Legal Notices 3-30
ADVERTISEMENT FOR BIDS
Bids for the design of the new joint
Crosby Rural Fire Protection District
and Divide County Ambulance Dis-
trict Fire and EMS Hall:
The work will include designing a
new Fire and EMS Hall located
within the city limits of Crosby, North
Dakota.
Bids must be received no later than
5 p.m., April 1, 2021. Mailed bids
must be sent to Crosby Rural Fire
Proctection District Architect Bids,
P.O.Box 84, Crosby, ND, 58730.
1. The bids will be opened at the
Crosby Rural Fire Protection District
above the Crosby City Hall on April
1, 2021 at 7:00 p.m.
2. That each bid must be accompa-
nied by a separate envelope con-
taining the contractor’s license and
bid security. The bid security must
be in a sum equal to five percent of
the full amount of the bid and must
be in the form of a bidder’s bond. A
bidder’s bond must be executed by
the bidder as principal and by a
surety, conditioned that if the
principal’s bid is accepted and the
contract awarded to the principal,
the principal, within ten days after
notice of the award, shall execute a
contract in accordance with the
terms of the bid and the bid bond
and any condition of the governing
body. A countersignature of a bid
bond is not required under this sec-
tion. If a successful bidder does not
execute a contract within the ten
days allowed, the bidder’s bond
must be forfeited to the governing
body and the project awarded to the
next lowest responsible bidder.
3. That a bidder, except a bidder on
a municipal, rural, and industrial wa-
ter supply project using funds pro-
vided under Public Law No. 99-294
[100 Stat. 426; 43 U.S.C. 390a],
must be licensed for the full amount
of the bid as required by section
43-07-12. For projects using funds
provided under Public Law No.
99-294 [100 Stat. 426; 43 U.S.C.
390a], the advertisement must state
that, unless a bidder obtains a
contractor’s license for the full
amount of its bid within twenty days
after it is determined the bidder is
the lowest responsible bidder, the
bid must be rejected and the con-
tract awarded to the next lowest
responsible bidder
4. That no bid may be read or con-
sidered if the bid does not fully com-
ply with the requirements of section
48-01.2 of the North Dakota Century
Code and that any deficient bid sub-
mitted must be resealed and re-
turned to the bidder immediately.
5. That the governing body reserves
the right to reject any and all bids
and rebid the project until a satis-
factory bid is received.
6. This project is a time sensitive
project and therefore will require a
projected completion date. The
Crosby Rural Fire Protection District
would like this project to be complet-
ed by November 30, 2021.
7.The bidder will also be required to
provide proof of insurance.
(March 19-20-22-23-24-25-26-
27-29-30-31; April 1, 2021)
CALL FOR BIDS
Harrison Township will accept bids
for year-round road maintenance in-
cluding blading, plowing, mowing,
sanding & other maintenance as
needed. Written and sealed bids
should be submitted to: Harrison
Township Clerk at 4520 46 St NW,
Minot, ND 58703, and are due April
15, 2021. Harrison Township
reserves the right to refuse any and
all bids. Bids not submitted properly
will not be considered.
(March 24-25-26-27-29-30-31, 2021)
LEGAL NOTICE
The North Dakota Department of
Commerce, Division of Community
Services, is announcing the availa-
bility of the state’s 2021 Annual Ac-
tion Plan for public review and com-
ment.
The 2021 Annual Action Plan serves
as the state’s grant application to the
Federal Department of Housing and
Urban Development (HUD) for the
Community Development Block
Grant, HOME, National Housing
Trust Fund, and Emergency Solu-
tions Grants programs. The Action
Plan describes how the funds from
each program will be distributed dur-
ing the 2021 program year, which is
scheduled to begin July 1, 2021.
Funds are expected to be received
on or about July 1, 2021.
All allocation amounts in the 2021
Action Plan are estimated amounts.
The Action Plan will be available on
the Division of Community Services
website, http://www.community
services.nd.gov/communitydevelop
ment/ConsolidatedPlan/ beginning
April 1, 2021. Written comments
must be received by the close of
business April 30, 2021.
Alternate formats of the Action Plan
are available upon request at
701-328-5300 or via Relay North
Dakota: TTY 1-800-366-6888, Voice
1-800-366-6889, or Spanish 1-800-
435-8590. Should anyone need ad-
ditional information, please contact
Bonnie Malo at 701-328-5300.
Written comments should be sent to:
North Dakota Department of Com-
merce
Division of Community Services
PO Box 2057
Bismarck, ND 58502-2057
or
Email: dcs@nd.gov
(March 30, 2021)
Minot Park District Call for Bids
Bid – Forestry Class 5 16,500
GVRW Pickup Cab & Chassis”
Notice is hereby given that sealed
bids will be received by Jarrod A. Ol-
son, Director of Operations, at the
Minot Park District Office, 420 3rd
Ave SW, PO Box 538, Minot, ND
58702, until 2pm April 15th, 2021 at
which times bids will be opened and
read for furnishing to the Board of
Park Commissioners.
Envelope containing the bid shall be
plainly marked on the outside – “Bid
– Forestry Class 5 Truck”
Copies of Specifications may be ob-
tained from the Park District Office
at above address or at
www.minotparks.com
The Board of Park Commissioners
reserves the right to reject any and
all bids, waive any irregularities
therein, and to award the contract as
they deem to be the best interest of
the Minot Park District.
Bidders are invited to be present at
the above-mentioned time and place
for the opening of the bids. Bids will
be presented to the Minot Park
Board on April 20th at 6:30pm at the
Minot Park Board Meeting.
