ADVERTISEMENT FOR BID

Children’s Museum of Minot, Inc –

New Magic City Discovery Center –

BP #1

Kraus-Anderson Construction Com-

pany is presently soliciting competi-

tive Lump Sum Bids for the

Children’s Museum of Minot, Inc. –

New Magic City Discovery Center,

Minot, ND – BP #1 (All Work).

Sealed bids will be received until

2:00 PM Central time on Tuesday,

March 9th, 2021 at the address not-

ed below. Bids received after this

time will not be considered. Bids will

be publicly opened at 3:00 PM Cen-

tral time on Tuesday, March 9th,

2021 and publicly read aloud at the

following location: Minot Park Com-

munity Room located in the Audito-

rium at 420 3rd Ave SW, Minot, ND

58701 and via Zoom.

Kraus-Anderson Construction Com-

pany is the only authorized agent to

receive bids.

Bids may be mailed or hand

delivered to:

Magic City Discovery Center

c/o Kraus-Anderson Construction

Company

Attn: Curt Janssen

615 South Broadway

Suite L2

Minot, ND 58701

The complete bid form shall be

without alterations, additions, or

erasures. All bids shall be on a lump

sum basis. No bid may be withdrawn

for a period of 60 days after bid re-

ceipt without consent of the Owner.

Kraus-Anderson Construction Com-

pany reserves the right to reject any

or all bids and to waive any irregu-

larities in bids.

Direct all communications regarding

this Project to the office of the Con-

struction Manager: Curt Janssen

(curt.janssen@krausanderson.com)

(701) 989-7150.

Procurement of Documents for

bidders on prime contracts: Obtain

the bidding documents, including the

Bid Form, Drawings and Specifica-

tions, via iSqft.com. Plans can be

purchased by contacting Franz

Reprographics at (701) 258-5060. In

order to receive all addenda, please

request to be added to the distribu-

tion list by emailing linda.

house@krausanderson.com. Bid

Documents are also available thru

many of the regional builders’ ex-

changes.

(February 10-17-24, 2021)

CALL FOR BIDS

Two (2) 44 Passenger Activity

Buses

Lewis and Clark School District

NOTICE IS HEREBY GIVEN that

the Lewis and Clark School District

#161 of Ward County, North Dakota

will receive sealed bids at the school

office, 401 4th Ave. NE, Berthold,

ND 58718 until 4:00 p.m., Monday,

March 8, 2021 for two (2) 44

passenger activity buses. Specs are

available upon request.

The bids will be opened and read at

7:00 p.m. on Monday, March 8,

2021 at the above address. No bids

will be received after the scheduled

closing time for the receipt of bids.

The school board reserves the right

to reject any and all bids, or to waive

informalities, irregularities, or defects

in any proposal, should it deem it to

be in the best interest of the Lewis

and Clark School District to do so. If

you have further questions, please

call Marc Ritteman, Superintendent

at 701-453-3484 or email marc.

ritteman1@k12.nd.us. Alternate bids

based on optional accessories will

be considered and possibly accept-

ed.

Trade-ins: Two 44 passenger, 2011

Blue Bird All American Buses

(February 24, 2021)

Minot Park District Call for Bids

Bid – Forestry One Ton Truck

Notice is hereby given that sealed

bids will be received by Jarrod A. Ol-

son, Director of Operations, at the

Minot Park District Office, 420 3rd

Ave SW, PO Box 538, Minot, ND

58702, until 2pm March 11th, 2021

at which times bids will be opened

and read for furnishing to the Board

of Park Commissioners.

Envelope containing the bid shall be

plainly marked on the outside – “Bid

– One Ton Truck”

Copies of Specifications may be ob-

tained from the Park District Office

at above address or at www.

minotparks.com

The Board of Park Commissioners

reserves the right to reject any and

all bids, waive any irregularities

therein, and to award the contract as

they deem to be the best interest of

the Minot Park District.

Bidders are invited to be present at

the above-mentioned time and place

for the opening of the bids. Bids will

be presented to the Minot Park

Board on March 16thth at 6:30pm at

the Minot Park Board Meeting.

Technical Questions Contact –

Troy Regstad – Forestry Technician

troyregstad@gmail.com or 701-818-

7258

*Delivery will be coordinated with

Minot Park District Forestry &

Maintenance Department

Jarrod A. Olson

Director of Operations

Minot Park District

jarrod@minotparks.com

(701) 857-4136 Office

(701) 833-7021 Cell

(February 24; March 3-10, 2021)

NOTICE OF ANNUAL MEETING

The Plaza Fire Protection District

Annual Meeting will be held, Tues-

day, March 9th, 2021 at 5:00 p.m. at

Backroads Bar & Grill.

Roger Fyllesvold, Secretary

(February 24; March 3, 2021)

NOTICE OF EXECUTION SALE

Civil No. 51-2020-CV-00394

IN DISTRICT COURT, WARD

COUNTY, NORTH DAKOTA

The Industrial Commission of North

Dakota, acting as the North Dakota

Housing Finance Agency,

Plaintiff,

vs.

