ADVERTISEMENT FOR BIDS

CITY OF MINOT, NORTH DAKOTA

2021 SIDEWALK, CURB AND

GUTTER REPLACEMENT

CITY PROJECT 4554

NOTICE IS HEREBY GIVEN that

the City of Minot (Owner) is re-

questing Bids for the construction of

the following Project: 2021 Sidewalk,

Curb and Gutter Replacement.

Bids for the construction of the Pro-

ject will be received at the office of

the City Clerk located at 515 Second

Avenue SW (Second Floor), Minot,

North Dakota 58701, until Tuesday,

March 9, 2021 at 11:00 AM local

time. At that time the Bids received

will be publicly opened and read.

The Project includes the following

Work: Removing and replacing con-

crete sidewalk, ADA ramps, curb &

gutter, asphalt, non-reinforced con-

crete pavement, reinforced concrete

pavement, and other related items.

Complete digital project bidding do-

cuments are available at www.

questcdn.com. You may download

the digital plan documents for $40

by inputting eBidDoc #7558040 on

the website’s Project Search page.

Please contact QuestCDN.com at

952-233-1632 or info@questcdn.

com for assistance in free member-

ship registration, downloading, and

working with this digital project infor-

mation. Project bidding documents

are also available at the Issuing Of-

fice – City of Minot Engineering

Department 1025 31st St SE and

are available for purchase for $75.

Potential bidders may contact the

Assistant City Engineer at

701-857-4100 with any questions.

Each bid must be accompanied by a

separate envelope containing the

bid security in a sum equal to five

percent of the full amount of the bid

and must be in the form of a bidder’s

bond. A bidder’s bond must be exe-

cuted by the bidder as principal and

by a surety, conditioned that if the

principal’s bid is accepted and the

contract awarded to the principal,

the principal, within ten days after

notice of the award, shall execute a

contract in accordance with the

terms of the bid and the bid bond,

and any condition of the City of

Minot, as required by law. A counter-

signature of a bid bond is not re-

quired. If the City of Minot elects to

award a contract to the lowest

responsible bidder, and the lowest

responsible bidder does not execute

a contract within the ten days al-

lowed, the bidder’s bond must be

forfeited to the City of Minot and the

project awarded to the next lowest

responsible bidder.

Each bidder must possess a valid

North Dakota contractor’s license for

the full amount of their bid, as re-

quired by Section 43-07-07 of the

North Dakota Century Code. Each

bidder MUST enclose a copy of their

Contractor’s License or Certificate of

Renewal, issued by the North Dako-

ta Secretary of State, in their bid

bond envelope, and each license

must be valid and dated at least 10

days prior to the date set for bid

opening, as required under Section

43-07-12 of the North Dakota Centu-

ry Code.

No bid may be read or considered if

it does not fully comply with the re-

quirements of Section 48-01.2-05 of

the North Dakota Century Code, and

any deficient bid submitted will be

resealed and returned to the bidder

immediately.

All Bids submitted and all Work

completed must be as stipulated in

the Agreement.

The City of Minot reserves the right

to hold all Bids for a period of 30

days after the date of the bid open-

ing, to reject any or all Bids and to

rebid the project until a satisfactory

bid is received, and to waive any in-

formality or irregularity in any Bid.

For all further requirements regard-

ing bid submittal, qualifications, pro-

cedures, and contract award, refer to

the Instructions to Bidders that are

included in the Bidding Documents.

By order of the City Council of the

City of Minot, North Dakota.

Owner: City of Minot

By: Kelly Matalka

Title: City Clerk

Date: February 12, 2021

(February 12-19-26, 2021)

ADVERTISEMENT FOR BIDS

CITY OF MINOT, NORTH DAKOTA

2021 Street Seal

CITY PROJECT 4552

NOTICE IS HEREBY GIVEN that

the City of Minot (Owner) is re-

questing Bids for the construction of

the following Project: 2021 Street

Seal.

Bids for the construction of the Pro-

ject will be received at the office of

the City Clerk located at 515 Second

Avenue SW (Second Floor), Minot,

North Dakota 58701, until Tuesday,

March 9, 2021 at 11:00 AM local

time. At that time the Bids received

will be publicly opened and read.

The Project includes the following

Work: Asphalt patching, milling, as-

phalt paving, crack sealing, chip

seal, fog seal, pavement markings,

traffic control, and other related

work.

Complete digital project bidding do-

cuments are available at www.quest

cdn.com. You may download the di-

gital plan documents for $40 by in-

putting eBidDoc #7558089 on the

website’s Project Search page.

Please contact QuestCDN.com at

952-233-1632 or info@questcdn.

com for assistance in free member-

ship registration, downloading, and

working with this digital project infor-

mation. Project bidding documents

are also available at the Issuing Of-

fice – City of Minot Engineering

Department 1025 31st St SE and

are available for purchase for $75.

Potential bidders may contact the

Assistant City Engineer at 701-

857-4100 with any questions.

Each bid must be accompanied by a

separate envelope containing the

bid security in a sum equal to five

percent of the full amount of the bid

and must be in the form of a bidder’s

bond. A bidder’s bond must be exe-

cuted by the bidder as principal and

by a surety, conditioned that if the

principal’s bid is accepted and the

contract awarded to the principal,

the principal, within ten days after

notice of the award, shall execute a

contract in accordance with the

terms of the bid and the bid bond,

and any condition of the City of

Minot, as required by law. A counter-

signature of a bid bond is not re-

quired. If the City of Minot elects to

award a contract to the lowest

responsible bidder, and the lowest

responsible bidder does not execute

a contract within the ten days al-

lowed, the bidder’s bond must be

forfeited to the City of Minot and the

project awarded to the next lowest

responsible bidder.

Each bidder must possess a valid

North Dakota contractor’s license for

the full amount of their bid, as re-

quired by Section 43-07-07 of the

North Dakota Century Code. Each

bidder MUST enclose a copy of their

Contractor’s License or Certificate of

Renewal, issued by the North Dako-

ta Secretary of State, in their bid

bond envelope, and each license

must be valid and dated at least 10

days prior to the date set for bid

opening, as required under Section

43-07-12 of the North Dakota Centu-

ry Code.

No bid may be read or considered if

it does not fully comply with the re-

quirements of Section 48-01.2-05 of

the North Dakota Century Code, and

any deficient bid submitted will be

resealed and returned to the bidder

immediately.

All Bids submitted and all Work

completed must be as stipulated in

the Agreement.

The City of Minot reserves the right

to hold all Bids for a period of 30

days after the date of the bid open-

ing, to reject any or all Bids and to

rebid the project until a satisfactory

bid is received, and to waive any in-

formality or irregularity in any Bid.

