INVITATION NO: IFB 21-13TOTAL

CONSTRUCTION

INVITATION TO BID

HEAT PUMP REPLACEMENT

(Area 2)

Bldg. 1500

Camp Gilbert C. Grafton

Devils Lake, North Dakota

Sealed bids for Heat Pump Re-

placement (Area 2), Bldg. 1500,

Camp Gilbert C. Grafton, Devils

Lake, North Dakota will be received

by the Adjutant General of the State

of North Dakota at Fraine Barracks,

Building 30, Bismarck, North Dako-

ta, until 2:00 PM, August 12, 2021,

and will be publicly read that date

and hour in the location designated.

All bids received after the scheduled

opening time will be returned to the

bidders unopened. The deadline for

receipt of technical questions is no

later than August 5, 2021.

Electronic bidding documents may

be requested. Emails must be ac-

companied by a copy of your current

North Dakota Contractor’s License

or Certificate of Renewal and your

request must be written on business

letterhead. No requests will be ack-

nowledged without receipt of both

documents. Requests for bidding

documents must be submitted to:

ng.nd.ndarng.list.dfe-contract-

management@mail.mil.

Due to COVID 19, the bid opening

will not be open to the public. The

front gate entrance to Fraine Bar-

racks is closed to the general public.

A representative from the Facilities

Engineering Division will be at the

gate from 12:00 Noon until 1:30 p.m.

CST on August 12, 2021. Bidders

may hand deliver their bids during

that time ONLY. Delivery by courier

service or U.S. Mail are the pre-

ferred methods for delivery.

Modifications to bids are allowed in

accordance with the instructions in

AGND Document 411, Subpara-

graph 4.4.2. All bid modifications

must be received by the Contract

Management Office no later than

2:00 p.m. CST. Be advised, the re-

ceipt of emails and faxed transmis-

sions have a delay time due to data

security restrictions and military

firewalls. Allow adequate time for

emailed and faxed transmissions to

travel through our security system.

The OWNER is not responsible for

bid modifications received by the

Contract Management Office later

than 2:00 p.m. CST on the day of

the bid opening. Modifications to

bids must be emailed to:

ng.nd.ndarng.list.dfe-contract-

management@mail.mil.

To listen to the bid opening, you

may dial in:

701-333-2840

ID No. 32068#

Pin No. 32068#

A single bid will be received for Total

Construction work (IFB 21-13).

OWNER

Office of the Adjutant General

Contract Management Branch

P.O. Box 5511

Bismarck, North Dakota 58506-5511

Telephone: (701) 333-2068

Copies of the bidding documents are

on file at the Construction Plans Ex-

change in Bismarck; Builders Ex-

changes in Dickinson, Fargo, Grand

Forks, Mandan, Minot, Rapid City,

Impact Procurement Technical As-

sistance Center in Fargo, North

Dakota and Minnesota Builders Ex-

change in Minneapolis, Minnesota.

Each bid shall be submitted in dupli-

cate using the bid response forms

provided by the Owner, enclosed in

a sealed opaque envelope and la-

beled with the necessary information

as required by the Supplementary

Instructions to Bidders.

Each bid shall be accompanied by a

separate sealed opaque envelope

containing a bidder’s bond made

payable to The Adjutant General,

State of North Dakota, and executed

by the bidder as principle and by a

surety company authorized to con-

duct business in North Dakota, in a

sum equal to five percent (5%) of

the bidder’s highest total bid combi-

nation, including all add alternates to

the bid items; conditioned that if the

bid is accepted and the contract

awarded, the bidder within ten (10)

days after notice of such award, will

effect and execute a contract in ac-

cordance with the terms of his bid

and provide payment and perfor-

mance bonds as required by law

and the regulations and determina-

tions of the Owner. AIA Document

A310, Bid Bond, is provided in the

electronic project manual and should

be used to execute the bid guaran-

tee.

In compliance with Section 43-07-12

of the North Dakota Century Code,

each contractor submitting a bid

must have a copy of their North

Dakota Contractor’s License or certi-

ficate of renewal issued by the

Secretary of State enclosed in the

bid bond envelope; must be licensed

for the highest amount of their total

bid combination including add alter-

nates; and such license must have

been in effect at least ten (10) days

prior to the date of the bid opening.

No bid will be read or considered

which does not fully comply with the

provisions herein as to bid bond and

contractor license, and any deficient

bid submitted will be resealed and

returned to the bidder immediately.

The Owner reserves the right to hold

all legitimate bids for a period of

forty-five (45) days following the date

fixed for the bid opening. It is the in-

tent of the Owner to award a con-

tract to the lowest and best bidder.

The Owner further reserves the right

to reject any and all bids and to

waive irregularities, and shall incur

no legal liability for the State for the

payment of any monies until the

contract is awarded and approved

by the proper authorities.