Amanda N. Daggett fka Amanda N.

Combs; Benjamin Daggett; and any

other person in possession;

Defendants.

1. NOTICE IS HEREBY GIVEN, that

by virtue of a judgment and decree

of foreclosure rendered and given in

the District Court in and for the

County of Ward, North Dakota,

North Central Judicial District, en-

tered and docketed in the Office of

the Clerk of said Court on January

19, 2021, in an action wherein The

Industrial Commission of North

Dakota acting as the North Dakota

Housing Finance Agency, was

Plaintiff and Amanda N. Daggett fka

Amanda N. Combs; Benjamin Dag-

gett and any other person in posses-

sion; were the Defendants; on which

day it was adjudged that there was

due and owing the Plaintiff from the

Defendant, Amanda N. Daggett fka

Amanda N. Combs; together with

costs and disbursements of said ac-

tion, the sum of $156,518.01, and by

virtue of a Special Execution issued

to me by the Clerk of said Court, I

will sell the real property described

in said judgment and hereafter

described to the highest bidder for

cash at public auction at the front

door of the Courthouse in the City of

Minot, County of Ward, North Dako-

ta, on March 17, 2021, at the hour of

10:00 a.m. of that day to satisfy the

amount due with accrued costs and

interest at the date of sale, or so

much thereof as the proceeds of

said sale applicable thereto will

satisfy.

2. The premises to be sold as afore-

said are situated in the County of

Ward, State of North Dakota, and

are more particularly described as

follows:

N1/2E1/2 of Lot 2, Prospect Heights

Addition to the City of Minot, Ward

County, North Dakota

Parcel ID Number: MI252970000024

(Street Address: 1410 2nd St. SE,

Minot, ND 58701)

Dated at Minot, North Dakota, this

4th day of February, 2021.

Robert Roed

Sheriff of Ward County,

North Dakota

/s/ Jamie Williams

Lieutenant Jamie Williams

Dean A. Rindy ND ID# 04206

Special Assistant Attorney General

Attorney for Plaintiff

720 Main Avenue

Fargo, ND 58103

701.235.8000

dean@okeeffeattorneys.com

(February 10-17-24, 2021)

NOTICE OF SALE

Civil No. 51-2018-CV-685

Notice is hereby given that by virtue

of an Order for Foreclosure and

Sheriff’s sale by the District Court of

the North Central Judicial District in

and for the County of Ward and

State of North Dakota, and entered

and docketed in the Office of the

Clerk of said Court on October 14,

2020, in an action wherein Gamma

Real Estate Capital LLC was Plain-

tiff and Nathan Smith Holdings, LLC,

Nathan Smith, and 55th, Holdings,

LLC; and any person in possession

were Defendants, in favor of Plaintiff

and against the Defendants for the

sum of Eighteen Million, Nine Hun-

dred Ninety Six Thousand, One

Hundred Twenty Nine dollars and

81/100 ($18,996,129.81), which ord-

er, among other things, direct the

sale by me of the real property

hereinafter described, to satisfy the

amount of said judgment, with in-

terest thereon and the costs and ex-

penses of such sale, or so much

thereof as the proceeds of said sale

will satisfy; and by virtue of a writ is-

sued to me out of the office of the

Clerk of said Court, I, Robert Roed,

Sheriff of Ward County, North Dako-

ta, will sell the property described in

the Judgment to the highest bidder

for cash at public auction at the front

door of the Courthouse in the City of

Minot in the County of Ward and

State of North Dakota, on March 17,

2021, at the hour of 10:00 A.M.

(Central Time), to satisfy the amount

due, with interest thereon, and the

costs and expenses of such sale, or

so much thereof as the proceeds of

such sale will satisfy. The property

to be sold is situated in the County

of Ward and State of North Dakota,

and described on Exhibit A:

IN TESTIMONY WHEREOF, I have

hereunto set my hand and seal this

2nd day of February 2021.

For: Robert Roed, Sheriff of Ward

County, North Dakota

/s/Jamie Williams

Jamie Williams, Deputy

STATE OF NORTH DAKOTA)

)ss.

County of Ward)

On this 2nd day of February, 2021,

before me, a Notary Public in and for

said County and State, personally

appeared Jamie Williams, known to

me to be the person who is

described in, and whose name is

subscribed to this instrument.

Kimberly A. Ohlhauser,

Notary Public

Ward County, North Dakota

My Commission expires: 6-14-2022

Exhibit A-1

LEGAL DESCRIPTION: Lots 16A,

16B, 17A, 17B, 18B, and 19A, Block

1; Lots 10A, 10B, 11A, and 11B,

Block 2; All in 55th Crossing 3rd Ad-

dition to the City of Minot, Ward

County, North Dakota,

AND

Lots 3A, 3B, 4A, 4B, 5A, 5B, 6A, 6B,

7A, and 7B, Block 4; Lots 1B and

2B, Block 5; Lots 13A and 13B,

Block 6; Lots 8A, 8B, 9A, 9B, 10A,

10B, 11A and 11B, Block 7; All in

55th Crossing 5th Addition to the

City of Minot, Ward County, North

Dakota.

