ADVERTISEMENT FOR BIDS

TGU SCHOOL DISTRICT #60

MECHANICAL UPGRADES –

PHASE 2

302 2ND ST SE

TOWNER, ND 58788

Sealed Bids for Single Prime Construction

of TGU School District #60,

Mechanical Upgrades – Phase 2 will

be accepted until:

2:00 PM Central Time, Thursday,

November 18, 2021 at the office of

Ackerman-Estvold

1907 17th Street SE

Minot, North Dakota

at which time and place the bids will

be opened and read aloud. Proposals

received after that time will not

be accepted.

Single Prime Construction Bid: All

Portions of Work – Mechanical,

Electrical, and General Construction.

Bidders may obtain Plans and

Specifications by contacting Sonya

Boykin at Ackerman-Estvold by

phone at 701-837-8737 or by email

a t

s o n y a . b o y k i n@a c k e r m a n –

e s t v o l d . c o m

and requesting a link providing access

to the project documents.

The Construction Documents will be

on file and may be examined at the

Office of Ackerman-Estvold, Minot,

North Dakota and the following

Builders Exchanges:

Bismarck-Mandan, Construction

Plans Exchange, Dickinson, Fargo,

Grand Forks, Minot, Williston, North

Dakota; St. Paul, and Minneapolis,

Minnesota; Construction Industry

Center, and Sioux Falls Builders Exchange,

South Dakota.

Any contractor who obtains their

plans from an exchange and wishes

to be added to the official plan holders

list or receive automatic email

notification of Addenda must also register

for the project on

Ackerman-Estvold’s plan room and

download the Project documents as

detailed below or contact the Architect

directly.

Each Bid must be accompanied by a

separate envelope, (attached to the

Bid Envelope) containing a Bid Bond

equal to five percent (5%) of the

amount of the Bid naming TGU

School District #60 as Obligee. The

Contractor shall also enclose within

the Bid Bond Envelope a copy of the

Bidder’s North Dakota Contractor’s

License or a copy of their latest

Renewal Certificate issued by the

Secretary of State as per North

Dakota Century Code 43-07-12. All

Contractors who submit Bids must

hold a North Dakota Contractors

License in the highest amount of

their Bids and such license must

have been in effect at least ten (10)

days prior to the date of the Bid

Opening. Any Bid not containing

these documents shall not be acceptable

and shall be returned to the

Bidder unopened. See AIA Document

A701-1997 “Instructions to

Bidders” in the Project Manual for

further information.

The Owner reserves the right to reject

any or all bids and to waive any

informalities in bidding.

The successful bidder will be required

to furnish a Payment Bond,

Performance Bond, Insurance Coverages

and other requirements

stipulated in the Project Manual.

No Bidder may withdraw his Bid

within 30 days of the actual date of

the opening.

A Pre-Bid Conference will be held at

TGU School District #60, 302 2nd St

SE, Towner, ND at 3:30 pm CST on

Thursday, November 4th, 2021.

Erik Sveet, Superintendent

TGU School District #60

(October 28, November 4-11, 2021)

ADVERTISEMENT FOR

CONSTRUCTION BIDS

Sealed bids for the construction of

Minot Landfill Recycling Transfer

Station for the City of Minot, North

Dakota will be received by the Owner

at the Office of the City Clerk at

515 2nd Avenue SW, Minot, ND

58701, until 2:00 PM local time on

Thursday, November 4, 2021, at

which time the construction bids will

be publicly opened and read.

There will be a pre-bid meeting on

Tuesday, October 26, 2021 at 2:00

PM local time. The pre-bid meeting

will be conducted virtually via

Microsoft Teams. A link to the

pre-bid meeting is available by email

request to

m e l i s –

sa.knutson@cpsengineering.net.

The scope of work generally consists

of the following:

Building is a pre-engineered metal

structure 100′-0″ by 100′-0″ with an

inside clearance of 30′-0″. An approximately

100′-0″ by 25′-0″ mezzanine

is included within the structure.

Deposition area includes approximately

4,400 square feet of

Mastertop metal aggregate concrete.

Remaining spaces consist of

rated Household Hazard Waste, office,

conference room, break room,

lockers, and restrooms.