In compliance with Section

48-01.2-10 of the North Dakota Cen-

tury Code, the successful bidder

shall be required to furnish payment

and performance bonds covering the

faithful performance of the contract

award and the payment of all obliga-

tions thereunder, and all additional

obligations required by the laws of

the State of North Dakota. Each

bond shall be in an amount equal to

the full contract award amount.

DATED: 19 July 2021

OFFICE OF THE ADJUTANT

GENERAL

Bismarck, North Dakota

By: /s/ JACKIE A. HUBER

Brigadier General, NDNG

Deputy Adjutant General

Contracting Officer

(July 26, August 2-9, 2021)

INVITATION NO: IFB 21-12 TOTAL

CONSTRUCTION

INVITATION TO BID

MILITARY PARKING LOT

SURFACING

Aviation Readiness Center

Complex

Bismarck, North Dakota

Sealed bids for Military Parking Lot

Surfacing, Aviation Readiness

Center Complex, Bismarck, North

Dakota will be received by the Adju-

tant General of the State of North

Dakota at Fraine Barracks, Building

30, Bismarck, North Dakota, until

2:00 PM, August 5, 2021, and will be

publicly read that date and hour in

the location designated. All bids re-

ceived after the scheduled opening

time will be returned to the bidders

unopened. The deadline for receipt

of technical questions is no later

than July 29, 2021. Electronic bid-

ding documents may be requested.

Emails must be accompanied by a

copy of your current North Dakota

Contractor’s License or Certificate of

Renewal and your request must be

written on business letterhead. No

requests will be acknowledged

without receipt of both documents.

Requests for bidding documents

must be submitted to:

ng.nd.ndarng.list.dfe-contract-

management@mail.mil.

Due to COVID 19, the bid opening

will not be open to the public. The

front gate entrance to Fraine Bar-

racks is closed to the general public.

A representative from the Facilities

Engineering Division will be at the

gate from 12:00 Noon until 1:30 p.m.

CST on August 5, 2021. Bidders

may hand deliver their bids during

that time ONLY. Delivery by courier

service or U.S. Mail are the pre-

ferred methods for delivery.

Modifications to bids are allowed in

accordance with the instructions in

AGND Document 411, Subpara-

graph 4.4.2. All bid modifications

must be received by the Contract

Management Office no later than

2:00 p.m. CST. Be advised, the re-

ceipt of emails and faxed transmis-

sions have a delay time due to data

security restrictions and military

firewalls. Allow adequate time for

emailed and faxed transmissions to

travel through our security system.

The OWNER is not responsible for

bid modifications received by the

Contract Management Office later

than 2:00 p.m. CST on the day of

the bid opening. Modifications to

bids must be emailed to:

ng.nd.ndarng.list.dfe-contract-

management@mail.mil.

To listen to the bid opening, you

may dial in:

701-333-2840

ID No. 32076#

Pin No. 32076#

A single bid will be received for Total

Construction work (IFB 21-12).

OWNER

Office of the Adjutant General

Contract Management Branch

P.O. Box 5511

Bismarck, North Dakota 58506-5511

Telephone: (701) 333-2068

Copies of the bidding documents are

on file at the Construction Plans Ex-

change in Bismarck; Builders Ex-

changes in Dickinson, Fargo, Grand

Forks, Mandan, Minot, Rapid City,

Impact Procurement Technical As-

sistance Center in Fargo, North

Dakota and Minnesota Builders Ex-

change in Minneapolis, Minnesota.

Each bid shall be submitted in dupli-

cate using the bid response forms

provided by the Owner, enclosed in

a sealed opaque envelope and la-

beled with the necessary information

as required by the Supplementary

Instructions to Bidders.

Each bid shall be accompanied by a

separate sealed opaque envelope

containing a bidder’s bond made

payable to The Adjutant General,

State of North Dakota, and executed

by the bidder as principle and by a

surety company authorized to con-

duct business in North Dakota, in a

sum equal to five percent (5%) of

the bidder’s highest total bid combi-

nation, including all add alternates to

the bid items; conditioned that if the

bid is accepted and the contract

awarded, the bidder within ten (10)

days after notice of such award, will

effect and execute a contract in ac-

cordance with the terms of his bid

and provide payment and perfor-

mance bonds as required by law

and the regulations and determina-

tions of the Owner. AIA Document

A310, Bid Bond, is provided in the

electronic project manual and should

be used to execute the bid guaran-

tee. In compliance with Section

43-07-12 of the North Dakota Centu-

ry Code, each contractor submitting

a bid must have a copy of their

North Dakota Contractor’s License

or certificate of renewal issued by

the Secretary of State enclosed in

the bid bond envelope; must be

licensed for the highest amount of

their total bid combination including

add alternates; and such license

must have been in effect at least ten

(10) days prior to the date of the bid

opening. No bid will be read or con-

sidered which does not fully comply

with the provisions herein as to bid

bond and contractor license, and

any deficient bid submitted will be

resealed and returned to the bidder

immediately.