For all further requirements regard-

ing bid submittal, qualifications, pro-

cedures, and contract award, refer to

the Instructions to Bidders that are

included in the Bidding Documents.

By order of the City Council of the

City of Minot, North Dakota.

Owner: City of Minot

By: Kelly Matalka

Title: City Clerk

Date: February 12, 2021

(February 12-19-26, 2021)

ADVERTISEMENT FOR BIDS

CITY OF MINOT, NORTH DAKOTA

2021 WATER MAIN

REPLACEMENT

BURDICK EXPRESSWAY

CITY PROJECT 4567.1

NOTICE IS HEREBY GIVEN that

the City of Minot (Owner) is re-

questing Bids for the construction of

the following Project: 2021 Water

Main Replacement – Burdick Ex-

pressway.

Bids for the construction of the Pro-

ject will be received at the office of

the City Clerk located at 515 Second

Avenue SW (Second Floor), Minot,

North Dakota 58701, until Tuesday,

March 9, 2021 at 11:00 am local

time. At that time the Bids received

will be publicly opened and read.

The Project includes the following

Work: The project consists of water

main replacement using the follow-

ing methods: open cut, pipe burst-

ing, and directional drilling. The pro-

ject also consists of abandoning and

installing new storm sewer, HMA

patching, concrete sidewalk, curb &

gutter, concrete pavement, and oth-

er related work.

Complete digital project bidding do-

cuments are available at www.

questcdn.com. You may download

the digital plan documents for $40

by inputting eBidDoc #7564461on

the website’s Project Search page.

Please contact QuestCDN.com at

952-233-1632 or info@questcdn.

com for assistance in free member-

ship registration, downloading, and

working with this digital project infor-

mation. Project bidding documents

are also available at the Issuing Of-

fice – City of Minot Engineering

Department 1025 31st St SE and

are available for purchase for $75.

Potential bidders may contact the

Assistant City Engineer at 701-

857-4100 with any questions.

Each bid must be accompanied by a

separate envelope containing the

bid security in a sum equal to five

percent of the full amount of the bid

and must be in the form of a bidder’s

bond. A bidder’s bond must be exe-

cuted by the bidder as principal and

by a surety, conditioned that if the

principal’s bid is accepted and the

contract awarded to the principal,

the principal, within ten days after

notice of the award, shall execute a

contract in accordance with the

terms of the bid and the bid bond,

and any condition of the City of

Minot, as required by law. A counter-

signature of a bid bond is not re-

quired. If the City of Minot elects to

award a contract to the lowest

responsible bidder, and the lowest

responsible bidder does not execute

a contract within the ten days al-

lowed, the bidder’s bond must be

forfeited to the City of Minot and the

project awarded to the next lowest

responsible bidder.

Each bidder must possess a valid

North Dakota contractor’s license for

the full amount of their bid, as re-

quired by Section 43-07-07 of the

North Dakota Century Code. Each

bidder MUST enclose a copy of their

Contractor’s License or Certificate of

Renewal, issued by the North Dako-

ta Secretary of State, in their bid

bond envelope, and each license

must be valid and dated at least 10

days prior to the date set for bid

opening, as required under Section

43-07-12 of the North Dakota Centu-

ry Code.

No bid may be read or considered if

it does not fully comply with the re-

quirements of Section 48-01.2-05 of

the North Dakota Century Code, and

any deficient bid submitted will be

resealed and returned to the bidder

immediately.

All Bids submitted and all Work

completed must be as stipulated in

the Agreement.

The City of Minot reserves the right

to hold all Bids for a period of 30

days after the date of the bid open-

ing, to reject any or all Bids and to

rebid the project until a satisfactory

bid is received, and to waive any in-

formality or irregularity in any Bid.

For all further requirements regard-

ing bid submittal, qualifications, pro-

cedures, and contract award, refer to

the Instructions to Bidders that are

included in the Bidding Documents.

By order of the City Council of the

City of Minot, North Dakota.

Owner: City of Minot

By: Kelly Matalka

Title: City Clerk

Date: February 12, 2021

(February 12-19-26, 2021)

ADVERTISEMENT FOR BIDS

City of Minot, North Dakota

Manhole Rehab – Minot Country

Club City Project #4571

NOTICE IS HEREBY GIVEN that

the City of Minot, North Dakota will

receive sealed Bids for the construc-

tion of Manhole Rehab – Minot

Country Club, at the office of the

City Clerk, 515 Second Avenue SW

(Second Floor), Minot, North Dako-

ta, until 11:00 AM on Thursday,

March 25, 2021 at which time the

bids will be publicly opened and

read in the Council Chambers.

All Bids must be submitted, and all

work shall be done, in full and strict

compliance with:

1. The Plans & Contract Documents

for this project;

2. Any Special Conditions for this

project;

3. The 2021 City of Minot Standard

Specifications and Details

Project bidding documents are avail-

able for examination and/or $100

purchase Monday through Friday

from 8:00 am to 12:00 pm and 1:00

pm to 5:00 pm at the office of

Ackerman-Estvold, 1907 17th Street

SE, Minot ND 58701. Complete di-

gital project bidding documents are

available at www.ackerman-

estvold.com/projects or www.

questcdn.com. You may download

the digital plan documents for $50

by inputting Quest project #7599950

on the website’s Project Search

page. Please contact QuestCDN.

com at 952-233-1632 or info@

questcdn.com for assistance in free

membership registration, download-

ing, and working with this digital pro-

ject information. Potential bidders

may contact Ackerman-Estvold at

(701) 837-8737 with any questions.

A voluntary pre-bid meeting will be

held Tuesday March 16, 2021. The

conference will be hosted on WebEx

and run from 10:00 am CST until

12:00 pm CST. The conference can

be accessed online at the following:

https://ackermanestvold.my.webex.c

om/ackermanestvold.my/j.php?MTI

D=m46ed11dec53745bc05d9a538e

8dd1524 or by phone: 1-408-

418-9388

Meeting Number/Access Code: 182

405 0025

Password: 1234

Any companies/teams/joint ventur-

ers planning to submit a bid are en-

couraged to have at least one

representative present at the pre-bid

conference.

Generally, the Work covered by the

Plans and Specifications for

Manhole Rehab – Minot Country

Club consists of the material, labor,

tools, and equipment required for the

cleaning, repair and lining of 16 –

72-inch dia. And 2 – 48″ dia. sanitary

manholes including removal of

manhole steps and replacement of

castings. Details of the construction

are included in the Drawings, Project

Manual, and the 2021 City of Minot

Standard Specifications and Details.