EXHIBIT A-2

Lots 1A, 1B, 2A, 2B, 3A, 3B, 4A, 4B,

5A, 5B, 6A, 6B, 7A, 7B, 8A, 8B, 9A,

9B, 10A, 10B, 11A, 11B, BLOCK 7;

LOTS 1A, 1B, 2A, 2B, 3A, 3B, 4A,

4B, 5A, 5B, 6A, 6B, 7A, 7B, 8A, 8B,

9A, 9B, 10A, 10B, BLOCK 8; LOTS

1, 2, 3, 4, 5, 6, 7, 8, 9, 10, 11, 12,

BLOCK 11; LOTS 1, 2, 3, 4, 5, 6, 7,

8, 9, 10, 11, 12, BLOCK 12; LOTS1,

2, 3, 4, 5, 6, 7, 8, 9, 10, BLOCK 13;

LOTS 1, 2, 3, 4, 5, 6, 7, 8, 9, 10, 11,

12, 13, BLOCK 14; LOTS 1, 2, 3, 4,

5, 6, 7, 8, 9, 10, 11, 12, 13, 14, 15,

16, BLOCK 15; LOTS 1, 2, 3, 4, 5, 6,

7, 8, 9, 10, BLOCK 16; LOTS 1, 2, 3,

4, 5, 6, 7, 8, 9, 10, 11, 12, BLOCK

17; LOTS 1, 2, 3, 4, 5, 6, 7, 8, 9, 10,

11, 12, BLOCK 18; LOTS 1, 2, 3, 4,

5, 6, 7, 8, 9, 10, 11, 12, BLOCK 19;

LOTS 1, 2, 3, 4, 5, 6, 7, 8, 9, 10, 11,

12, BLOCK 20; LOTS 1, 2, 3, 4, 5, 6,

7, 8, 9, 10, BLOCK 21; LOTS 1A,

1B, 2A, 2B, 3A, 3B, 4A, 4B, 5A, 5B,

6A, 6B, 7A, 7B, 8A, 8B, 9A, 9B,

10A, 10B, 11A, 11B, 12A, 12B, 13A,

13B, 14A, 14B, 15A, 15B, 16A, 16B,

17A, 17B, 18A, 18B, 19A, 19B,

BLOCK 22; LOTS 14, 15, 16, 17, 18,

19, 20, 21, 22, 23, BLOCK 23; LOTS

1, 2, 3, 4, 5, 6, 7, 8, 9, 10, 11, 12,

13, 14, 15, BLOCK 24; All in 55th

Crossing Addition to the City of

Minot, Ward County, North Dakota

AND

Blocks 2, 5, 6, 7, 10, All in 55th

Crossing 2nd Addition to the City of

Minot, Ward County, North Dakota

AND

Lots 4A, 4B, 5A, 5B, 6A, 6B, 7A, 7B,

8A, 8B, 9A, 9B, 10A, 10B, 11A, 11B,

12A, 12B, 13A, 13B, 14A, 14B, 15A,

15B, BLOCK 1; LOTS 5A, 5B, 6A,

6B, 7A, 7B, 8A, 8B, 9A, 9B, BLOCK

2; All in 55th Crossing 3rd Addition

to the City of Minot, Ward County,

North Dakota

AND

LOTS 1 AND 2, BLOCK 1; LOTS

1B, 2A, 2B, 3A, 3B, 4A, 4B, 5A, 5B,

6A, 6B, 7A, 7B, BLOCK 2; LOTS 1,

2, 3, BLOCK 3; LOTS 1, 2, 3, 4, 5,

6, 7, 8, 9, 10, 11, 12, 13, 14, 15, 16,

17, 18, 19, 20, 21, BLOCK 4; LOT 1,

BLOCK 5; LOTS 1, 3, BLOCK 6;