The Owner reserves the right to hold

all legitimate bids for a period of thir-

ty (30) days following the date fixed

for the bid opening. It is the intent of

the Owner to award a contract to the

lowest and best bidder. The Owner

further reserves the right to reject

any and all bids and to waive irregu-

larities, and shall incur no legal liabil-

ity for the State for the payment of

any monies until the contract is

awarded and approved by the prop-

er authorities. In compliance with

Section 48-01.2-10 of the North

Dakota Century Code, the success-

ful bidder shall be required to furnish

payment and performance bonds

covering the faithful performance of

the contract award and the payment

of all obligations thereunder, and all

additional obligations required by the

laws of the State of North Dakota.

Each bond shall be in an amount

equal to the full contract award

amount.

DATED: 12 July 2021

OFFICE OF THE ADJUTANT

GENERAL

Bismarck, North Dakota

By: /s/ JACKIE A. HUBER

Brigadier General, NDNG

Deputy Adjutant General

Contracting Officer

(July 19-26 August 2, 2021)

MINOT CITY COUNCIL –

SCHEDULED MEETING –

JULY 19, 2021 AT 5:30 P.M.

Members Present: Evans, Jantzer,

Olson, Pitner, Podrygula, Ross,

Sipma Members Absent: None May-

or Sipma presiding and led the City

Council in the Pledge of Allegiance.

The City Manager provided a written

update describing events and activi-

ties for various departments. He also

gave a reminder of the public input

meeting on Thursday from 6:00-8:00

pm regarding plans and designs for

the new City Hall Rehabilitation pro-

ject. Ross moved Pitner seconded

and was carried unanimously to ap-

prove a subdivision plat to create

Pendleton Estates 2nd Addition sub-

division, being Lots 9 & 10, Block 2,

Pendleton Estates Addition; approve

a subdivision plat to create Urban

15th addition, being Lots 2, 3, & 4,

Urban Fifth Addition to the City of

Minot; approve a subdivision plat to

create 3 separate lots known as

Southwest Business Park 3rd Addi-

tion from Lot 2, Block 1 of Southwest

Business Park Second Addition,

Section 32, Township 155 North,

Range 83 West. The City Council

held a public hearing to consider a

request for an annexation and a zon-

ing map amendment from “AG” to

“M1” of Outlot 35 Section

29-155N-82W. No one appeared in

favor or opposed to the request.

Jantzer moved Olson seconded and

was carried unanimously to close

the public hearing and place and

pass ordinance 5627 on first reading

to annex into the corporate limits of

the City of Minot Outlot 35 of Section

29-155N-82W; place and pass ordi-

nance 5628 on first reading to

change the zoning designation of

Outlot 35 of Section 29-155N-82W

from “AG” to “M1”. The ordinance is

available for public inspection M-F

from 8:00-4:30. The City Council

held a public hearing to consider a

request for a zoning map amend-

ment from “C2” to “AG” for a 10-acre

portion of their property to be known

as Outlot 23. The property is legally

known as an unplatted portion of the

NE 1/4 of the SE 1/4, Section 19,

Township 155 North, Range 83

West, Ward County, North Dakota.

No one appeared in favor or op-

posed to the request. Pitner moved

Jantzer seconded and was carried

unanimously to close the public

hearing and place and pass ordi-

nance 5629 on first reading to

change the zoning designation of

Outlot 23 of Section 19-155N-83W

from “C2” to “AG”. The ordinance is

available for public inspection M-F

from 8:00-4:30. Olson moved Ross

seconded and was carried unani-

mously to confirm Lindsey Bertsch

to the Library Board with a term to

expire June 2024; approve the

minutes of the July 6, 2021 regular

City Council meeting; place and

pass ordinance 5611 on second

reading to rezone Bertsch Addition,

Lot 2 from “AG” to both “AG” and

“RR”; place and pass ordinance

5623 on second reading amending

the 2021 annual budget for LOIS,

using cash reserves; place and pass

ordinance 5624 on second reading

amending the 2021 annual budget

for the CRISI grant, using cash

reserves; place and pass ordinance

5625 on second reading amending

the 2021 annual budget for the 2021

ACRGP concessions addendum

grant; place and pass ordinance

5626 on second reading amending

the 2021 annual budget for the trade

of the Airport 2019 Toro mower; rati-

fy the administratively approved re-

quests; approve final payment to

NDDOT in the amount of $3,607.42

for the 3rd Street SE and Burdick

Expy HSIP project; approve final

payment to Wagner Construction in

the amount of $162,990.49 for

Storm Sewer District 123- 10th

Street SW; approve the bid from

Gefroh Electric in the amount of

$131,280 for 160 LED streetlights

for the Traffic Department; place and

pass ordinance 5630 on first reading

amending the 2021 annual budget

for the street light LED conversion;