All Bids are to be submitted on the

basis of cash payment for the Work

and Materials necessary to complete

the project. Each bid must be ac-

companied by a separate envelope

containing the contractor’s license

and bid security. The bid security

must be in a sum equal to five per-

cent of the full amount of the bid and

must be in the form of a bidder’s

bond. A bidder’s bond must be exe-

cuted by the bidder as principal and

by a surety, conditioned that if the

principal’s bid is accepted and the

contract awarded to the principal,

the principal, within ten days after

notice of the award, shall execute a

contract in accordance with the

terms of the bid and the bid bond

and any condition of the governing

body. A countersignature of a bid

bond is not required under this sec-

tion. If a successful bidder does not

execute a contract within the ten

days allowed, the bidder’s bond

must be forfeited to the Owner and

the project awarded to the next

lowest responsible bidder. Bidders

must be licensed for the full amount

of the bid as required by section

43-07-12 of the North Dakota Centu-

ry Code.

No Bid may be read or considered if

it does not fully comply with the re-

quirements of Section 48-01.2-05 of

the North Dakota Century Code.

The Owner reserves the right to hold

all Bids for 30 days, to reject any or

all Bids, to waive any informality or

irregularity in any Bid, to accept the

Bid deemed in the best interest of

the Owner, and to rebid the project

until a satisfactory bid is received.

There shall be endorsed upon the

outside of the envelope containing

the Bid, the following:

1. “City of Minot, Manhole Rehab –

Minot Country Club, Project Number

4571”

2. The name of the person, firm, cor-

poration, or joint venture submitting

the Bid.

3. The Bidder’s Contractor’s License

or Contractor’s License Renewal

Number.

4. Acknowledgement of the Adden-

da, if any.

Any deficient Bid received will be

resealed and returned to the Bidder

immediately.

Work shall not commence until July

20, 2021 and all work shall be sub-

stantially complete by October 15,

2021. All work shall be completed

and ready for final payment in accor-

dance with the General Conditions

by October 30, 2021.

Should the Contractor fail to com-

plete its obligations under the Con-

tract within the time required herein

or within such extra time as may

have been granted by formal exten-

sions of time approved by the Own-

er, there will be deducted from any

amount due to the Contractor the

sum of $750 per day for each and

every calendar day that the comple-

tion of the Work is delayed. The

Contractor and his Surety will be li-

able for any excess. Such payment

will be as and for liquidated dam-

ages and not as a penalty.

By order of the City Council of the

City of Minot, North Dakota.

Dated this 22nd day of February

2021.

Kelly Matalka,

City Clerk

(February 26; March 5-12, 2021)

CALL FOR BIDS

WARD COUNTY

ROAD AND BRIDGE MATERIALS

EQUIPMENT RENTAL AND

SUPPLIES

Notice is hereby given that sealed

bids will be received by the Board of

Ward County Commissioners at the

office of the County Engineer, 200

72nd Street SE, Minot, North Dakota

until 2:00 o’clock p.m. on Monday,

March 15, 2021 for (1) rental of road

construction and maintenance

equipment, including operator on an

hourly basis, (2) the leasing of road

construction and maintenance

equipment without operators on an

hourly, weekly, monthly and annual

basis, (3) the furnishing of various

materials and/or supplies for the

construction or maintenance of

roads and bridges during the 2021

construction season.

Awards of bids shall be made

throughout the year on the basis of

need as dictated by the require-

ments of Ward County Highway

Department both anticipated and

unanticipated.

All bids shall be made on the forms

attached to this bid call and may be

obtained at the office of the County

Highway Department. Any or all bid

categories may be submitted.

If bidding the rental of equipment,

the minimum insurance require-

ments form accompanying the call

for bids must be completed and ap-

plicable certificate(s) of insurance

must accompany the bid.

Ward County reserves the right to

accept or reject any or all bids in the

best interest of the County and to

waive technicalities or irregularities

not deemed material by the County

Commissioners.

Proposals must be mailed or other-

wise deposited with the County

Highway Engineer and shall be

sealed and endorsed listing the

items bid on the front of the en-

velope, for example “culverts”, etc.

(February 26; March 5, 2021)

CALL FOR BIDS

WARD COUNTY WEED CONTROL

BIDS FOR FURNISHING THE

FOLLOWING EQUIPMENT:

One (1) 3/4 Ton 4wd Extended Cab

Pickup

Will be received by the Ward County

Weed Control Board until Monday,

March 15th at 9:00 am, at which

time and place they will be publicly

opened and read.

Bids must be submitted on forms

furnished by the Ward County Weed

Control Board in accordance with

specifications and conditions con-

tained. Forms and specifications

may be obtained from the Ward

County Weed Control Office, located

at 200 72nd St SE, Minot, ND.

Phone (701) 852-1970.

Bids may be mailed to P.O. Box

5005, Minot, ND 58702, or otherwise

deposited with the County Weed

Control Officer and shall be sealed

and endorsed “Bid for (One) 3/4 Ton

4wd Extended Cab Pickup.

The Ward County Weed Control

Board reserves the right to accept or

reject any or all bids and to waive

any formalities or technicalities

which they may deem to be the most

favorable or beneficial to Ward

County.

By order of the Ward County Weed

Control Board dated this 10th day of

February, 2021 at Minot, ND

Signed:

Derrill Fick,

Ward County Weed Control Officer

(February 26; March 5, 2021)

CALL FOR CHEMICAL BIDS

Notice is hereby given that sealed

bids for the following chemicals will

be received by the Ward County

Weed Control Board. Bid forms may

be obtained from the Ward County

Weed Control Office located in the

Ward County Highway Department

building, 200 72nd St SE, Minot,

N.D. phone: 701-852-1970.

The products and quantities are as

follows:

Tordon 22K – 100 gallons or more in

2.5 and one-gallon containers

Imazapic product – 15 gallons or

more in all quantity sizes available

Milestone – 15 gallons or more in all

quantity sizes available

Method – 15 gallons or more in all

quantity sizes available

Glyphosate product – 20 gallons or

more in 2.5-gallon containers

The bids must be received by the

Ward County Weed Control Board

no later than 9:00 a.m., Monday,

March 15, 2021, at which time they

will be opened during the regular

scheduled meeting. Each bid shall

be accompanied by a bidders’ bond

in a sum equal to five percent (5%)

of the full amount of the bid. The

bond shall be attached in a separate

envelope to the front of the envelope

containing the bid.

Mail bids to:

Ward County Weed Control Board

PO Box 5005

Minot, ND 58702

The Ward County Weed Board

reserves the right to accept or reject

any or all bids in the best interest of

the County, and to waive any techni-

calities or irregularities therein. The

Ward County Weed Board reserves

the right to negotiate details or alter-

natives with the successful bidder in

the best interest of the County.