Site Work consists of Removals,

Earthwork, Geosynthetics, Salvage

and Aggregate Base Course, Concrete

Pavement, Watermain, Sanitary

Sewer, Septic Tanks, Bore and

Push, , Seeding, Erosion and Sediment

Control, Traffic Control, Signing,

and other related items.

Bids will be on a unit price basis. Allowances

for specified compactor

and conveyor equipment shall be included

as separate line items on the

Bid Form.

Each bid shall be accompanied by a

separate envelope containing an acceptable

bidder’s bond in an amount

equal to five percent (5%) of the full

amount of the bid, executed by the

bidder as principal and by a Surety,

conditioned that if the principal’s bid

is accepted and the contract awarded

to the principal, the principal,

within fifteen (15) days after Notice

of Award, shall execute a contract in

accordance with the terms of the bid

and Contractor’s Bond as required

by law and regulations and determinations

of the governing body.

Each bid shall contain a copy of the

bidder’s North Dakota Contractor

license or certificate of renewal

thereof issued by the Secretary of

State enclosed in the required bid

bond envelope. Bidder must be

licensed for the full amount of the

bid. No bid shall be read or considered

which does not fully comply

with the above provisions as to bond

and license. Any deficient bid submitted

must be resealed and returned

to the bidder.

The City of Minot reserves the right

to reject any or all bids and/or to

waive any informality in the bids received

and to accept any bid

deemed to be most favorable to the

interest of the City. All work shall be

completed on or before October 15,

2022.

The successful bidder shall warrant

and guarantees work for two (2)

years from the date of final project

acceptance and shall furnish performance

and payments bonds, in the

amount of one hundred percent

(100%) of the contract. Bonds shall

remain in effect until two (2) years

after date of final payment.

Complete digital project bidding documents

are available at

www.questcdn.com. Digital plan documents

may be downloaded for

$15 by inputting Quest project

#8052911 on the website’s Project

Search page. Please contact

QuestCDN.com at (952) 233-1632

or info@questcdn.com for assistance

in free membership registration,

downloading, and working with

this digital project information. An

optional paper set of the Bidding Documents

may be obtained from

CPS, Ltd., 308 2nd Avenue North,

Grand Forks, North Dakota 58203;

upon a non-refundable payment of

$250 per set. All costs associated

with preparation of the bids shall be

borne by the Bidder. Please contact

CPS at (701) 746-7459 if you have

any questions in this regard.

The City of Minot reserves the right

to hold all Bids for a period of forty

five (45) days after the date fixed for

the opening thereof. No Bidder may

withdraw his Bid within forty five (45)

days after the actual date of the

opening thereof. Published by order

of the City of Minot, North Dakota.

By: ss Kelly Matalka

City Clerk

(October 14-21-28, 2021)

FARM LAND FOR SALE

Farmland for sale in McLean County,

North Dakota. The legal description

for the property is:

Township 150 North, Range 80

West of the 5th P.M.

Section 28: NE1/4

Township 150 North, Range 84

West of the 5th P.M.

Section 3: SW1/4, NW1/4

Section 4: SE1/4, NE1/4

Section 10: NW1/4, SW1/4

Subject the following terms and

conditions:

1. A bid form may be obtained by

contacting the offices of: Sheldon A.

Smith, Smith Porsborg Law Firm,

122 East Broadway Ave, P.O. Box

460, Bismarck, ND 58502-0460,

701-258-0630 or by email at either

ssmith@smithporsborg.com or

rderung@smithporsborg.com.

2. Interested bidders must submit

written bids by mail to the above

address OR by email by

November15, 2021 at 5:00 p.m. All

bids should be for the full price for

the tract of land. You must include

your telephone contact number. You

will be contacted and informed of the

date, time and place for oral bidding,

at which time you may attend or

have a proxy appear for you to raise

your bids.

3. Payment will be made as follows:

10% earnest money payable upon

acceptance of the bid and the

balance of the purchase price upon

closing which will be 30 days after

the date of sale.

