ADVERTISEMENT FOR BIDS

CITY OF MINOT, NORTH DAKOTA

10 Street NW Storm Sewer

Rehabilitation

CITY PROJECT 4616

NOTICE IS HEREBY GIVEN that

the City of Minot (Owner) is re-

questing Bids for the construction of

the following Project: 10th Street

NW Storm Sewer Rehabilitation.

Bids for the construction of the Pro-

ject will be received at the office of

the City Clerk located at 515 Second

Avenue SW (Second Floor), Minot,

North Dakota 58701, until Thursday,

August 19, 2021 at 11:00 AM local

time. At that time the Bids received

will be publicly opened and read.

The Project includes the following

Work: 500 LF storm sewer replace-

ment, asphalt removal, asphalt pav-

ing, installing catch basins, installing

manholes, concrete sidewalk re-

placement, concrete driveway re-

placement, ADA ramps, concrete

curb & gutter, traffic control,

landscaping, and other related work.

Complete digital project bidding do-

cuments are available at

www.questcdn.com. You may down-

load the digital plan documents for

$40 by inputting eBidDoc #7958852

on the website’s Project Search

page. Please contact

QuestCDN.com at 952-233-1632 or

info@questcdn.com for assistance

in free membership registration,

downloading, and working with this

digital project information. Project

bidding documents are also avail-

able at the Issuing Office – City of

Minot Engineering Department 1025

31st St SE and are available for pur-

chase for $75. Potential bidders may

contact the Assistant City Engineer

at 701-857-4100 with any questions.

Each bid must be accompanied by a

separate envelope containing the

bid security in a sum equal to five

percent of the full amount of the bid

and must be in the form of a bidder’s

bond. A bidder’s bond must be exe-

cuted by the bidder as principal and

by a surety, conditioned that if the

principal’s bid is accepted and the

contract awarded to the principal,

the principal, within ten days after

notice of the award, shall execute a

contract in accordance with the

terms of the bid and the bid bond,

and any condition of the City of

Minot, as required by law. A counter-

signature of a bid bond is not re-

quired. If the City of Minot elects to

award a contract to the lowest

responsible bidder, and the lowest

responsible bidder does not execute

a contract within the ten days al-

lowed, the bidder’s bond must be

forfeited to the City of Minot and the

project awarded to the next lowest

responsible bidder.

Each bidder must possess a valid

North Dakota contractor’s license for

the full amount of their bid, as re-

quired by Section 43-07-07 of the

North Dakota Century Code. Each

bidder MUST enclose a copy of their

Contractor’s License or Certificate of

Renewal, issued by the North Dako-

ta Secretary of State, in their bid

bond envelope, and each license

must be valid and dated at least 10

days prior to the date set for bid

opening, as required under Section

43-07-12 of the North Dakota Centu-

ry Code.

No bid may be read or considered if

it does not fully comply with the re-

quirements of Section 48-01.2-05 of

the North Dakota Century Code, and

any deficient bid submitted will be

resealed and returned to the bidder

immediately.

All Bids submitted and all Work

completed must be as stipulated in

the Agreement.

The City of Minot reserves the right

to hold all Bids for a period of 30

days after the date of the bid open-

ing, to reject any or all Bids and to

rebid the project until a satisfactory

bid is received, and to waive any in-

formality or irregularity in any Bid.

For all further requirements regard-

ing bid submittal, qualifications, pro-

cedures, and contract award, refer to

the Instructions to Bidders that are

included in the Bidding Documents.

By order of the City Council of the

City of Minot, North Dakota.

Owner: City of Minot

By: Kelly Matalka

Title: City Clerk

Date: July 22, 2021

(July 27; August 3-10, 2021)

ADVERTISEMENT FOR BIDS

CITY OF MINOT, NORTH DAKOTA

10 Street NW Storm Sewer

Rehabilitation

CITY PROJECT 4616

NOTICE IS HEREBY GIVEN that

the City of Minot (Owner) is request-

ing Bids for the construction of the

following Project: 10th Street NW

Storm Sewer Rehabilitation.

Bids for the construction of the Pro-

ject will be received at the office of

the City Clerk located at 515 Second

Avenue SW (Second Floor), Minot,

North Dakota 58701, until Thursday,

August 19, 2021 at 11:00 AM local

time. At that time the Bids received

will be publicly opened and read.