Dated this 10th day of February,

2021 at Minot, North Dakota by ord-

er of the Ward County Weed Control

Board.

Derrill Fick

Ward County Weed Control Officer

(February 26; March 5, 2021)

NOTICE BEFORE

FORECLOSURE

To the Title Owners, Borrowers and

Occupants of the Property:

Elizabeth L. Vanderhorst

2955 North Hill Field Road, Apt 2094

Layton, UT 84041

Matthew Vanderhorst

2955 North Hill Field Road, Apt 2094

Layton, UT 84041

Pursuant to the provisions of the

Federal Fair Debt Collection Prac-

tices Act, you are advised that un-

less you dispute the validity of the

foregoing debt or any portion thereof

within thirty days after receipt of this

letter, we will assume the debt to be

valid. If the debt or any portion

thereof is disputed, we will obtain

verification of the debt and will mail

you a copy of such verification. You

are also advised that upon your re-

quest within the thirty day period, we

will provide you with the name and

address of your original creditor, if

different from the creditor referred to

in this Notice. We are attempting to

collect a debt and any information

obtained will be used for that pur-

pose.

At this time, no attorney with this

firm has personally reviewed the

particular circumstances of your ac-

count. However, if you fail to con-

tact our office, our client may consid-

er additional remedies to recover the

balance due.

The real property that this notice

pertains to is located at 4821 42nd

Street Southeast, Minot, ND 58701,

and more particularly described as:

Lot 2, Faith Hills to the City of Minot,

Ward County, North Dakota.

Notice is hereby given that a certain

mortgage, recorded against the

above described property by Eliza-

beth L. Vanderhorst and Matthew

Vanderhorst, executed and

delivered to U.S. Bank National As-

sociation, dated May 25, 2016,

(“Mortgage”); and given to secure

the payment of $320,000.00, and in-

terest and other fees and costs ac-

cording to the terms and obligations

of a certain promissory note, is in

default. The current Mortgagee of

the Mortgage is U.S. Bank National

Association.

The following is a statement of the

sum due for principal, interest,

taxes, insurance, maintenance, etc.

as of October 26, 2020:

Principal $300,192.41

Interest – Good thru 10/30/2020

$13,595.01

Escrow Advance $2,878.85

Late Charges $120.00

Recoverable Balance $1,305.00

Grand Total $318,091.27

That as of October 26, 2020, the

amount due to cure any default, or

to be due under the terms of the

mortgage, exists in the following

respects:

Monthly Mortgage Payments

$24,514.30

Late Charges $120.00

Corp Advances $1,305.00

Grand Total $25,939.30

In the event that you either payoff or

reinstatement the loan, payment

must be paid by certified funds, and

made payable to U.S. Bank National

Association, and mailed to Halliday,

Watkins & Mann, P.C., at 376 East

400 South, Suite 300, Salt Lake

City, UT 84111. Additionally, you

must pay any additional accrued in-

terest, subsequent payments or late

charges which become due and any

further expenses for preservation of

the property which may be ad-

vanced. Please contact Halliday,

Watkins & Mann, P.C. for the exact

amount due through a certain date.

You have the right, in accordance

with the terms of the mortgage, to

cure the default specified above.

You also have the right in the fore-

closure action to assert that no de-

fault exists or any other defense you

may have to said action.

Notice is further provided that if the

total sums in default, together with

interest accrued thereon at the time

of such payment, accrued payments

then due and expenses advanced,

are not paid within thirty (30) days

from the date of mailing or service of

this Notice, the Mortgagee will deem

the whole sum secured by the Mort-

gage to be due and payable in full

without further notice. Furthermore,

proceedings will be commenced to

foreclosure such Mortgage, and in

the event of Sheriff’s sale as provid-

ed by the laws of the State of North

Dakota, the time for redemption

shall be as provided by law, but not

less than sixty (60) days after the

Sheriff’s Sale.

Date: October 26, 2020

Halliday, Watkins & Mann, P.C.

/s/ Scott S. Skeen

Scott S. Skeen

Attorney for Creditor

376 East 400 South, Suite 300

Salt Lake City, UT 84111

Tel: 801-355-2886

Fax: 801-328-9714

Email: scott@hwmlawfirm.com

HWM: ND10307

(February 19-26; March 5, 2021)

NOTICE BEFORE

FORECLOSURE

To the Title Owners, Borrowers and

Occupants of the Property:

Lee Robles

2370 14th St NW

Minot, ND 58703

Miguel Robles

2370 14th St NW

Minot, ND 58703

Pursuant to the provisions of the

Federal Fair Debt Collection Prac-

tices Act, you are advised that un-

less you dispute the validity of the

foregoing debt or any portion thereof

within thirty days after receipt of this

letter, we will assume the debt to be

valid. If the debt or any portion

thereof is disputed, we will obtain

verification of the debt and will mail

you a copy of such verification. You

are also advised that upon your re-

quest within the thirty day period, we

will provide you with the name and

address of your original creditor, if

different from the creditor referred to

in this Notice. We are attempting to

collect a debt and any information

obtained will be used for that pur-

pose.

At this time, no attorney with this

firm has personally reviewed the

particular circumstances of your ac-

count. However, if you fail to con-

tact our office, our client may consid-

er additional remedies to recover the

balance due.

The real property that this notice

pertains to is located at 2370 14th St

NW, Minot, ND 58703, and more

particularly described as:

Lot 9B, Lakeside 18th Addition to

the City of Minot, Ward County,

North Dakota.

Notice is hereby given that a certain

mortgage, recorded against the

above described property by Miguel

Robles and Lee Robles, executed

and delivered to Mortgage Electronic

Registration Systems, Inc., as Mort-

gagee, as nominee for Bremer

Bank, National Association, its suc-

cessors and assigns, dated No-

vember 3, 2015, (“Mortgage”); and

given to secure the payment of

$254,118.00, and interest and other

fees and costs according to the

terms and obligations of a certain

promissory note, is in default. The

current Mortgagee of the Mortgage

is ServiceMac, LLC.

The following is a statement of the

sum due for principal, interest,

taxes, insurance, maintenance, etc.

as of November 19, 2020:

Principal $230,827.28

Interest good thru 12/03/2020

$5,667.55

Total Fees $20.00

Late Charges $115.68

Grand Total $236,630.51

That as of November 19, 2020, the

amount due to cure any default, or

to be due under the terms of the

mortgage, exists in the following

respects:

Monthly Mortgage Payments

$13,013.55

Late Charge $115.68

Grand Total $13,129.23

In the event that you either payoff or

reinstatement the loan, payment

must be paid by certified funds, and

made payable to ServiceMac, LLC,

and mailed to Halliday, Watkins &

Mann, P.C., at 376 East 400 South,

Suite 300, Salt Lake City, UT 84111.