4. Seller reserves the right to reject

any and all bids or waive any

irregularities.All announcements

made at the bid opening will take

precedence over any printed or

advertised material. Sellers will

retain all mineral rights

Sheldon A Smith

Smith Porsborg

122 East Broadway

Bismarck ND 58501

(October 28, 2021)

NORTH DAKOTA DEPARTMENT

OF ENVIRONMENTAL QUALITY

PUBLIC NOTICE OF OPPORTUNITY

TO COMMENT ON DRAFT

PERMIT FOR A SOLID WASTE

MANAGEMENT FACILITY UNDER

THE NORTH DAKOTA SOLID

WASTE MANAGEMENT RULES

FACILITY NAME: Central Point

Landfill and Transfer LLC – Transfer

Station – Permit 0378

APPLICANT: Central Point Landfill

and Transfer LLC

105 34th Ave. NE

Minot, ND 58703

BACKGROUND: On May 3, 2021,

the North Dakota Department of Environmental

Quality (Department) received

a permit application for a

renewal for the Central Point Landfill

and Transfer LLC’s (Central Point)

transfer station. The facility was previously

owned and permitted by

Rugby Sanitation, Inc.

Central Point currently owns and

operates a transfer station, regulated

under Permit 0378 on approximately

40 acres, of which 20 acres is usable

for solid waste management

activities, located in the NW1/4 of

the NE1/4 of Section 1, Township

155 North, Range 73 West in Pierce

County, ND. Central Point is proposing

to renew the permit to continue

operating a transfer station. The facility

was first permitted in 1994 as

the Rugby Sanitation, Inc. transfer

station.

The Department believes that a permit

which meets the requirements of

the North Dakota Solid Waste

Management Rules and is protective

of human health and the environment

can be issued to Central Point

Landfill and Transfer LLC – Transfer

Station and has prepared a Draft

Permit for public review and comment.

PUBLIC COMMENTS AND

HEARING

As required by Section

33.1-20-03.1-03 of the North Dakota

Administrative Code, the Draft Permit

will be available for public review

and comment for thirty (30) days following

publication of the Public Notice.

The public comment period begins

October 23, 2021 and ends November

26, 2021. During that period,

any interested person may submit

written comments and request a

public hearing by stating the nature

of the specific issues to be raised. A

fifteen (15) day notice will be provided

before any hearing is scheduled.

The North Dakota Department of

Environmental Quality will consider

all comments prior to taking any action

on the permit. Comments, questions

and written communication

should be directed to:

Charles R. Hyatt, Director

North Dakota Department of Environmental

Quality

Division of Waste Management

4201 Normandy Street

Bismarck, ND 58503

Comments may also be sent via

e-mail to solidwaste@nd.gov.

The Draft Permit and Permit Application

are available for review during

the hours of 8:30 a.m. to 4:00 p.m.,

Monday through Friday, at the North

Dakota Department of Environmental

Quality, Division of Waste

Management, 4201 Normandy

Street, Bismarck, ND. A copy of this

Public Notice is also on the

Department’s website at:

https://deq.nd.gov/PublicNotice.

aspx

Anyone requiring special access or

accommodations to review the Draft

Permit may contact the Department

at 701-328-5166

(October 28, 2021)

NOTICE OF REAL ESTATE SALE

CIVIL NUMBER: 51-2019-CV-00936

IN THE STATE OF NORTH

DAKOTA, COUNTY OF WARD

IN THE DISTRICT COURT, NORTH

CENTRAL JUDICIAL DISTRICT

U.S. Bank Trust National

Association, as Trustee, for ABS

Loan Trust II,

Plaintiff,

v.

Amber A. Bjork a/k/a Amber

Twogood; Brent Twogood; The United

States of America, acting by and

through the Administrator of the

Small Business Administration; and

all persons unknown, claiming any

estate or interest in, or lien or encumbrance

upon, the real estate

described in the complaint; any person

in possession,

Defendants.

Amended Judgment in the amount

of $167,170.14, having been entered

in favor of Plaintiff and against Defendants,

which Judgment was filed

with the Clerk of Courts of Ward

County, North Dakota, on August

16, 2021, for the foreclosure of a

real estate mortgage. Notice is hereby

given pursuant to said Judgment

that the real property described as:

Lot 1, Block 4, North Minot, an Addition

to the City of Minot, Ward

County,

North Dakota. Real Property address:

523 3rd Street NW, Minot,

ND

58703

The above real property is the subject

of the Mortgage dated July 30,

2010, which Mortgagor, Amber A.