The Project includes the following

Work: 500 LF storm sewer replace-

ment, asphalt removal, asphalt pav-

ing, installing catch basins, installing

manholes, concrete sidewalk re-

placement, concrete driveway re-

placement, ADA ramps, concrete

curb & gutter, traffic control,

landscaping, and other related work.

Complete digital project bidding do-

cuments are available at

www.questcdn.com. You may down-

load the digital plan documents for

$40 by inputting eBidDoc #7958852

on the website’s Project Search

page. Please contact

QuestCDN.com at 952-233-1632 or

info@questcdn.com for assistance

in free membership registration,

downloading, and working with this

digital project information. Project

bidding documents are also avail-

able at the Issuing Office – City of

Minot Engineering Department 1025

31st St SE and are available for pur-

chase for $75. Potential bidders may

contact the Assistant City Engineer

at 701-857-4100 with any questions.

Each bid must be accompanied by a

separate envelope containing the

bid security in a sum equal to five

percent of the full amount of the bid

and must be in the form of a bidder’s

bond. A bidder’s bond must be exe-

cuted by the bidder as principal and

by a surety, conditioned that if the

principal’s bid is accepted and the

contract awarded to the principal,

the principal, within ten days after

notice of the award, shall execute a

contract in accordance with the

terms of the bid and the bid bond,

and any condition of the City of

Minot, as required by law. A counter-

signature of a bid bond is not re-

quired. If the City of Minot elects to

award a contract to the lowest

responsible bidder, and the lowest

responsible bidder does not execute

a contract within the ten days al-

lowed, the bidder’s bond must be

forfeited to the City of Minot and the

project awarded to the next lowest

responsible bidder.

Each bidder must possess a valid

North Dakota contractor’s license for

the full amount of their bid, as re-

quired by Section 43-07-07 of the

North Dakota Century Code. Each

bidder MUST enclose a copy of their

Contractor’s License or Certificate of

Renewal, issued by the North Dako-

ta Secretary of State, in their bid

bond envelope, and each license

must be valid and dated at least 10

days prior to the date set for bid

opening, as required under Section

43-07-12 of the North Dakota Centu-

ry Code.

No bid may be read or considered if

it does not fully comply with the re-

quirements of Section 48-01.2-05 of

the North Dakota Century Code, and

any deficient bid submitted will be

resealed and returned to the bidder

immediately.

All Bids subMitted and all Work

completed must be as stipulated in

the Agreement.

The City of Minot reserves the right

to hold all Bids for a period of 30

days after the date of the bid open-

ing, to reject any or all Bids and to

rebid the project until a satisfactory

bid is received, and to waive any in-

formality or irregularity in any Bid.

For all further requirements regard-

ing bid submittal, qualifications, pro-

cedures, and contract award, refer to

the Instructions to Bidders that are

included in the Bidding Documents.

By order of the City Council of the

City of Minot, North Dakota.

Owner: City of Minot

By: Kelly Matalka

Title: City Clerk

Date: July 22, 202

(July 27; August 3-10, 2021)

INVITATION NO: IFB 21-12 TOTAL

CONSTRUCTION

INVITATION TO BID

MILITARY PARKING LOT

SURFACING

Aviation Readiness Center

Complex

Bismarck, North Dakota

Sealed bids for Military Parking Lot

Surfacing, Aviation Readiness

Center Complex, Bismarck, North

Dakota will be received by the Adju-

tant General of the State of North

Dakota at Fraine Barracks, Building

30, Bismarck, North Dakota, until

2:00 PM, August 5, 2021, and will be

publicly read that date and hour in

the location designated. All bids re-

ceived after the scheduled opening

time will be returned to the bidders

unopened. The deadline for receipt

of technical questions is no later

than July 29, 2021.

Electronic bidding documents may

be requested. Emails must be ac-

companied by a copy of your current

North Dakota Contractor’s License

or Certificate of Renewal and your

request must be written on business

letterhead. No requests will be ack-

nowledged without receipt of both

documents. Requests for bidding

documents must be submitted to:

ng.nd.ndarng.list.dfe-contract-

management@mail.mil.