Additionally, you must pay any addi-

tional accrued interest, subsequent

payments or late charges which be-

come due and any further expenses

for preservation of the property

which may be advanced. Please

contact Halliday, Watkins & Mann,

P.C. for the exact amount due

through a certain date.

You have the right, in accordance

with the terms of the mortgage, to

cure the default specified above.

You also have the right in the fore-

closure action to assert that no de-

fault exists or any other defense you

may have to said action.

Notice is further provided that if the

total sums in default, together with

interest accrued thereon at the time

of such payment, accrued payments

then due and expenses advanced,

are not paid within thirty (30) days

from the date of mailing or service of

this Notice, the Mortgagee will deem

the whole sum secured by the Mort-

gage to be due and payable in full

without further notice. Furthermore,

proceedings will be commenced to

foreclosure such Mortgage, and in

the event of Sheriff’s sale as provid-

ed by the laws of the State of North

Dakota, the time for redemption

shall be as provided by law, but not

less than sixty (60) days after the

Sheriff’s Sale.

Date: November 19, 2020

Halliday, Watkins & Mann, P.C.

/s/ Scott S. Skeen

Scott S. Skeen

Attorney for Creditor

376 East 400 South, Suite 300

Salt Lake City, UT 84111

Tel: 801-355-2886

Fax: 801-328-9714

Email: scott@hwmlawfirm.com

HWM: ND10610

(February 19-26; March 5, 2021)

NOTICE OF REAL ESTATE SALE

CIVIL NUMBER: 51-2019-CV-01671

IN THE STATE OF NORTH

DAKOTA, COUNTY OF WARD

IN THE DISTRICT COURT, NORTH

CENTRAL JUDICIAL DISTRICT

Quicken Loans Inc.

Plaintiff,

v.

Devon Wold a/k/a Devon T. Wold;

Heirs & Devisees of the Estate of

Devon Wold a/k/a Devon T. Wold;

United States of America, acting by

and through the Internal Revenue

Service; any person in possession,

and all persons unknown, claiming

any estate or interest in, or lien or

encumbrance upon, the real estate

described in the complaint,

Defendants.

1. Judgment in the amount of

$378,434.75, having been entered in

favor of Plaintiff and against Defen-

dants, which Judgment was filed

with the Clerk of Courts of Ward

County, North Dakota, on December

31, 2020, for the foreclosure of a

real estate mortgage.

2. Notice is hereby given pursuant to

said Judgment that the real property

described as:

Lot 11, Bel Air 13th Addition to the

City of Minot, Ward County, North

Dakota.

Real Property address:713 27th

Street NW, Minot, ND 58703

The above real property is the sub-

ject of the Mortgage dated June 25,

2018, which Mortgagor, Devon

Wold, executed and delivered to

Mortgage Electronic Registration

Systems Inc., as Mortgagee, as

nominee for Quicken Loans Inc., its

successors and assigns and record-

ed in the office of the Clerk and

Recorder of Ward County, North

Dakota, on June 27, 2018, Instru-

ment Number 3019696, which is

subject to the entered Judgment.

Said Mortgage was assigned to

Plaintiff, its successors or assigns,

by Assignment of Mortgage record-

ed May 6, 2019, Instrument Number

3027721.

3. In order to realize the amount of

$378,434.75, as of December 31,

2020, plus interest accruing

thereafter on said amount at the rate

of 4.99% per year together with the

costs and expenses of sale, the pro-

perty will be sold subject to redemp-

tion as provided by law as one par-

cel of land at public auction, subject

to any lien for unpaid real estate

taxes and assessments of Ward

County, North Dakota, and ease-

ments and restrictions of record, to

the highest bidder for cash under the

direction of the Sheriff of Ward

County, North Dakota, at the main

entrance of the Ward County Court-

house located at 315 SE 3rd Street,

Minot, North Dakota 58701, on

March 17, 2021 (“Sale Date”), at

10:00 AM.

4. If the sale is set aside for reason,

the Purchaser at the sale shall be

entitled only to a return of the depo-

sit paid. The purchaser shall have

no further recourse against the Mort-

gagor, the Mortgagee or the

Mortgagee’s attorney.

DATED this 3rd day of February

2021.

For: Robert Roed

/s/Jamie Williams

Deputy Sheriff of Ward County

Halliday, Watkins & Mann, P.C.

/s/ Scott S. Skeen

Attorneys for Plaintiff

376 East 400 South, Suite 300

Salt Lake City, UT 84111

801-355-2886

Email: scott@hwmlawfirm.com

ND Bar No.: 09334

(February 12-19-26, 2021)

N O T I C E T O B I D D E R S

The City Clerk of the City of Minot

will receive sealed bids at her office

at City Hall until 11:00 a.m. on Tues-

day, March 16, 2021, for furnishing

the City of Minot the following:

Two (2) Tandem Trucks and Ac-

cessories for the Water/Sewer

and Street Departments

Project #4573

Specifications and general instruc-

tions to bidders are available in the

Public Works Office at 1025 31st St.

SE. or on the City of Minot webpage

www.minotnd.org under City Clerk

department.

The bid envelope shall be plainly

marked:

“Bid for Two (2) Tandem Trucks

and Accessories”

Project #4573

The City Council of the City of Minot

reserves the right to reject any or all

bids and to award the contract as it

deems to be in the best interest of

the City of Minot. Each bid must be

accompanied by a bidder’s bond, a

certified check, or a cashier’s check

in the amount of five percent (5%) of

the bid and must be in a separate

envelope marked “bid bond” and at-

tached to the outsideof the bid.

Bidders are invited to be present at

the City Clerk office, 515 2nd Ave.

SW for the opening of bids.

Kelly Matalka

City Clerk

(February 26; March 5, 2021)

REQUEST FOR QUALIFICATIONS

(RFQ) FOR PROFESSIONAL

AIRPORT PLANNING AND EN-

VIRONMENTAL

CONSULTANT SERVICES

2021-2026

General

The Minot International Airport (Air-

port), located in the City of Minot,

Ward County, North Dakota, is re-

questing Statements of Qualifica-

tions for Professional Airport Plan-

ning and Environmental Consultant

Services at the Minot International

Airport for projects in the Airport

Capital Improvement Plan (CIP),

and others, as may be necessary

over a five-year term (2021-2026).