place and pass ordinance 5631 on

first reading modifying the 1st Street

SW approaches from Yield control to

Stop control at the intersection with

13th Avenue SW; accept the ARPA

grant for Federal Assistance to as-

sist with costs related to operations,

personnel, cleaning, sanitizing, jani-

torial services, prevention, prepara-

tion, and response to the COVID-19

pandemic; approve the Right of Way

Encroachment Agreement Applica-

tion submitted by S-J ONE

ELEVEN, LLC for the installation of

an ADA access for their building at

111 West Central Avenue; approve

the Right of Way Encroachment Per-

mit Application by Dakota Agronomy

Partners for the sign at 1602 27th St

SE; approve the Right of Way En-

croachment Agreement Application

submitted by Meadowlark Holdings,

LLC for the installation of private

storm sewer to tie into a City catch

basin east of Lot 1 Livingston’s 9th

Addition, along 21st Avenue SE.

The City Manager stated he has

heard public concerns regarding

inaccessibility to the Carnegie

Center. He discussed the issue with

community leaders, contacted the

current lease holder, and decided

the agreement with MACA would be

a better use of the facility. In con-

junction with the effort to revitalize

downtown and considering the signi-

ficant repairs recently done on the

facility, this lease will mutually bene-

fit the City and Minot Area Council of

the Arts (MACA). The lease includes

rental fees to act as revenue for

MACA while providing a percentage

to the City to cover costs of utilities

and maintenance. Mayor Sipma said

he shares the concerns with acces-

sibility and hopes MACA can better

utilize the space. Olson said she ful-

ly supports the new arrangement but

asked about the religious group who

has been renting the space. Mr.

Stewart explained that he is waiting

for an opinion from the City Attorney

but in his experience, a religious ac-

tivity is not a permitted use in a

taxpayer-owned facility. Allowing re-

ligious organizations to rent the facil-

ity could lead to potential litigation if

anyone raised concerns. Ross

asked if MACA developed a plan for

use of the facility. Justin Anderson,

Executive Director of Minot Area

Council of the Arts said, the Board

discussed it but has to wait and see

how it is received by the public. The

building hasn’t been highlighted pub-

licly so it is difficult to project the lev-

el of interest. He also said, the lease

was written in a way so that aspects

can be revisited periodically. The

building will be available for rent and

they hope revenue can be invested

into the facility to bring it up to par

with other event spaces. Olson

moved Pitner seconded and was

carried unanimously to approve a

two-year Lease of the Carnegie

Center to MACA. The Mayor rem-

inded everyone the ND State Fair

starts on Friday. He will participate

in the parade on Saturday as will the

Police Department, Fire Department

and Sanitation. He encouraged

everyone to support the local

businesses involved especially since

the Fair was cancelled in 2020. He

also commented on the impact the

closed Canadian border will have on

the event this year. Liaison Reports

Alderman Podrygula said the Emer-

gency Resource Council had a

presentation from the National

Guard on the resources they have

available. The Commission on Aging

will take their August meeting off but

will have a presence at the State

Fair. They are currently working on

parking lot repairs and many of their

programs will return in August. The

Ward County Planning Commission

continues to struggle with rewriting

the zoning code. They will begin

sharing the plan throughout smaller

towns within the county for input.

Alderwoman Olson said her commit-

tees have not met but she also rem-

inded everyone to attend the City

Hall project Open House on Thurs-

day. Alderwoman Evans said the Li-

brary Board appointment was con-

firmed by the Council adding a

younger perspective to the Board.

She also announced the Library has

eliminated fees for all materials ex-

cept tools. Mayor Sipma attended

the Chamber EDC meeting. He also

testified in Bismarck for NAWS and

spoke to the Water Topics Commit-

tee. Alderman Ross met with the

Zoning Ordinance Steering Commit-

tee, details of which were included in

the City Manager report. They will

continue to work on the Subdivision

chapter of the Code. Alderman

Jantzer had no meetings to report.