Due to COVID 19, the bid opening

will not be open to the public. The

front gate entrance to Fraine Bar-

racks is closed to the general public.

A representative from the Facilities

Engineering Division will be at the

gate from 12:00 Noon until 1:30 p.m.

CST on August 5, 2021. Bidders

may hand deliver their bids during

that time ONLY. Delivery by courier

service or U.S. Mail are the pre-

ferred methods for delivery.

Modifications to bids are allowed in

accordance with the instructions in

AGND Document 411, Subpara-

graph 4.4.2. All bid modifications

must be received by the Contract

Management Office no later than

2:00 p.m. CST. Be advised, the re-

ceipt of emails and faxed transmis-

sions have a delay time due to data

security restrictions and military

firewalls. Allow adequate time for

emailed and faxed transmissions to

travel through our security system.

The OWNER is not responsible for

bid modifications received by the

Contract Management Office later

than 2:00 p.m. CST on the day of

the bid opening. Modifications to

bids must be emailed to:

ng.nd.ndarng.list.dfe-contract-

management@mail.mil.

To listen to the bid opening, you

may dial in:

701-333-2840

ID No. 32076#

Pin No. 32076#

A single bid will be received for Total

Construction work (IFB 21-12).

OWNER

Office of the Adjutant General

Contract Management Branch

P.O. Box 5511

Bismarck, North Dakota 58506-5511

Telephone: (701) 333-2068

Copies of the bidding documents are

on file at the Construction Plans Ex-

change in Bismarck; Builders Ex-

changes in Dickinson, Fargo, Grand

Forks, Mandan, Minot, Rapid City,

Impact Procurement Technical As-

sistance Center in Fargo, North

Dakota and Minnesota Builders Ex-

change in Minneapolis, Minnesota.

Each bid shall be submitted in dupli-

cate using the bid response forms

provided by the Owner, enclosed in

a sealed opaque envelope and la-

beled with the necessary information

as required by the Supplementary

Instructions to Bidders.

Each bid shall be accompanied by a

separate sealed opaque envelope

containing a bidder’s bond made

payable to The Adjutant General,

State of North Dakota, and executed

by the bidder as principle and by a

surety company authorized to con-

duct business in North Dakota, in a

sum equal to five percent (5%) of

the bidder’s highest total bid combi-

nation, including all add alternates to

the bid items; conditioned that if the

bid is accepted and the contract

awarded, the bidder within ten (10)

days after notice of such award, will

effect and execute a contract in ac-

cordance with the terms of his bid

and provide payment and perfor-

mance bonds as required by law

and the regulations and determina-

tions of the Owner. AIA Document

A310, Bid Bond, is provided in the

electronic project manual and should

be used to execute the bid guaran-

tee.

In compliance with Section 43-07-12

of the North Dakota Century Code,

each contractor submitting a bid

must have a copy of their North

Dakota Contractor’s License or certi-

ficate of renewal issued by the

Secretary of State enclosed in the

bid bond envelope; must be licensed

for the highest amount of their total

bid combination including add alter-

nates; and such license must have

been in effect at least ten (10) days

prior to the date of the bid opening.

No bid will be read or considered

which does not fully comply with the

provisions herein as to bid bond and

contractor license, and any deficient

bid submitted will be resealed and

returned to the bidder immediately.

The Owner reserves the right to hold

all legitimate bids for a period of thir-

ty (30) days following the date fixed

for the bid opening. It is the intent of

the Owner to award a contract to the

lowest and best bidder. The Owner

further reserves the right to reject

any and all bids and to waive irregu-

larities, and shall incur no legal liabil-

ity for the State for the payment of

any monies until the contract is

awarded and approved by the prop-

er authorities.

In compliance with Section

48-01.2-10 of the North Dakota Cen-

tury Code, the successful bidder

shall be required to furnish payment

and performance bonds covering the

faithful performance of the contract

award and the payment of all obliga-

tions thereunder, and all additional

obligations required by the laws of

the State of North Dakota. Each

bond shall be in an amount equal to

the full contract award amount.