FAA Advisory Circular (AC)

150/5100-14E, Architectural, En-

gineering, and Planning Consulting

Services for Airport Grant Projects,

should be referenced. This AC pro-

vides guidance for airport sponsors

in the selection and engagement of

consultants. It also discusses ser-

vices that normally would be includ-

ed in an airport grant project, types

of contracts for these services, con-

tract format and provisions, and

guidelines for determining the rea-

sonableness of consultant fees.

Do not include estimated fees in the

RFQ submittal.

Rejection of Statements

No proposals shall be accepted

from, or contracts awarded to, any

person, firm, or corporation that is in

arrears to the Airport or City of

Minot, upon debt or contract or that

is a defaulter, as surety or other-

wise, upon any obligation to the Air-

port. Prospective firms may be re-

quired to submit satisfactory evi-

dence that they have the financial

resources to perform and complete

the work outlined in this RFQ.

Debarment

By submitting this proposal, the

prospective consultant certifies that

neither the company nor its princi-

pals are presently debarred,

suspended, in the process of de-

barment, declared ineligible, or

voluntarily excluded from participa-

tion in this transaction by any federal

department or agency.

Contract

The top-ranked firm will be invited to

negotiate a contract with the Airport.

A detailed scope of work will be

developed and agreed to by the

selected consultant and the Airport.

This detailed scope of work and the

associated fees will be part of the

contract.

The consultant shall not discriminate

on the basis of race, color, national

origin, or sex in the performance of

the contract. DOT 49 CFR Par 26

Disadvantaged Business Enterprise

(DBE) utilization is strongly en-

couraged. The City of Minot/Minot

International Airport is an Equal Op-

portunity Employer.

Submission of Qualifications

Statement and Contact Person

Six (6) paper copies and one (1)

electronic version of the Qualifica-

tions Statement must be submitted

no later than 4:30 p.m. on March

26th, 2021 to:

Deanna Stoddard

Operations Manager

Minot International Airport

305 Airport Road, Suite 216

Minot, ND 58703

701-857-4725

All questions regarding this RFQ

should be directed in writing, no later

than March 12th, 2021 to:

Deanna Stoddard

Operations Manager

Minot International Airport

305 Airport Road, Suite 216

Minot, ND 58703

701-857-4725

All requests for changes or revisions

to this RFQ will be through written

addendum. Additional information

can be found on the City website at

minotnd.org/bids.

(February 26; March 5-12, 2021)

REQUEST FOR QUALIFICATIONS

(RFQ) FOR PROFESSIONAL

AIRPORT ARCHITECTURAL AND

ENGINEERING

CONSULTANT SERVICES

2021-2026

General

The Minot International Airport (Air-

port), located in the City of Minot,

Ward County, North Dakota, is re-

questing Statements of Qualifica-

tions for Professional Airport Archi-

tectural and Engineering Consultant

Services at the Minot International

Airport for projects in the Airport

Capital Improvement Plan (CIP),

and others, as may be necessary

over a five-year term (2021-2026).

FAA Advisory Circular (AC)

150/5100-14E, Architectural, En-

gineering, and Planning Consulting

Services for Airport Grant Projects,

should be referenced. This AC pro-

vides guidance for airport sponsors

in the selection and engagement of

consultants. It also discusses ser-

vices that normally would be includ-

ed in an airport grant project, types

of contracts for these services, con-

tract format and provisions, and

guidelines for determining the rea-

sonableness of consultant fees.

Do not include estimated fees in the

RFQ submittal.

Selection of the Consultant

It is the intent of the Airport to form a

committee to review the Statements

of Qualifications submitted and rank

the qualified firm(s). Members of the

selection committee may consist of

Airport Staff, City Staff to include

Department Heads, City Council

Members, and others.

The Airport may choose to interview

a shortlist of consultants before

making the selection. The shortlisted

consultants shall be notified at least

7 days prior to the interview date.

All unsuccessful firms will be notified

in writing no later than 10 days after

selection of the Consultant and may

contact the Airport for debriefing.

The Airport reserves the right to re-

ject any and all submissions to this

RFQ, request clarification, or waive

informalities/technicalities, if it is

deemed in the best interest of the

Airport. The Airport assumes no

responsibility for costs incurred in

responding to this RFQ. All submit-

tals to this RFQ become property of

the Airport.

In accordance with FAA selection

procedures, all selections will be

qualification based. No overhead

rate, fees, or any cost information

should be identified as part of this

submission.

Rejection of Statements

No proposals shall be accepted

from, or contracts awarded to, any

person, firm, or corporation that is in

arrears to the Airport or City of

Minot, upon debt or contract or that

is a defaulter, as surety or other-

wise, upon any obligation to the Air-

port. Prospective firms may be re-

quired to submit satisfactory evi-

dence that they have the financial

resources to perform and complete

the work outlined in this RFQ.

Debarment

By submitting this proposal, the

prospective consultant certifies that

neither the company nor its princi-

pals are presently debarred,

suspended, in the process of debar-

ment, declared ineligible, or volun-

tarily excluded from participation in

this transaction by any federal

department or agency.

Contract

The top-ranked firm will be invited to

negotiate a contract with the Airport.

A detailed scope of work will be

developed and agreed to by the

selected consultant and the Airport.

This detailed scope of work and the

associated fees will be part of the

contract.

The consultant shall not discriminate

on the basis of race, color, national

origin, or sex in the performance of

the contract. DOT 49 CFR Par 26

Disadvantaged Business Enterprise

(DBE) utilization is strongly en-

couraged. The City of Minot/Minot

International Airport is an Equal Op-

portunity Employer.

Submission of Qualifications

Statement and Contact Person

Six (6) paper copies and one (1)

electronic version of the Qualifica-

tions Statement must be submitted

no later than 4:30 p.m. on March

26th, 2021 to:

Deanna Stoddard

Operations Manager

Minot International Airport

305 Airport Road, Suite 216

Minot, ND 58703

701-857-4725

All questions regarding this RFQ

should be directed in writing, no later

than March 12th, 2021 to:

Deanna Stoddard

Operations Manager

Minot International Airport

305 Airport Road, Suite 216

Minot, ND 58703

701-857-4725

All requests for changes or revisions

to this RFQ will be through written

addendum. Additional information

can be found on the City website at

minotnd.org/bids.