Alderman Pitner sat on the selection

committee to choose a firm to up-

date the comprehensive plan. They

came to a decision and staff is

currently working out the details of

the contract. There being no further

business, Pitner moved Ross

seconded and carried unanimously

to adjourn the meeting at 5:54 pm

APPROVED: Shaun Sipma, Mayor;

ATTEST: Kelly Matalka, City Clerk –

PURSUANT TO NDCC 40-01-09.1,

THESE MINUTES PUBLISHED

SUBJECT TO THE COUNCIL’S RE-

VIEW AND REVISION

(July 26,2021)

NOTICE

CASE NO. 51-2021-CV-00616

STATE OF NORTH DAKOTA,

COUNTY OF WARD, IN DISTRICT

COURT, NORTH CENTRAL

JUDICIAL DISTRICT

First Western Bank & Trust,

a Corporation

Plaintiff,

Vs.

Stacy L. Mathson a/k/a Stacy L.

Hetletved

and Anthony R. Mathson,

Defendants.

NOTICE IS HEREBY GIVEN that by

virtue of a Judgment and decree in

foreclosure, rendered by the District

Court of the North Central Judicial

District, in and for the County of

Ward, State of North Dakota, and

entered and docketed in the office of

the Clerk of District Court in and for

said County on the 10th day of June,

2021, in an action wherein First

Western Bank & Trust was the

Plaintiff, and Stacy L. Mathson a/k/a

Stacy L. Hetletved and Anthony R.

Mathson were the Defendants, ad-

judging that there was due and ow-

ing the Plaintiff as of such day from

Defendants Stacy L. Mathson a/k/a

Stacy L. Hetletved and Anthony R.

Mathson, together with costs and

disbursements of said action, the

sum of $192,631.14, which Judg-

ment and decree, among other

things, directs the sale of the real

estate hereinafter described to satis-

fy the amount of the Judgment with

interest thereon and the costs and

expenses of such sale or so much

thereof as the

proceeds of the sale will satisfy, and

by virtue of a Special Execution is-

sued to me by the

Clerk of said Court, I will sell the real

property described in said Judgment

and hereafter

described to the highest bidder for

cash, at public auction at the front

door of the

courthouse located at 315 3rd Street

SE, Minot, Ward County, North

Dakota, on the 18th

day of August, 2021 at 10:00 a.m.

on that day, to satisfy the amount

due with accrued

costs and interest at the date of

sale, or so much thereof as the

proceeds of said sale

applicable thereto will satisfy.

The premises to be sold as afore-

said is situated in the County of

Ward, State of

North Dakota, and is more particu-

larly described as follows:

Lot 16, Western Hills Addition to

the City of Minot, Ward County,

North

Dakota, plus ¢ Adjacent Vacated

Alley

The failure to include the street ad-

dress in the Notice does not affect

the validity

of this Notice. Please note the sale

is subject to cancellation or post-

ponement.

Dated this 7th day of July, 2021.

Robert Roed

Sheriff of Ward County, North Dako-

ta

By: /s/ Jamie Williams

Jamie Williams – Deputy Sheriff

Matthew H. Olson – #06182

Pringle & Herigstad, P.C.

2525 Elk Drive

P.O. Box 1000

Minot, ND 58702-1000

Telephone (701) 852-0381

molson@pringlend.com

Attorneys for Plaintiff

(July 19-26; August 2, 2021)

Notice of Public Hearing

A public hearing will be held on

Tuesday August 10th, 2021, at the

Surrey City Hall at 6:00pm on the

following request: Martin Saldana

and Chelsi Hansen are requesting a

Conditional use to house livestock

(i.e.) chickens, goats, and cows at

815 97th St SE, legal description

(OLT 64 of SWSW 19-155-81

Surrey TWPA 2.00). Anyone protest-

ing or having questions regarding

the granting of the conditional use

may appear to this hearing.

BY THE ORDER OF THE SURREY

CITY COUNCIL AND THE PLAN-

NING AND ZONING COMMISION

CITY OF SURREY

KIM SHAW, DEPUTY AUDITOR

(July 26, 2021)

NOTICE OF REAL ESTATE SALE

Civil No: 51-2020-CV-00336

STATE OF NORTH DAKOTA,

COUNTY OF WARD IN THE

DISTRICT COURT, NORTH

CENTRAL JUDICIAL DISTRICT

U.S. Bank National Association,

Plaintiff,

vs.

Gregory P. Prellwitz and State of

North Dakota acting by and through

the Department of Human Services

and all persons unknown, claiming

any estate or interest in, or lien or

encumbrance upon, the real estate

described in the complaint, and any

person in possession,

Defendants.

1. Judgment in the amount of

$149,586.35, having been entered in

favor of Plaintiff and against Defen-

dants, which Judgment was filed

with the Clerk of Courts of Ward

County, North Dakota, on March 10,

2021, for the foreclosure of a real

estate mortgage.