LOTS 1, 2, 3, 4, BLOCK 7; LOTS

1A, 1B, 2A, 2B, 3A, 3B, 4A, 4B, 5A,

5B, 6A, 6B, 7A, 7B, 8A, 8B, 9A, 9B,

10A, 10B, 11A, 11B, 12A, 12B, 13A,

13B, 14A, 14B, BLOCK 8; LOTS 1,

2, 3, 4, 5, 6, 7, 8, 9, 10, 11, 12, 13,

14, BLOCK 9; LOTS 1, 2, 3, 4, 5, 6,

7, 8, 9, 10, 11, 12, 13, 14, BLOCK

10; LOTS 1A, 1B, 2A, 2B, 3A, 3B,

4A, 4B, 5A, 5B, 6A, 6B, 7A, 7B, 8A,

8B, 9A, 9B, 10A, 10B, 11A, 11B,

12A, 12B, 13A, 13B, 14A, 14B,

BLOCK 11; LOTS 1, 2, 3, 4, 5, 6, 7,

8, 9, BLOCK 12; LOTS 1, 2, 3, 4, 5,

6, 7, 8, BLOCK 13; LOTS 1, 2, 3, 4,

5, 6, BLOCK 14; All in 55th Cross-

ing 4th Addition to the City of Minot,

Ward County, North Dakota

AND

LOTS 1A, 1B, 2A, 2B, 3A, 3B, 4A,

4B, 5A, 5B, BLOCK 1; LOTS 1A,

1B, 2A, 2B, 3A, 3B, 4A, 4B, 5A, 5B,

6A, 6B, 7A, 7B, 8A, 8B, 9A, 9B,

10A, 10B, 11A, 11B, 12A, 12B, 13A,

13B, 14A, 14B, 15A, 15B, 16A, 16B,

17A, 17B, 18A, 18B, 19A, 19B, 20A,

20B, 21A, 21B, 22A, 22B, 23A, 23B,

24A, 24B, 25A, 25B, 26A, 26B, 27A,

27B, 28A, 28B, 29A, 29B, 30A, 30B,

31A, 31B, 32A, 32B, 33A, 33B, 34A,

34B, BLOCK 2; LOTS 1A, 1B, 2A,

2B, 3A, 3B, 4A, 4B, 5A, 5B, 6A, 6B,

7A, 7B, 8A, 8B, 9A, 9B, 10A, 10B,

11A, 11B, 12A, 12B, 13A, 13B, 14A,

14B, 15A, 15B, 16A, 16B, 17A, 17B,

18A, 18B, 19A, 19B, 20, BLOCK 3;

LOTS 1A, 1B, 2A, 2B, 8A, 8B, 9A,

9B, 10A, 10B, 11A, 11B, 12A, 12B,

13A, 13B, 14A, 14B,BLOCK 4; Lots

8A, 8B, 9A, 9B, 10A, 10B, 11A, 11B,

12A, 12B, 13A, 13B, 14A, 14B,

BLOCK 5; LOTS 1A, 1B, 2A, 2B,

3A, 3B, 4A, 4B, 5A, 5B, 6A, 6B, 7A,

7B, BLOCK 6; LOTS 1A, 1B, 2A,

2B, 3A, 3B, 4A, 4B, 5A, 5B, 6A, 6B,

7A, 7B, 12A, 12B, 13A, 13B, 14A,

14B, BLOCK 7; LOTS 1A, 1B, 2A,

2B, 3A, 3B, 4A, 4B, 5A, 5B, 6A, 6B,

7A, 7B, 8A, 8B, 9A, 9B, 10A, 10B,

11A, 11B, 12A, 12B, 13A, 13B, 14A,

14B, BLOCK 8; LOTS 1A, 1B, 2A,

2B, 3A, 3B, 4A, 4B, 5A, 5B, 6A, 6B,

7A, 7B, 8A, 8B, 9A, 9B, 10A, 10B,

11A, 11B, 12A, 12B, 13A, 13B, 14A,

14B, BLOCK 9; All in 55th Crossing

5th Addition to the City of Minot,

Ward County North Dakota

AND

LOTS 2A, 2B, 3A, 3B, 4A, 4B, 5A,

5B, 6A, 6B, 7A, 7B, 8A, 8B, 9A, 9B,

10A, 10B, 11A, 11B, 12A, 12B, 13A,

13B, 14A, 14B, 15A, 15B, 16, 17,

18, 19, 20, 21, 22, 23, 24, 25, 26, All

in 55th Crossing 7th Addition to the

City of Minot, Ward County, North

Dakota

AND

LOT 2, 55th Crossing 8th Addition to

the City of Minot, Ward County,

North Dakota

AND

Outlots 37, 38, 39, and 40, Section

28, Township 155 North, Range 82

West of the 5th P.M., Ward County,

North Dakota

Ebeltoft . Sickler . Lawyers

2272 8th Street West

Dickinson, ND 58602-1598

Attorneys for Plaintiff

(February 17-24; March 3, 2021)

NOTICE TO CREDITORS

51-2021-PR-00044

IN THE DISTRICT COURT OF

WARD COUNTY, STATE OF

NORTH DAKOTA

IN THE MATTER OF THE ESTATE

OF DONALD J. McGOWAN,

DECEASED.

NOTICE IS HEREBY GIVEN that

the undersigned has been appointed

Personal Representative of the

above estate. All persons having

claims against the deceased are re-

quired to present their claims within

three months after the date of the

first publication of this notice or said

claims will be forever barred. Claims

must be presented to Melissa Bliss,

in care of Thomas Law Firm, 114

South Main Street, P.O. Box 2298,

Minot, North Dakota 58702, or filed

with the Court.

Dated this 17th day of February,

2021.