(February 26; March 5-12, 2021)

REQUEST FOR QUALIFICATIONS

16TH ST SW AND 37TH AVE SW

MILL & OVERLAY

CITY PROJECT 4592

The City of Minot, North Dakota, is

requesting “Statements of Qualifica-

tions” from engineering consulting

firms to provide Consultant En-

gineering services for the mill and

overlay of 16th St SW from 24th Ave

SW to 37th Ave SW and mill and

overlay of 37th Ave SW from 16th St

SW to Broadway. Interested firms

must submit five (5) bound copies

and one digital copy of their qualifi-

cations by 4:00 pm, March 5, 2021

to:

City of Minot Engineering Depart-

ment

1025 31st Street SE

Minot, ND 58701

Attn: Lance Meyer, City Engineer

Proposals should be marked:

“Qualifications Submittal for 16th St

SW and 37th Ave SW Mill & Overlay

City Project 4592”

Provide the City of Minot with prel-

iminary, design, and construction

engineering services for the mill and

overlay of 16th St SW from 24th Ave

SW to 37th Ave SW and Mill and

Overlay of 37th Ave SW from 16th

St SW to Broadway. This project is

funded through the NDDOT Urban

Roads program and other local fund-

ing sources. Consultant must have

the ability and experience to design

and inspect an arterial roadway mill

and overlay project that will include

NEPA document, asphalt mill and

overlay, LED street lighting conver-

sion, and ADA ramp upgrades. Con-

sultant must also provide project

management and construction en-

gineering services.

Detailed information for those in-

terested in submitting proposals is

available in the City Engineering

Department Office, City of Minot

Public Works Building, 1025 31st

Street SE, Minot, ND, Monday

through Friday between the hours of

8:00 a.m. and 4:30 p.m. or tele-

phone at (701) 857-4100. Proposals

must be delivered to the City En-

gineer by 4:00 pm on March 5,

2021. The City of Minot reserves the

right to reject any and all proposals.

(February 12-19-26, 2021)

SUMMONS

Case No. 51-2021-DM-00072

In the Interest of J.D.D. and J.G.G.,

Minor Children.

STATE OF NORTH DAKOTA,

COUNTY OF WARD, IN DISTRICT

COURT, NORTH CENTRAL

JUDICIAL DISTRICT

State of North Dakota,

Plaintiff,

v.

Anna Marie Day,

Defendant.

The State of North Dakota to Anna

Marie Day:

You are summoned and required to

defend against the Complaint by

serving an Answer, which is a writ-

ten response, on the State of North

Dakota within 21 days after service

of this Summons and by also filing

that Answer with the court. If you do

not serve and file an Answer, the

court can grant the requests made in

the Complaint by ordering that a de-

fault judgment be entered against

you.

Dated this 1st day of August, 2020.

/s/ Tina M. Heinrich

Tina M. Heinrich

Special Assistant Attorney General

Bar I.D. Number: 04088

1015 S. Broadway Suite 18,

Minot, ND 58701

1-800-231-4255; minotcse@nd.gov

Attorney for Child Support

(February 12-19-26, 2021)

SUMMONS

Case No. 51-2021-DM-00065

STATE OF NORTH DAKOTA,

COUNTY OF WARD, IN DISTRICT

COURT, NORTH CENTRAL

JUDICIAL DISTRICT

State of North Dakota, and

Bonita Shyer Little Dog,

Plaintiffs,

v.

Harlan Lee Ross,

Defendant.

The State of North Dakota to Harlan

Lee Ross:

You are summoned and required to

defend against the Complaint by

serving an Answer, which is a writ-

ten response, on the State of North

Dakota and Bonita Shyer Little Dog

within 21 days after service of this

Summons and by also filing that

Answer with the court. If you do not

serve and file an Answer, the court

can grant the requests made in the

Complaint by ordering that a default

judgment be entered against you.

Dated this 3rd day of February,

2021.

/s/ Tina M. Heinrich

Tina M. Heinrich

Special Assistant Attorney General

Bar I.D. Number: 04088

1015 S. Broadway Suite 18,

Minot, ND 58701

1-800-231-4255; minotcse@nd.gov

Attorney for Child Support

(February 12-19-26, 2021)

SUMMONS

Case No. 51-2021-DM-00070

STATE OF NORTH DAKOTA,

COUNTY OF WARD, IN DISTRICT

COURT, NORTH CENTRAL

JUDICIAL DISTRICT

State of North Dakota, and

Cyngay Emberly Merjil,

Plaintiffs,

v.

David Riley III,

Defendant.

The State of North Dakota to David

Riley III:

You are summoned and required to

defend against the Complaint by

serving an Answer, which is a writ-

ten response, on the State of North

Dakota and Cyngay Emberly Merjil

within 21 days after service of this

Summons and by also filing that

Answer with the court. If you do not

serve and file an Answer, the court

can grant the requests made in the

Complaint by ordering that a default

judgment be entered against you.

Dated this 10th day of December,

2020.

/s/ Tina M. Heinrich

Tina M. Heinrich

Special Assistant Attorney General

Bar I.D. Number: 04088

1015 S. Broadway Suite 18,

Minot, ND 58701

1-800-231-4255; minotcse@nd.gov

Attorney for Child Support

(February 12-19-26, 2021)

SUMMONS

Case No. 51-2021-DM-00069

STATE OF NORTH DAKOTA,

COUNTY OF WARD, IN DISTRICT

COURT, NORTH CENTRAL

JUDICIAL DISTRICT

State of North Dakota, and

Ebony Joy Falode,

Plaintiffs,

v.

Edmond James Smith,

Defendant.

The State of North Dakota to Ed-

mond James Smith:

You are summoned and required to

defend against the Complaint by

serving an Answer, which is a writ-

ten response, on the State of North

Dakota and Ebony Joy Falode within

21 days after service of this Sum-

mons and by also filing that Answer

with the court. If you do not serve

and file an Answer, the court can

grant the requests made in the Com-

plaint by ordering that a default judg-

ment be entered against you.

Dated this 18th day of May, 2020.

/s/ Tina M. Heinrich

Tina M. Heinrich

Special Assistant Attorney General

Bar I.D. Number: 04088

1015 S. Broadway Suite 18,

Minot, ND 58701

1-800-231-4255; minotcse@nd.gov

Attorney for Child Support

(February 12-19-26, 2021)

SUMMONS

Case No. 51-2021-DM-00071

STATE OF NORTH DAKOTA,

COUNTY OF WARD, IN DISTRICT

COURT, NORTH CENTRAL

JUDICIAL DISTRICT

State of North Dakota, and

Rikki Leigh Ritz,

Plaintiffs,

v.

Anthony Andrade,

Defendant.

The State of North Dakota to Antho-

ny Andrade:

You are summoned and required to

defend against the Complaint by

serving an Answer, which is a writ-

ten response, on the State of North

Dakota and Rikki Leigh Ritz within

21 days after service of this Sum-

mons and by also filing that Answer

with the court. If you do not serve

and file an Answer, the court can

grant the requests made in the Com-

plaint by ordering that a default judg-

ment be entered against you.

Dated this 1st day of July, 2020.