2. Notice is hereby given pursuant to

said Judgment that the real property

described as:

Lot 5, Block 9, Blaisdell-Bird Ad-

dition to the City of Minot, Ward

County, North Dakota. Real Pro-

perty address: 517 17th Street

NW, Minot, ND 58703

The above real property is the sub-

ject of the Mortgage dated August

15, 2012, which Mortgagors, Gre-

gory P. Prellwitz, executed and

delivered to Mortgage Electronic

Registration Systems, Inc., as mort-

gagee, as nominee for U.S. Bank

N.A., its successors and assigns.

and recorded in the office of the

Clerk and Recorder of Ward County,

North Dakota, on August 16, 2012,

Instrument Number 2945052, which

is subject to the entered Judgment.

Said Mortgage was assigned to

Plaintiff, its successors or assigns,

by Assignment of Mortgage record-

ed August 28, 2017, Instrument

Number 3011461.

3. In order to realize the amount of

$149,586.35, as of March 10, 2021,

plus interest accruing thereafter on

said amount at the rate of 3.25000%

per year together with the costs and

expenses of sale, will be sold sub-

ject to redemption as provided by

law as one parcel of land at public

auction, subject to the lien for unpaid

real estate taxes and assessments

of Ward County, North Dakota, and

easements and restrictions of

record, to the highest bidder for cash

under the direction of the Sheriff of

Ward County, North Dakota, at the

main entrance of the Ward County

Courthouse located at 315 SE 3rd

Street, Minot, North Dakota 58701,

on August 18, 2021 (“Sale Date”), at

10:00 AM.

4. If the sale is set aside for reason,

the Purchaser at the sale shall be

entitled only to a return of the depo-

sit paid. The purchaser shall have

no further recourse against the Mort-

gagor, the Mortgagee or the

Mortgagee’s attorney.

DATED this 7th day of July, 2021.

SHERIFF OF WARD COUNTY

By: Robert Roed Sheriff / Deputy

Sheriff of Ward

Halliday, Watkins & Mann, P.C.

By: Scott S. Skeen

Attorneys for Plaintiff

376 East 400 South, Suite 300

Salt Lake City, UT 84111

Tel: 801-355-2886

Email: scott@hwmlawfirm.com

Bar: 0933

(July 19-26 August 2, 2021)

NOTICE OF REAL ESTATE SALE

Civil No: 51-2018-CV-00127

STATE OF NORTH DAKOTA,

COUNTY OF WARD IN THE

DISTRICT COURT, NORTH

CENTRAL JUDICIAL DISTRICT

Reverse Mortgage Funding, LLC,

Plaintiff,

vs.

Cheryl D. Lane and Heirs & Devi-

sees of the Estate of Cheryl D. Lane

and United States of America, acting

by and through the Secretary of

Housing and Urban Development

and Unknown Spouse of Cheryl D.

Lane and Unknown Spouse of Ruth

Lane and all persons unknown,

claiming any estate or interest in, or

lien or encumbrance upon, the real

estate described in the complaint,

and any person in possession

Defendants.

1. Judgment in the amount of

$197,606.49, having been entered in

favor of Plaintiff and against Defen-

dants, which Judgment was filed

with the Clerk of Courts of Ward

County, North Dakota, on December

7, 2020, for the foreclosure of a real

estate mortgage.

2. Notice is hereby given pursuant to

said Judgment that the real property

described as:

The above real property is the sub-

ject of the Mortgage dated February

13, 2015, which Mortgagors, Cheryl

D. Lane, executed and delivered to

Mortgage Electronic Registration

Systems, Inc., as Mortgagee, as

nominee for Reverse Mortgage

Funding LLC, its successors and

assigns.and recorded in the office of

the Clerk and Recorder of Ward

County, North Dakota, on March 2,

2015, Instrument Number 2983529,

which is subject to the entered Judg-

ment. Said Mortgage was assigned

to Plaintiff, its successors or The fol-

lowing described parcel of land, and

improvements and appurtenances

thereto in the County of Ward, State

of ND, to wit: Countryside Villas, 3rd

Addition Lot 2, Nedrose-S4 A 2 To-

gether with: Used 2000 Bonnavilla

52 x 28 Manufactured Home Serial

No. NEB00A28052S. MORE

CORRECTLY DESCRIBED AS

FOLLOWS: The following described

parcel of land, and improvements

and appurtenances thereto in the

County of Ward, State of ND, to wit:

Countryside Villas, 3rd Addition Lot

2, Nedrose-S4 A 2 Together with:

Used 2000 Bonneville 52 x 28

Manufactured Home Serial No.

NEB00A28052S. Real Property ad-

dress: 2105 55th Street SE, Minot,

ND 58701 assigns, by Assignment

of Mortgage recorded September

13, 2017, Instrument Number

3012033.