/s/Melissa Bliss

Melissa Bliss

c/o THOMAS LAW FIRM

114 South Main Street

P.O. Box 2298

Minot, North Dakota 58702

(February 24; March 3-10, 2021)

NOTICE TO CREDITORS

PROBATE NO. 51-2021-PR-00019

IN THE DISTRICT COURT OF

WARD COUNTY, STATE OF

NORTH DAKOTA

In the Matter of the Estate of

BECKY JANE ODELL, a/k/a BECKY

ODELL, Deceased.

NOTICE IS HEREBY GIVEN that

the undersigned has been appointed

personal representative of the above

estate. All persons having claims

against the said deceased are re-

quired to present their claims within

three months after the date of the

first publication or mailing of this no-

tice or said claims will be forever

barred. Claims must either be

presented to FARRAH MAE NUZ-

ZO, Personal Representative of the

estate, at 2525 Elk Drive, P.O. Box

1000, Minot, ND 58702-1000, or

filed with the Court.

Dated this 4th day of February 2021.

/s/Farrah Mae Nuzzo

Farrah Mae Nuzzo

Brent M. Olson – #05593

PRINGLE & HERIGSTAD, P.C.

2525 Elk Drive

P.O. Box 1000

Minot, ND 58702-1000

bolson@pringlend.com

(February 10-17-24, 2021)

NOTICE TO CREDITORS

PROBATE NO. 51-2021-PR-00022

IN THE DISTRICT COURT OF

WARD COUNTY, STATE OF

NORTH DAKOTA

In the Matter of the Estate of

DANIEL A. DEPUTE, Deceased.

NOTICE IS HEREBY GIVEN that

the undersigned has been appointed

personal representative of the above

estate. All persons having claims

against the said deceased are re-

quired to present their claims within

three months after the date of the

first publication or mailing of this no-

tice or said claims will be forever

barred. Claims must either be

presented to MELISSA DEPUTE,

Personal Representative of the

estate, at 2525 Elk Drive, P.O. Box

1000, Minot, ND 58702-1000, or

filed with the Court.

Dated this 4th day of February 2021.

/s/Melissa Depute

Melissa Depute

Matthew H. Olson – #06182

PRINGLE & HERIGSTAD, P.C.

2525 Elk Drive

P.O. Box 1000

Minot, ND 58702-1000

molson@pringlend.com

(February 10-17-24, 2021)

NOTICE TO LAND OWNERS

Hiddenwood Township Annual

meeting will be held March 16, 2021

6 p.m. at the Paul Bersaw home.

Business meeting and election of (1)

officer and any other business

brought before the board of Supervi-

sors will be conducted at this meet-

ing.

(February 24; March 3, 2021)

ORDER TERMINATING

PARENTAL RIGHTS

(Revised for Publication)

File No. 51-2020-JV-00143

STATE OF NORTH DAKOTA,

COUNTY OF WARD, IN JUVENILE

COURT, NORTH CENTRAL

JUDICIAL DISTRICT

IN THE INTEREST OF J.M.,

MINOR CHILD

State of North Dakota,

Petitioner,

vs.

J.M., child,

Unknown Father

Cody Glander, putative father,

Respondents.

THE STATE OF NORTH DAKOTA

TO THE ABOVE NAMED RESPON-

DENT CODY GLANDER AND UNK-

NOWN FATHER.

A petition to Terminate Parental

Rights of Cody Glander and Unk-

nown Father was heard by the Court

on February 5, 2021.

The Respondent parents, Cody

Glander, putative father and Unk-

nown Father, did not participate in

said hearing.

That the Court found based on the

file and the testimony and evidence

that Cody Glander putative father

and Unknown Father, should be for-

ever deprived of all parental rights

with reference to J.M.

Based on the foregoing the Court

entered an ORDER TO TER-

MINATE PARENTAL RIGHTS that

Cody Glander, putative father and

Unknown Father, be and hereby

deprived of all parental rights with

reference to said child and the rela-

tionship of parent and child between

the child and the natural mother and

natural father is hereby forever ter-

minated.

Dated at Minot, North Dakota this

19th day of February, 2021.

BY THE COURT:

/s/Connie S. Portscheller

Connie S. Portscheller

Judicial Referee

(February 24; March 3-10, 2021)

PUBLIC HEARING NOTICE

NORTH DAKOTA HOUSING

FINANCE AGENCY

PROPOSED ALLOCATION PLAN

UNDER THE 2021 NATIONAL

HOUSING TRUST FUND

North Dakota Housing Finance

Agency (NDHFA) will hold a Public

Hearing, via toll-free conference call,

with respect to its Proposed Alloca-

tion Plan Under the 2021 National

Housing Trust Fund on April 1,

2021, at 11:00 a.m., CT.

The Plan sets forth the procedures

and criteria which NDHFA is to use

in allocating the National Housing

Trust Fund annual allocation made

available to owners and developers

of rental housing pursuant to 24

CFR 91 and 93.

The Public Hearing is for interested

parties to provide either written or

oral comments regarding the pro-

posed Plan. Persons who do not at-

tend the hearing may submit written

comments by 5:00 p.m., CT, on

March 31, 2021. The plan can be

viewed on NDHFA’s website,

www.ndhfa.org, beginning on March

1, 2021. Please contact NDHFA pri-

or to the hearing for accommoda-

tions or additional information.