DATED: 12 July 2021

OFFICE OF THE ADJUTANT GEN-

ERAL

Bismarck, North Dakota

By: /s/ JACKIE A. HUBER

Brigadier General, NDNG

Deputy Adjutant General

Contracting Officer

(July 13-20-27, 2021)

Minot Park District

Request for Proposal Bid –

Compact Tractor- Snow Blower &

Broom

Notice is hereby given that sealed

bids will be received by Jarrod A. Ol-

son, Director of Operations, at the

Minot Park District Office, 420 3rd

Ave SW, PO Box 538, Minot, ND

58702, until 2pm August 12th, 2021

at which times proposals will be

opened and read for furnishing to

the Board of Park Commissioners.

Envelope containing the proposal

shall be plainly marked on the out-

side – “Bid – Compact Tractor –

Snow Blower & Broom”

Copies of Specifications may be ob-

tained from the Park District Office

at above address or at

www.minotparks.com

The Board of Park Commissioners

reserves the right to reject any and

all Bids, waive any irregularities

therein, and to award the contract as

they deem to be the best interest of

the Minot Park District.

Bidders are invited to be present at

the above -mentioned time and

place for the opening of the bids.

Proposals will be presented to the

Minot Park Board on August 17th at

6:30pm.

Technical Questions Contact:

Shawn Schafer

Senior Equipment Mechanic

mechanic@minotparks.com

(701) 822-3281

Bid questions contact:

Jarrod A. Olson

Director of Operations

Minot Park District

jarrod@minotparks.com

(701) 857-4136 Office

(701) 833-7021 Cell

(July 27; August 3-10, 2021)

NOTICE OF EXECUTION SALE

Case No. 51-2019-CV-02150

STATE OF NORTH DAKOTA, IN

DISTRICT COURT, COUNTY OF

WARD, NORTH CENTRAL

JUDICIAL DISTRICT

QUICKEN LOANS INC.,

Plaintiff,

vs.

LINDA PRICE and OCCUPANTS

OF 2514 SW 2ND AVE., MINOT,

ND 58701,

Defendants.

NOTICE IS HEREBY GIVEN, that

by virtue of a Special Execution is-

sued to me by the Clerk of the Dis-

trict Court in and for the County of

Ward, North Dakota, North Central

Judicial District, I will sell the real

property described in the Judgment

entered and docketed in the Office

of the Clerk of said Court on March

19, 2020, and hereafter described to

the highest bidder for cash at public

auction at the Ward County Court-

house located in Minot, North Dako-

ta, on August 11, 2021, at the hour

of 10:00 AM (CT)of that day to satis-

fy the amount due and owing the

Plaintiff from the Defendant(s) in the

sum of $198,150.73, plus accrued

costs and interest to the date of

sale, or so much thereof as the

proceeds of said sale applicable

thereto will satisfy. The premises to

be sold as aforesaid are situated in

the County of Ward, State of North

Dakota, and are more particularly

described as follows:

Land Situated in the City of Minot in

the County of Ward in the State of

ND

Lot 21, Block 3, Dacotah Homes

Second Addition to the City of

Minot, North Dakota.

(Street Address: 2514 2nd Ave.

SW, Minot, ND 58701(June

3-10-17, 2021)

ON TESTIMONY WHEREOF, I

have hereunto set my hand and seal

the 7th day of July, 2021.

For: Robert Roed

Sheriff of Ward County,

North Dakota

By:/s/Jamie Williams

Deputy Sheriff

APPROVED AS TO FORM AND

CONTENT:

The Sayer Law Group, P.C.

Janelle G. Ewing

925 E. 4th St.

Waterloo, IA 50703

(319) 234-2530

Attorney ID No.: 08611

generalupdates@sayerlaw.com

Attorneys for Plaintiff

(July 13-20-27, 2021)

NOTICE TO CREDITORS

Probate No. 51-2021-PR-00097

IN THE DISTRICT COURT OF

WARD COUNTY, STATE OF

NORTH DAKOTA

In the Matter of the Estate of

Steven L. McLain, Deceased.

NOTICE IS HEREBY GIVEN that

the undersigned has been appointed

personal representative of the above

estate. All persons having claims

against Steven L. McLain are re-

quired to present their claims within

three (3) months after the date of the

first publication of this noticeor said

claims will be forever barred.

