRAL
JUDICIAL DISTRICT
QUICKEN LOANS INC.,
Plaintiff,
vs.
LINDA PRICE and OCCUPANTS
OF 2514 SW 2ND AVE., MINOT,
ND 58701,
Defendants.
NOTICE IS HEREBY GIVEN, that
by virtue of a Special Execution is-
sued to me by the Clerk of the Dis-
trict Court in and for the County of
Ward, North Dakota, North Central
Judicial District, I will sell the real
property described in the Judgment
entered and docketed in the Office
of the Clerk of said Court on March
19, 2020, and hereafter described to
the highest bidder for cash at public
auction at the Ward County Court-
house located in Minot, North Dako-
ta, on August 11, 2021, at the hour
of 10:00 AM (CT)of that day to satis-
fy the amount due and owing the
Plaintiff from the Defendant(s) in the
sum of $198,150.73, plus accrued
costs and interest to the date of
sale, or so much thereof as the
proceeds of said sale applicable
thereto will satisfy. The premises to
be sold as aforesaid are situated in
the County of Ward, State of North
Dakota, and are more particularly
described as follows:
Land Situated in the City of Minot in
the County of Ward in the State of
ND
Lot 21, Block 3, Dacotah Homes
Second Addition to the City of
Minot, North Dakota.
(Street Address: 2514 2nd Ave.
SW, Minot, ND 58701(June
3-10-17, 2021)
ON TESTIMONY WHEREOF, I
have hereunto set my hand and seal
the 7th day of July, 2021.
For: Robert Roed
Sheriff of Ward County,
North Dakota
By:/s/Jamie Williams
Deputy Sheriff
APPROVED AS TO FORM AND
CONTENT:
The Sayer Law Group, P.C.
Janelle G. Ewing
925 E. 4th St.
Waterloo, IA 50703
(319) 234-2530
Attorney ID No.: 08611
generalupdates@sayerlaw.com
Attorneys for Plaintiff
(July 13-20-27, 2021)
NOTICE TO CREDITORS
Probate No. 51-2021-PR-00097
IN THE DISTRICT COURT OF
WARD COUNTY, STATE OF
NORTH DAKOTA
In the Matter of the Estate of
Steven L. McLain, Deceased.
NOTICE IS HEREBY GIVEN that
the undersigned has been appointed
personal representative of the above
estate. All persons having claims
against Steven L. McLain are re-
quired to present their claims within
three (3) months after the date of the
first publication of this noticeor said
claims will be forever barred.
Claims must either be presented, in
writing, to Eric A. McLain,personal
representative of the estate, at P.O.
Box 998, Minot, ND 58702-0998,or
filed with the Court.
Dated July 2, 2021
Eric A. McLain
Personal Representative
(July 13-20-27, 2021)
NOTICE TO CREDITORS
Probate No. 51-2021-PR-00110
IN THE DISTRICT COURT OF
WARD COUNTY, STATE OF
NORTH DAKOTA
In the Matter of the Estate of
Margueritte Forsberg, Deceased.
NOTICE IS HEREBY GIVEN that:
1.Jeffrey Farstad has been appoint-
ed personal representative of the
Estate of Margueritte Forsberg.
2.All persons having claims against
Margueritte Forsberg are required to
present their claims within three (3)
months after the date of the first
publication of this notice or said
claims will be forever barred.
3.Claims must either be presented
to Jeffrey Farstad, personal
representative of the estate, at P.O.
Box 998, Minot, ND 58702-0998, or
filed with the Court.
July 7, 2021
Jeffrey Farstad
Personal Representative
(July 13-20-27, 2021)
NOTICE TO CREDITORS
Probate No. 51-2021-PR-00114
IN THE DISTRICT COURT OF
WARD COUNTY, STATE OF
NORTH DAKOTA
In the Matter of this Estate of
Dennis Long, Deceased.
NOTICE IS HEREBY GIVEN that
the undersigned has been appointed
Personal Representative of the
above estate. All persons having
claims against the deceased are re-
quired to present their claims within
three months, 90 days, after the date
of the first publication or mailing of
this notice or the claims will be for-
ever barred. Claims must either be
presented to Michael Long, Personal
Representative of the Estate of
Dennis Long, in care of , in care of
Morgan Glines of Boppre Law Firm,
PLLC, 2151 36th Ave SW, Suite B,
Minot, North Dakota 58701, or filed
with the Court.
Michael Long,
Personal Representative
Morgan Glines (ID #08853)
Boppre Law Firm, PLLC
2151 36th Ave SW, Suite B
Minot, ND 58701
Office: 701-852-5224
Fax: 701-852-5229
mglines@bopprelawfirm.com
Attorney for Personal Representativ
(July 27; August 3-10, 2021)
SUMMONS
IN THE STATE OF NORTH
DAKOTA, COUNTY OF WARD, IN
THE DISTRICT COURT, NORTH
CENTRAL JUDICIAL DISTRICT
US Bank Trust Natonal Association,
not in its individual capacity but sole-
ly as Owner Trustee for VRMTG As-
set Trust,
Plaintiff,
v.
Christopher A. Vickerman; Bremer
Bank; National Association; State of
North Dakota d/b/a The Bank of
North Dakota; any person in posses-
sion,
Defendants.
THE STATE OF NORTH DAKOTA
TO THE ABOVE-NAMED DEFEN-
DANTS:
1.To the above-mentioned Defen-
dants including all persons unk-
nown, claiming any estate or interest
in, or lien or encumbrance upon, the
real estate described below and in
the complaint.
2.You are hereby summoned and
required to appear and defend
against the Complaint in this action,
which is herewith served upon you,
by serving upon the undersigned a
copy of an Answer or other proper
response within twenty-one (21)
days after the service of this Sum-
mons upon you, exclusive of the day
of service.
3.If you fail to do so, Judgment by
default will be taken against you for
the relief demanded in the Com-
plaint.
4. This Summons and Complaint will
be filed with the Clerk of this Court.
5.This action relates to the foreclo-
sure of a mortgage upon the follow-
ing described real property in the
County of Ward, State of North
Dakota:
Lot 3, Vold’s Addition to the City
of Minot, Ward County, North
Dakota.
Property Address: 909 2nd Ave-
nue Northwest, Minot, ND 58703
6.The Plaintiff is not seeking a per-
sonal judgment against the
above-named Defendants.
Dated June 2, 2021
/s/Scott S. Skeen
Scott S. Skeen
376 East 400 South, Suite 300
Salt Lake City Utah 84111
Tel: 801-355-2886
Email: scott@hwmlawfirm.com
Bar Number: 09334
HWM: ND10664
(July 13-20-27, 2021)