/s/ Tina M. Heinrich

Tina M. Heinrich

Special Assistant Attorney General

Bar I.D. Number: 04088

1015 S. Broadway Suite 18,

Minot, ND 58701

1-800-231-4255; minotcse@nd.gov

Attorney for Child Support

(February 12-19-26, 2021)

SUMMONS

Case No. 51-2021-DM-00067

STATE OF NORTH DAKOTA,

COUNTY OF WARD, IN DISTRICT

COURT, NORTH CENTRAL

JUDICIAL DISTRICT

State of North Dakota, and

Barbara Serine Haga,

Plaintiffs,

v.

Peter Paul Beatty,

Defendant.

The State of North Dakota to Peter

Paul Beatty:

You are summoned and required to

defend against the Complaint by

serving an Answer, which is a writ-

ten response, on the State of North

Dakota and Barbara Serine Haga

within 21 days after service of this

Summons and by also filing that

Answer with the court. If you do not

serve and file an Answer, the court

can grant the requests made in the

Complaint by ordering that a default

judgment be entered against you.

Dated this 10th day of November,

2020.

/s/ Stephen Williamson

Stephen Williamson

Special Assistant Attorney General

Bar I.D. Number: 09282

1015 S. Broadway Suite 18,

Minot, ND 58701

1-800-231-4255; minotcse@nd.gov

Attorney for Child Support

(February 12-19-26, 2021)

SUMMONS

Civil No. 51-2021-CV-00273

STATE OF NORTH DAKOTA,

COUNTY OF WARD, IN DISTRICT

COURT, NORTH CENTRAL

JUDICIAL DISTRICT

ProCollect Services, LLC,

Plaintiff,

vs.

Savannah and Matthew Fixsal,

Defendant.

THE STATE OF NORTH DAKOTA

TO THE ABOVE-NAMED DEFEN-

DANT:

YOU ARE HEREBY SUMMONED

and required to appear and defend

against the Complaint in this action,

which is herewith served upon you,

by serving on the undersigned an

Answer or other proper response

within twenty-one days after service

of this Summons upon you, ex-

clusive of the day of service. If you

fail to do so, judgment by default will

be taken against you for the relief

demanded in the complaint.

Dated February 22, 2021.

/s/Christopher A. Carlson

Chistopher A. Carlson (ID #03378)

PO Box 1097

Bismarck, North Dakota 58502-1097

701-258-4800

carlsonlaw@qwestoffice.net

Attorney for the Plaintiff

(February 26; March 5-12, 2021)

SUMMONS

Civil No. 51-2021-CV-00274

STATE OF NORTH DAKOTA,

COUNTY OF WARD, IN DISTRICT

COURT, NORTH CENTRAL

JUDICIAL DISTRICT

ProCollect Services, LLC,

Plaintiff,

vs.

Matthew Fixsal,

Defendant.

THE STATE OF NORTH DAKOTA

TO THE ABOVE-NAMED DEFEN-

DANT:

YOU ARE HEREBY SUMMONED

and required to appear and defend

against the Complaint in this action,

which is herewith served upon you,

by serving on the undersigned an

Answer or other proper response

within twenty-one days after service

of this Summons upon you, ex-

clusive of the day of service. If you

fail to do so, judgment by default will

be taken against you for the relief

demanded in the complaint.

Dated February 22, 2021.

/s/Christopher A. Carlson

Chistopher A. Carlson (ID #03378)

PO Box 1097

Bismarck, North Dakota 58502-1097

701-258-4800

carlsonlaw@qwestoffice.net

Attorney for the Plaintiff

(February 26; March 5-12, 2021)

SUMMONS

Civil No. 51-2021-CV-00276

STATE OF NORTH DAKOTA,

COUNTY OF WARD, IN DISTRICT

COURT, NORTH CENTRAL

JUDICIAL DISTRICT

ProCollect Services, LLC,

Plaintiff,

vs.

Savannah Fixsal,

Defendant.

THE STATE OF NORTH DAKOTA

TO THE ABOVE-NAMED DEFEN-

DANT:

YOU ARE HEREBY SUMMONED

and required to appear and defend

against the Complaint in this action,

which is herewith served upon you,

by serving on the undersigned an

Answer or other proper response

within twenty-one days after service

of this Summons upon you, ex-

clusive of the day of service. If you

fail to do so, judgment by default will

be taken against you for the relief

demanded in the complaint.

Dated February 23, 2021.

/s/Christopher A. Carlson

Chistopher A. Carlson (ID #03378)

PO Box 1097

Bismarck, North Dakota 58502-1097

701-258-4800

carlsonlaw@qwestoffice.net

Attorney for the Plaintiff

(February 26; March 5-12, 2021)

SUMMONS

CIVIL NUMBER: 51-2021-CV-00038

IN THE STATE OF NORTH

DAKOTA, COUNTY OF WARD

IN THE DISTRICT COURT, NORTH

CENTRAL JUDICIAL DISTRICT

Lakeview Loan Servicing, LLC,

Plaintiff,

v.

Jeffrey Leedy; Krista Leedy; Jay

Ragbardi; Mary Burney; any person

in possession, and all persons unk-

nown, claiming any estate or interest

in, or lien or encumbrance upon, the

real estate described in the com-

plaint,

Defendants.

1. To the above-mentioned Defen-

dants including all persons unk-

nown, claiming any estate or interest

in, or lien or encumbrance upon, the

real estate described below and in

the complaint.

2. You are hereby summoned and

required to appear and defend

against the Complaint in this action,

which is herewith served upon you,

by serving upon the undersigned a

copy of an Answer or other proper

response within twenty-one (21)

days after the service of this Sum-

mons upon you, exclusive of the day

of service.

3. If you fail to do so, Judgment by

default will be taken against you for

the relief demanded in the Com-

plaint.

4. This Summons and accompany-

ing Complaint will be filed with the

Clerk of the Court named above.

5. This action relates to the foreclo-

sure of a mortgage upon the follow-

ing described real property in the

County of Ward, State of North

Dakota:

All of the following real property lying

and being in the County of Ward,

State of North Dakota, and

described as follows, to-wit

Lot 35, Block 3, Silver Springs Addi-

tion to the City of Surrey, Ward

County, North Dakota.

Property Address: 22 Cambridge

Cove, Surrey, ND 58785

6. The Plaintiff is not seeking a per-

sonal judgment against the

above-named Defendants.

Date: December 23, 2020

/s/ Scott S. Skeen

Scott S. Skeen

376 East 400 South, Suite 300

Salt Lake City, UT 84111

Tel: 801-355-2886

Fax: 801-328-9714

Email: scott@hwmlawfirm.com

Bar Number: 08371

HWM: ND10094

(February 19-26; March 5, 2021)