Bjork, executed and delivered to

Mortgage Electronic Registration

Systems, Inc., as Mortgagee, as

nominee for Premier Mortgage Corporation,

a North Dakota corporation,

its successors and assigns, and

recorded in the office of the Clerk

and Recorder of Ward County, North

Dakota, on August 2, 2010, Instrument

Number 2912966, which is

subject to the entered Judgment.

Said Mortgage was assigned to

Plaintiff, its successors or assigns,

by Assignment of Mortgage recorded

September 16, 2020, Instrument

Number 3043465. In order to realize

the amount of $167,170.14, as of

August 16, 2021, plus interest accruing

thereafter on said amount at the

rate of 5.00000% per year together

with the costs and expenses of sale,

will be sold subject to redemption as

provided by law as one parcel of

land at public auction, subject to the

lien for unpaid real estate taxes and

assessments of Ward County, North

Dakota, and easements and restrictions

of record, to the highest bidder

for cash under the direction of the

Sheriff of Ward County, North Dakota,

at the main entrance of the Ward

County Courthouse located at 315

3rd Street SE, Minot, North Dakota

58701, on December 1, 2021 (“Sale

Date”), at 10:00 AM. If the sale is set

aside for reason, the Purchaser at

the sale shall be entitled only to a return

of the deposit paid. The purchaser

shall have no further

recourse against the Mortgagor, the

Mortgagee or the Mortgagee’s attorney.

DATED this 7th day of October,

2021.

SHERIFF OF WARD COUNTY For:

Robert Roed By: Jamie Williams

Sheriff / Deputy Sheriff of Ward

Halliday, Watkins & Mann, P.C.

By Zachary Nesbit

Zachary Nesbit

Attorneys for Plaintiff

376 East 400 South, Suite 300

Salt Lake City, UT 84111

Tel: 801-355-2886

Email: zach@hwmlawfirm.com

Bar: 07552

(October 14-21-28, 2021)

SUMMONS

Civil No. 51-2021-CV-01658

STATE OF NORTH DAKOTA IN

DISTRICT COURT

COUNTY OF WARD NORTH

CENTRAL JUDICIAL DISTRICT

ProCollect Services, LLC,

Plaintiff,

vs.

Gregory Leonard,

Defendant.

THE STATE OF NORTH DAKOTA

TO THE ABOVE-NAMED

DEFENDANT:

YOU ARE HEREBY SUMMONED

and required to appear and defend

against the Complaint in this action,

which is herewith served upon you,

by serving on the undersigned an

Answer or other proper response

within twenty-one days after service

of this Summons upon you, exclusive

of the day of service. If you

fail to do so, judgment by default will

be taken against you for the relief

demanded in the complaint.

Dated October 18, 2021.

/s/ Christopher A. Carlson

Christopher A. Carlson (id #03378)

PO Box 1097

Bismarck ND 58502-1097

701-258-4800

carlsonlaw@qwestoffice.net

Attorney for the Plaintiff

(October 21-28 November 4, 2021)

SUMMONS

Civil No. 51-2021-CV-01681

STATE OF NORTH DAKOTA,

COUNTY OF WARD,

IN DISTRICT COURT NORTH

CENTRAL JUDICIAL DISTRICT

Benjamin John Kamm and Sheila

Kay Pierce,

Plaintiff,

vs

Robert Patzner and any unknown

Defendants,

The State of North Dakota to the

above named Defendants:

You are hereby summoned and required

to appear and defend against

the complaint in this action, which

will be filed with the clerk of this

court, by serving upon the undersigned

an answer or other proper

response within twenty (20) days

after the service of this summons

upon you, exclusive the day of service.

If you fail to do so, judgement

by default will be taken against you

for the relief demanded in the complaint.

You are hereby notified that the land

parcel to which this NDCC Chapter

32-17 quiet title action relates is loctated

in Ward County, North Dakota,

to-wit:

Radio CIty S/D S27 E200 L4 Blk4

with the objective of this action being

to void any adverse claims to the

above – descibed property and quiet

title in the Plaintiff.

Dated this 21st day of October,

2021.

Ashley E Beall (ID 06589)

Attorney for Plaintiffs

PO Box 791

Minot, ND 58702

(701)340-2316

ashley.beall.law@gmail.com

(October 28, November 4-11, 2021)