3. In order to realize the amount of

$197,606.49, as of December 7,

2020, plus interest accruing

thereafter on said amount at the rate

of 2.882% per year together with the

costs and expenses of sale, will be

sold subject to redemption as pro-

vided by law as one parcel of land at

public auction, subject to the lien for

unpaid real estate taxes and assess-

ments of Ward County, North Dako-

ta, and easements and restrictions

of record, to the highest bidder for

cash under the direction of the Sher-

iff of Ward County, North Dakota, at

the main entrance of the Ward

County Courthouse located at 315

SE 3rd Street, Minot, North Dakota

58701, on August 18, 2021 (“Sale

Date”), at 10:00 AM.

4. If the sale is set aside for reason,

the Purchaser at the sale shall be

entitled only to a return of the depo-

sit paid. The purchaser shall have

no further recourse against the Mort-

gagor, the Mortgagee or the

Mortgagee’s attorney.

DATED this 7th day of July, 2021.

SHERIFF OF WARD COUNTY

By: Robert Roed

Sheriff / Deputy Sheriff of Ward

Halliday, Watkins & Mann, P.C.

By: Scott S. Skeen

Attorneys for Plaintiff

376 East 400 South, Suite 300

Salt Lake City, UT 84111

Tel: 801-355-2886

Email: scott@hwmlawfirm.com

Bar: 0933

(July 19-26 August 2, 2021)

NOTICE OF REAL ESTATE SALE

Civil No: 51-2020-CV-00313

STATE OF NORTH DAKOTA,

COUNTY OF WARD IN THE

DISTRICT COURT, NORTH

CENTRAL JUDICIAL DISTRICT

Flagstar Bank,

Plaintiff,

vs.

Andrea L. Golden and Kevin M. Gol-

den and ProCollect Services, L.L.C.

and all persons unknown, claiming

any estate or interest in, or lien or

encumbrance upon, the real estate

described in the complaint, and any

person in possession,

Defendants.

1. Judgment in the amount of

$266,718.38, having been entered in

favor of Plaintiff and against Defen-

dants, which Judgment was filed

with the Clerk of Courts of Ward

County, North Dakota, on May 19,

2021, for the foreclosure of a real

estate mortgage.

2. Notice is hereby given pursuant to

said Judgment that the real property

described as:

Lot 2, Block 4, Valli Hai Addition

to the City of Minot, Ward County,

North Dakota.

Real Property address:1304 13th

Avenue NW, Minot, ND 58703

The above real property is the sub-

ject of the Mortgage dated June 7,

2017, which Mortgagors, Andrea L.

Golden, Kevin M. Golden, executed

and delivered to Mortgage Electronic

Registration Systems, Inc., as Mort-

gagee, as nominee for Premier

Mortgage Corp, its successors and

assigns .and recorded in the office of

the Clerk and Recorder of Ward

County, North Dakota, on June 8,

2017, Instrument Number 3009204,

which is subject to the entered Judg-

ment. Said Mortgage was assigned

to Plaintiff, its successors or as-

signs, by Assignment of Mortgage

recorded May 29, 2019, Instrument

Number 3028226.

3. In order to realize the amount of

$266,718.38, as of May 19, 2021,

plus interest accruing thereafter on

said amount at the rate of 3.87500%

per year together with the costs and

expenses of sale, will be sold sub-

ject to redemption as provided by

law as one parcel of land at public

auction, subject to the lien for unpaid

real estate taxes and assessments

of Ward County, North Dakota, and

easements and restrictions of

record, to the highest bidder for cash

under the direction of the Sheriff of

Ward County, North Dakota, at the

main entrance of the Ward County

Courthouse located at 315 SE 3rd

Street, Minot, North Dakota 58701,

on August 18, 2021 (“Sale Date”), at

10:00 AM.

4. If the sale is set aside for reason,

the Purchaser at the sale shall be

entitled only to a return of the depo-

sit paid. The purchaser shall have

no further recourse against the Mort-

gagor, the Mortgagee or the

Mortgagee’s attorney.

DATED this 7th day of July, 2021.

SHERIFF OF WARD COUNTY

By: Robert Roed

Sheriff / Deputy Sheriff of Ward

Halliday, Watkins & Mann, P.C.

By: Scott S. Skeen

Attorneys for Plaintiff

376 East 400 South, Suite 300

Salt Lake City, UT 84111

Tel: 801-355-2886

Email: scott@hwmlawfirm.com

Bar: 09334

(July 19-26 August 2, 2021)

NOTICE OF REAL ESTATE SALE

Civil No: 51-2017-CV-01103

STATE OF NORTH DAKOTA,

COUNTY OF WARD IN THE

DISTRICT COURT, NORTH

CENTRAL JUDICIAL DISTRICT

U.S. Bank National Association,

Plaintiff,

vs.