Claims must either be presented, in

writing, to Eric A. McLain,personal

representative of the estate, at P.O.

Box 998, Minot, ND 58702-0998,or

filed with the Court.

Dated July 2, 2021

Eric A. McLain

Personal Representative

(July 13-20-27, 2021)

NOTICE TO CREDITORS

Probate No. 51-2021-PR-00110

IN THE DISTRICT COURT OF

WARD COUNTY, STATE OF

NORTH DAKOTA

In the Matter of the Estate of

Margueritte Forsberg, Deceased.

NOTICE IS HEREBY GIVEN that:

1.Jeffrey Farstad has been appoint-

ed personal representative of the

Estate of Margueritte Forsberg.

2.All persons having claims against

Margueritte Forsberg are required to

present their claims within three (3)

months after the date of the first

publication of this notice or said

claims will be forever barred.

3.Claims must either be presented

to Jeffrey Farstad, personal

representative of the estate, at P.O.

Box 998, Minot, ND 58702-0998, or

filed with the Court.

July 7, 2021

Jeffrey Farstad

Personal Representative

(July 13-20-27, 2021)

NOTICE TO CREDITORS

Probate No. 51-2021-PR-00114

IN THE DISTRICT COURT OF

WARD COUNTY, STATE OF

NORTH DAKOTA

In the Matter of this Estate of

Dennis Long, Deceased.

NOTICE IS HEREBY GIVEN that

the undersigned has been appointed

Personal Representative of the

above estate. All persons having

claims against the deceased are re-

quired to present their claims within

three months, 90 days, after the date

of the first publication or mailing of

this notice or the claims will be for-

ever barred. Claims must either be

presented to Michael Long, Personal

Representative of the Estate of

Dennis Long, in care of , in care of

Morgan Glines of Boppre Law Firm,

PLLC, 2151 36th Ave SW, Suite B,

Minot, North Dakota 58701, or filed

with the Court.

Michael Long,

Personal Representative

Morgan Glines (ID #08853)

Boppre Law Firm, PLLC

2151 36th Ave SW, Suite B

Minot, ND 58701

Office: 701-852-5224

Fax: 701-852-5229

mglines@bopprelawfirm.com

Attorney for Personal Representativ

(July 27; August 3-10, 2021)

SUMMONS

IN THE STATE OF NORTH

DAKOTA, COUNTY OF WARD, IN

THE DISTRICT COURT, NORTH

CENTRAL JUDICIAL DISTRICT

US Bank Trust Natonal Association,

not in its individual capacity but sole-

ly as Owner Trustee for VRMTG As-

set Trust,

Plaintiff,

v.

Christopher A. Vickerman; Bremer

Bank; National Association; State of

North Dakota d/b/a The Bank of

North Dakota; any person in posses-

sion,

Defendants.

THE STATE OF NORTH DAKOTA

TO THE ABOVE-NAMED DEFEN-

DANTS:

1.To the above-mentioned Defen-

dants including all persons unk-

nown, claiming any estate or interest

in, or lien or encumbrance upon, the

real estate described below and in

the complaint.

2.You are hereby summoned and

required to appear and defend

against the Complaint in this action,

which is herewith served upon you,

by serving upon the undersigned a

copy of an Answer or other proper

response within twenty-one (21)

days after the service of this Sum-

mons upon you, exclusive of the day

of service.

3.If you fail to do so, Judgment by

default will be taken against you for

the relief demanded in the Com-

plaint.

4. This Summons and Complaint will

be filed with the Clerk of this Court.

5.This action relates to the foreclo-

sure of a mortgage upon the follow-

ing described real property in the

County of Ward, State of North

Dakota:

Lot 3, Vold’s Addition to the City

of Minot, Ward County, North

Dakota.

Property Address: 909 2nd Ave-

nue Northwest, Minot, ND 58703

6.The Plaintiff is not seeking a per-

sonal judgment against the

above-named Defendants.

Dated June 2, 2021

/s/Scott S. Skeen

Scott S. Skeen

376 East 400 South, Suite 300

Salt Lake City Utah 84111

Tel: 801-355-2886

Email: scott@hwmlawfirm.com

Bar Number: 09334

HWM: ND10664

(July 13-20-27, 2021)