Public Hearing Details:

Attendance to the public hearing is

available by telephone only.

Toll-Free Dial (877) 216-1555

Passcode 526124

NDHFA Contact:

Jennifer Henderson

Director, Planning and Housing

Development Division

PO Box 1535

Bismarck, ND 58502

(800) 292-8621

(800) 366-6889 (TTY)

hfainfo@nd.gov

Equal Housing Opportunity

(February 24, 2021)

PUBLIC HEARING NOTICE

NORTH DAKOTA HOUSING

FINANCE AGENCY

PROPOSED QUALIFIED

ALLOCATION PLAN UNDER THE

2022 LOW INCOME HOUSING

TAX CREDIT PROGRAM

North Dakota Housing Finance

Agency (NDHFA) will hold a Public

Hearing, via toll-free conference call,

with respect to its proposed Quali-

fied Allocation Plan (QAP) under the

2022 Low Income Housing Tax

Credit Program on April 1, 2021, at

10:00 a.m., CT.

The QAP sets forth the procedures

and criteria which NDHFA will

adhere to in allocating low income

housing tax credits to owners and

developers of rental housing pur-

suant to Section 42 of the Internal

Revenue Code.

The Public Hearing is for interested

parties to provide either written or

oral comments regarding the pro-

posed QAP. Persons who do not at-

tend the hearing may submit written

comments by 5:00 p.m., CT, on

March 31, 2021. The plan can be

viewed on NDHFA’s website,

www.ndhfa.org, beginning on March

1, 2021. Please contact NDHFA pri-

or to the hearing for accommoda-

tions or additional information.

Public Hearing Details:

Attendance to the public hearing is

available by telephone only.

Toll-Free Dial (877) 216-1555

Passcode 526124

NDHFA Contact:

Jennifer Henderson

Director, Planning and Housing

Development Division

PO Box 1535

Bismarck, ND 58502

(800) 292-8621

(800) 366-6889 (TTY)

hfainfo@nd.gov

Equal Housing Opportunity

(February 24, 2021)

PUBLIC NOTICE

An Environmental Assessment (EA)

has been prepared to analyze the

impacts of the construction of a new

22,000-sf children’s museum and

activity center, the Magic City

Discovery Center (MCDC) in north

Minot, North Dakota.

The EA evaluates potential impacts

of the alternative actions on the en-

vironment including the No-action

Alternative. Based on this analysis,

the MCDC has prepared a proposed

Finding of No Significant Impact

(FONSI).

Electronic copies of the documents

can also be found on the City of

Minot website at www.minotnd.org.

A hard copy of the documents can

be found at the Minot Public Library,

516 2nd Ave SW, Minot, ND for re-

view. You are encouraged to submit

comments through March 12th,

2021.

Comments should be provided to

Ackerman-Estvold, Attn: Kevin

Ploof, 1907 17th St. SE, Minot ND

58701.

(February 10-17-24, 2021)

PUBLIC NOTICE

STATE OF NORTH DAKOTA 2019

ANNUAL REPORT TO HUD

The North Dakota Department of

Commerce, Division of Community

Services and North Dakota Housing

Finance Agency announce the

state’s Annual Report to the U.S.

Department of Housing and Urban

Development for 2019 Action Plan

will be available for public review

during the period of March 1-16,

2021.

The 2019 Action Plan served as the

state’s grant application to HUD for

the Community Development Block

Grant, HOME, Emergency Solutions

Grant, and National Housing Trust

Fund programs. The Annual Report

provides information on the various

activities funded by these programs

from July 1, 2019, through June 30,

2020, and describes how these ac-

tivities addressed the goals and ob-

jectives of the state’s 2015-2019

Consolidated Plan. In addition, the

Annual Report identifies the number

and types of households that bene-

fited from these programs during the

2019 program year.

To obtain a copy of the Annual Re-

port, contact Bonnie Malo at

701-328-5300, ND Relay TTY:

1-800-366-6888, ND Relay Voice

1-800-366-6889, ND Relay Spanish

1-800-435-8590, or email at

dcs@nd.gov. The report can also

be viewed on our website at:

http://www.communityservices.nd.go

v/communitydevelopment/Consolida

tedPlan/

Alternate formats of this report are

available upon request.

The public may submit written com-

ments to the report. Comments must

be received by the close of business

on March 16, 2021.

Send written comments to:

Bonnie Malo

ND Department of Commerce

Division of Community Services

PO Box 2057

Bismarck, ND 58502-2057

(February 24, 2021)

PUBLIC NOTICE

The City of Minot is posting this legal

notice. The City of Minot is currently

pursuing the aid of the United States

Air Force Reserve in Vector Control

for fiscal year 2020 and 2021. The

proposal is for the Department of

Defense (Innovative Readiness

Training Program) to perform arthro-

pod borne disease control training

through the aerial application of pes-

ticides. There is no funding for these

operations without the assistance of

the USAFR unit. To fulfill the

non-competitive requirements of the

Department of Defense, this notice

is given. Any questions or objections

regarding the non-competition pro-

cess should be made within 14 days

of the publication of this legal notice

in the Minot Daily News. Send com-

ments in writing to: Dan Jonasson,

City of Minot Public Works Director,

PO Box 5006, Minot, ND 58702.