Joshua D. Gill and Portfolio

Recovery Associates, LLC and Pro-

Collect Services LLC and all per-

sons unknown, claiming any estate

or interest in, or lien or encumbrance

upon, the real estate described in

the complaint, and any person in

possession,

Defendants.

1. Judgment in the amount of

$360,532.12, having been entered in

favor of Plaintiff and against Defen-

dants, which Judgment was filed

with the Clerk of Courts of Ward

County, North Dakota, on March 25,

2021, for the foreclosure of a real

estate mortgage.

2. Notice is hereby given pursuant to

said Judgment that the real property

described as:

Lot 44, Green Acres Third Addi-

tion to the City of Minot, Ward

County, North Dakota. Real Pro-

perty address: 2312 23rd Street

SW, Minot, ND 58701

The above real property is the sub-

ject of the Mortgage dated August

27, 2015, which Mortgagors, Joshua

D. Gill, executed and delivered to

Mortgage Electronic Registration

Systems, Inc., as Mortgagee, as

nominee for Town and Country

Credit Union, its successors and

assigns.and recorded in the office of

the Clerk and Recorder of Ward

County, North Dakota, on August

31, 2015, Instrument Number

2989692, which is subject to the en-

tered Judgment. Said Mortgage was

assigned to Plaintiff, its successors

or assigns, by Assignment of Mort-

gage recorded May 2, 2016, Instru-

ment Number 2996820.

3. In order to realize the amount of

$360,532.12, as of March 25, 2021,

plus interest accruing thereafter on

said amount at the rate of 3.50000%

per year together with the costs and

expenses of sale, will be sold sub-

ject to redemption as provided by

law as one parcel of land at public

auction, subject to the lien for unpaid

real estate taxes and assessments

of Ward County, North Dakota, and

easements and restrictions of

record, to the highest bidder for cash

under the direction of the Sheriff of

Ward County, North Dakota, at the

main entrance of the Ward County

Courthouse located at 315 SE 3rd

Street, Minot, North Dakota 58701,

on August 18, 2021 (“Sale Date”), at

10:00 AM.

4. If the sale is set aside for reason,

the Purchaser at the sale shall be

entitled only to a return of the depo-

sit paid. The purchaser shall have

no further recourse against the Mort-

gagor, the Mortgagee or the

Mortgagee’s attorney.

DATED this 7th day of July, 2021.

SHERIFF OF WARD COUNTY

By: Robert Roed

Sheriff / Deputy Sheriff of Ward

Halliday, Watkins & Mann, P.C.

By: Scott S. Skeen

Attorneys for Plaintiff

376 East 400 South, Suite 300

Salt Lake City, UT 84111

Tel: 801-355-2886

Email: scott@hwmlawfirm.com

Bar: 09334

(July 19-26 August 2, 2021)

NOTICE TO CREDITORS

Probate No. 51-2021-PR-00112

IN THE DISTRICT COURT OF

WARD COUNTY, STATE OF

NORTH DAKOTA, NORTH

CENTRAL JUDICIAL DISTRICT

In the Matter of the Estate of Patricia

Ann Vedquam, Deceased.

NOTICE IS HEREBY GIVEN that

Lisa Hoffer has been appointed per-

sonal representative of the above

estate. All persons having claims

against the said deceased are re-

quired to present their claims within

three months after the date of the

first publication of this notice or said

claims will be forever barred. Claims

must either be presented to Lisa

Hoffer, personal representative of

the estate in care of Robert Martin,

at Martin Law, 201 South Main St.

Suite 200, Minot, North Dakota

58701, or filed with the Court.

Dated this 14th day of July, 2021.

/s/Robert W. Martin (ID No. 04636)

Martin Law

201 South Main St., Suite 200

Minot, ND 58701

rwmlawyer@hotmail.com

Telephone: (701) 852-4837

(July19-26 August 2, 2020)

School Annexation Hearing

Notice is given that a public hearing

will be held by the Ward County Tui-

tion Appeals Committee, Wednes-

day, August 11th, 2021at 1:00 pm in

the Commissioners’ Chambers,

Ward County Administration Build-

ing, 255 3rd Street SE, Minot, North

Dakota, for the purpose of consider-

ing a tuition appeal from the Surrey

School District #41 to the Minot

School District #1. Both School Dis-

tricts are located primarily in Ward

County.

The Tuition Free Request comes

from the following territory:

Section 18: Silver Springs South 3rd

Addition; Lot 2 of Surrey Township

155 North, Range 81 West of Ward

County, North Dakota

This hearing is held in accordance

with the North Dakota Century

School Code Chapter 15.1-29 and

by order of the Ward County Tuition

Appeal Committee

Jodi Johnson, Ward County Super-

intendent of Schools

(July 26, 2021)