(February 17-24; March 3-10, 2021)

STATE OF NORTH DAKOTA

PUBLIC SERVICE COMMISSION

Halstad Telephone Company

Designated Eligible Carrier Ex-

pansion

Application

Case No. PU-21-55

NOTICE OF OPPORTUNITY FOR

HEARING

February 17, 2021

On January 28, 2021, Halstad Tele-

phone Company (Halstad) filed, as a

non-incumbent local exchange car-

rier, an application for designation

as an eligible telecommunications

carrier (ETC) for the purpose of re-

ceiving Federal Communications

Commission’s Rural Digital Oppor-

tunity Fund Phase I funding in

Federal Communications Commis-

sion (FCC) specified census blocks

in rural areas of North Dakota. The

FCC requires that Halstad be desig-

nated as an ETC by June 7, 2021.

The issues to be considered in this

matter are:

1. Is the applicant qualified under the

Telecommunications Act of 1996,

Section 214(e) for designation as an

ETC eligible to receive federal

universal service funding?

2. What ETC universal service sup-

port area should be designated?

3. Is designation of the applicant as

an ETC in the public interest?

Those interested are invited to com-

ment on the application in writing.

Persons desiring a hearing must file

a written request identifying their in-

terest in the proceeding and the rea-

sons for requesting a hearing. Com-

ments and requests for hearings

must be received by March 29,

2021. If deemed appropriate, the

Commission can determine the

matter without a formal hearing.

For more information contact the

Public Service Commission, State

Capitol, Bismarck, North Dakota

58505, 701-328-2400; or Relay

North Dakota 1-800-366-6888 TTY.

If you require any auxiliary aids or

services, such as readers, signers,

or Braille materials please notify the

Commission.

PUBLIC SERVICE COMMISSION

Randy Christmann, Commissioner

Julie Fedorchak, Chair

Brian Kroshus, Commissioner

(February 24, 2021)

STATE OF NORTH DAKOTA

PUBLIC SERVICE COMMISSION

Polar Telcom, Inc.

Designated Eligible Carrier Ex-

pansion

Application

Case No. PU-21-51

NOTICE OF OPPORTUNITY FOR

HEARING

February 17, 2021

On January 28, 2021, Polar Telcom,

Inc. (Polar) filed, as a

non-incumbent local exchange car-

rier, an application for designation

as an eligible telecommunications

carrier (ETC) for the purpose of re-

ceiving Federal Communications

Commission’s Rural Digital Oppor-

tunity Fund Phase I funding in

Federal Communications Commis-

sion (FCC) specified census blocks

in rural areas of North Dakota. The

FCC requires that Polar be designat-

ed as an ETC by June 7, 2021.

The issues to be considered in this

matter are:

1. Is the applicant qualified under the

Telecommunications Act of 1996,

Section 214(e) for designation as an

ETC eligible to receive federal

universal service funding?

2. What ETC universal service sup-

port area should be designated?

3. Is designation of the applicant as

an ETC in the public interest?

Those interested are invited to com-

ment on the application in writing.

Persons desiring a hearing must file

a written request identifying their in-

terest in the proceeding and the rea-

sons for requesting a hearing. Com-

ments and requests for hearings

must be received by March 29,

2021. If deemed appropriate, the

Commission can determine the

matter without a formal hearing.

For more information contact the

Public Service Commission, State

Capitol, Bismarck, North Dakota

58505, 701-328-2400; or Relay

North Dakota 1-800-366-6888 TTY.

If you require any auxiliary aids or

services, such as readers, signers,

or Braille materials please notify the

Commission.

PUBLIC SERVICE COMMISSION

Randy Christmann, Commissioner

Julie Fedorchak, Chair

Brian Kroshus, Commissioner

(February 24, 2021)

STATE OF NORTH DAKOTA

PUBLIC SERVICE COMMISSION

MLGC, LLC

Designated Eligible Carrier Ex-

pansion

Application

Case No. PU-21-50

NOTICE OF OPPORTUNITY FOR

HEARING

February 17, 2021

On January 28, 2021, MLGC, LLC

(MLGC) filed, an application for

designation as an eligible telecom-

munications carrier (ETC) for the

purpose of receiving Federal Com-

munications Commission’s Rural Di-

gital Opportunity Fund Phase I fund-

ing in Federal Communications

Commission (FCC) specified census

blocks in rural areas of North Dako-

ta. The FCC requires that MLGC be

designated as an ETC by June 7,

2021.

The issues to be considered in this

matter are:

1. Is the applicant qualified under the

Telecommunications Act of 1996,

Section 214(e) for designation as an

ETC eligible to receive federal

universal service funding?

2. What ETC universal service sup-

port area should be designated?

3. Is designation of the applicant as

an ETC in the public interest?

Those interested are invited to com-

ment on the application in writing.

Persons desiring a hearing must file

a written request identifying their in-

terest in the proceeding and the rea-

sons for requesting a hearing. Com-

ments and requests for hearings

must be received by March 29,

2021. If deemed appropriate, the

Commission can determine the

matter without a formal hearing.

For more information contact the

Public Service Commission, State

Capitol, Bismarck, North Dakota

58505, 701-328-2400; or Relay

North Dakota 1-800-366-6888 TTY.

If you require any auxiliary aids or

services, such as readers, signers,

or Braille materials please notify the

Commission.

PUBLIC SERVICE COMMISSION

Randy Christmann, Commissioner

Julie Fedorchak, Chair

Brian Kroshus, Commissioner

(February 24, 2021)

STATE OF NORTH DAKOTA

PUBLIC SERVICE COMMISSION

Daktel Communications LLC

Designated Eligible Carrier Ex-

pansion

Application

Case No. PU-21-41

AMENDED NOTICE OF OPPOR-

TUNITY FOR HEARING

February 17, 2021

On January 21, 2021, Daktel Com-

munications LLC (Daktel) filed, as a

non-incumbent local exchange car-

rier, an application for designation

as an eligible telecommunications

carrier (ETC) for the purpose of re-

ceiving Federal Communications

Commission’s Rural Digital Oppor-

tunity Fund Phase I funding in

Federal Communications Commis-

sion (FCC) specified census blocks

in rural areas of North Dakota. The

FCC requires that Daktel be desig-

nated as an ETC by June 7, 2021.

Daktel also filed an application for

designation as an ETC for the pur-

pose of receiving federal universal

service support for low-income con-

sumers under 47 CFR Part 54 Sub-

part E. Such designation is also

known as Lifeline-only ETC designa-

tion. Daktel proposes to provide Life-

line universal services to qualifying

low income North Dakota customers

using its own facilities.

The issues to be considered in this

matter are:

1. Is the applicant qualified under the

Telecommunications Act of 1996,

Section 214(e) for designation as an

ETC eligible to receive federal

universal service funding?

2. What ETC universal service sup-

port area should be designated?

3. Is designation of the applicant as

an ETC in the public interest?

Those interested are invited to com-

ment on the application in writing.

Persons desiring a hearing must file

a written request identifying their in-

terest in the proceeding and the rea-

sons for requesting a hearing. Com-

ments and requests for hearings

must be received by March 29,

2021. If deemed appropriate, the

Commission can determine the

matter without a formal hearing.

For more information contact the

Public Service Commission, State

Capitol, Bismarck, North Dakota

58505, 701-328-2400; or Relay

North Dakota 1-800-366-6888 TTY.

If you require any auxiliary aids or

services, such as readers, signers,

or Braille materials please notify the

Commission.

PUBLIC SERVICE COMMISSION

Randy Christmann, Commissioner

Julie Fedorchak, Chair

Brian Kroshus, Commissioner

(February 24, 2021)

SUMMONS (AMENDED)

Case No. 51-2020-DM-0420

STATE OF NORTH DAKOTA,

COUNTY OF WARD, IN DISTRICT

COURT, NORTH CENTRAL

JUDICIAL DISTRICT

IN THE MATTER OF THE

ADOPTION OF GABRIANNA

ALYCE LONDON AND ISABELLA

NEVAEH SKY LONDON.

ANTHONY BRENT LONDON,

PETITIONER,

VS.

JOSHUA MIGUEL WILSON, AND

EXECUTIVE DIRECTOR OF THE

NORTH DAKOTA DEPARTMENT

OF HUMAN SERVICES, CHIRSTO-

PHER D. JONES AND MELISSA

BLISS, WARD COUNTY SERVICE

ZONE, MYRA JO LONDON,

RESPONDENTS.

YOU ARE HEREBY SUMMONED

AND REQUIRED TO APPEAR to

defend against the Petitioner’s Peti-

tion in this action, which is herewith

served upon you, by serving upon

the undersigned an Answer or other

proper response within twenty-one

(21) days after the service of this

Summons upon you, exclusive of

the day of service. If you are a party

out of the state of North Dakota, you

are given an additional fifteen (15)

days, in accordance with North

Dakota Rule of Civil Procedure 4(g)

to provide the aforementioned

Answer. If you fail to do so, judg-

ment by default will be taken against

you for the relief demanded in the

Complaint.

Dated this 26th day of January,

2021.

/s/Brandon Rowenhorst

Brandon Rowenhorst,

Bar I.D. 06484

Attorney for Petitioners

Rowenhorst Law

122 South Main Street, Suite D.

bdhorst@midco.net

Minot, ND 58701

(701)340-9788

(February 10-17-24, 2021)