Technical Questions Contact
1. Troy Regstad – Forestry Techni-
cian troyregstad@gmail.com or
701-818-7258
2. Shawn Schafer- Head Mechanic
mechanic@minotparks.com or 701-
822-3281
*Delivery will be coordinated with
Minot Park District Forestry &
Maintenance Department
Jarrod A. Olson
Director of Operations
Minot Park District
jarrod@minotparks.com
(701) 857-4136 Office
(701) 833-7021 Cell
(March 30, April 6-13 2021)
Minot Park District Call for Bids
Bid – Maysa Roof
Notice is hereby given that sealed
bids will be received by Jarrod A. Ol-
son, Director of Operations, at the
Minot Park District Office, 420 3rd
Ave SW, PO Box 538, Minot, ND
58702, until 2pm April 15th, 2021 at
which times bids will be opened and
read for furnishing to the Board of
Park Commissioners.
Envelope containing the bid shall be
plainly marked on the outside – “Bid
-Maysa Roof”
Copies of Specifications may be ob-
tained from the Park District Office
at above address or at
www.minotparks.com
The Board of Park Commissioners
reserves the right to reject any and
all bids, waive any irregularities
therein, and to award the contract as
they deem to be the best interest of
the Minot Park District.
Bidders are invited to be present at
the above -mentioned time and
place for the opening of the bids.
Bids will be presented to the Minot
Park Board on April 20th at 6:30pm.
Technical Questions Contact
-Brian Mathson-Maintenance Su-
perintendent brian@minotparks.com
or 701-833-7055
*Project will be coordinated with Bob
Gillen-Maysa General Manager
Jarrod A. Olson
Director of Operations
Minot Park District
jarrod@minotparks.com
(701) 857-4136 Office
(701) 833-7021 Cell
(March 30, April 6-13, 2021)
Minot Park District Call for Bids
Equipment: Play Structure
Bid – Play Structure – Green
Valley Park
Notice is hereby given that sealed
bids will be received by Jarrod A. Ol-
son, Director of Operations, at the
Minot Park District Office, 420 3rd
Ave SW, PO Box 538, Minot, ND
58702, until 2pm April 15th, 2021 at
which times bids will be opened and
read for furnishing to the Board of
Park Commissioners.
Envelope containing the bid shall be
plainly marked on the outside – “Bid
– Play Structure-Green Valley
Park”
Copies of Specifications may be ob-
tained from the Park District Office
at above address or at
www.minotparks.com
The Board of Park Commissioners
reserves the right to reject any and
all bids, waive any irregularities
therein, and to award the contract as
they deem to be the best interest of
the Minot Park District.
Bidders are invited to be present at
the above-mentioned time and place
for the opening of the bids. Bids will
be presented to the Minot Park
Board on April 20th at 6:30pm.
Technical Questions Contact –
Brian Mathson-Maintenance Super-
intendent brian@minotparks.com or
701-833-7055
*Delivery will be coordinated with
Brian Mathson-Maintenance Super-
intendent
Jarrod A. Olson
Director of Operations
Minot Park District
jarrod@minotparks.com
(701) 857-4136 Office
(701) 833-7021 Cell
(March 30, April 6-13, 2021)
NOTICE
Effective immediately Harrison
Township will conduct meetings on
the second Tuesday in May, July,
Sept, Nov, Jan and Mar. All meet-
ings will begin at 6:30 pm at the
Minot Rural Fire Dept, 400 31st Ave
SW, Minot, ND 58701.
Cindy Whitesell
Harrison Township Clerk
(March 24-25-26-27-29-30-31, 2021)
NOTICE OF REAL ESTATE SALE
CIVIL NUMBER: 51-2018-CV-00127
IN THE STATE OF NORTH
DAKOTA, COUNTY OF WARD
IN THE DISTRICT COURT, NORTH
CENTRAL JUDICIAL DISTRICT
Reverse Mortgage Funding, LLC,
Plaintiff,
v.
Cheryl D. Lane; Heirs & Devisees of
the Estate of Cheryl D. Lane; United
States of America, acting by and
through the Secretary of Housing
and Urban Development; Unknown
Spouse of Cheryl D. Lane; Unknown
Spouse of Ruth Lane; any person in
possession, and all persons unk-
nown, claiming any estate or interest
in, or lien or encumbrance upon, the
real estate described in the com-
plaint,
Defendants.
1. Judgment in the amount of
$197,606.49, having been entered in
favor of Plaintiff and against Defen-
dants, which Judgment was filed
with the Clerk of Courts of Ward
County, North Dakota, on December
7, 2020, for the foreclosure of a real
estate mortgage.
2. Notice is hereby given pursuant to
said Judgment that the real property
described as:
The following described parcel of
land, and improvements and ap-
purtenances thereto in the County of
Ward, State of ND, to wit:
Countryside Villas, 3rd Addition Lot
2, Nedrose-S4 A 2
Together with: Used 2000 Bonnavil-
la 52 x 28 Manufactured Home Seri-
al No. NEB00A28052S.
MORE CORRECTLY DESCRIBED
AS FOLLOWS:
The following described parcel of
land, and improvements and ap-
purtenances thereto in the County of
Ward, State of ND, to wit:
Countryside Villas, 3rd Addition Lot
2, Nedrose-S4 A 2
Together with: Used 2000 Bonne-
ville 52 x 28 Manufactured Home
Serial No. NEB00A28052S.
With an address of 2105 55th Street
SE, Minot, ND 58701, and being the
subject of the Mortgage dated
February 13, 2015, which Mortga-
gor, Cheryl D. Lane, executed and
delivered to Mortgage Electronic
Registration Systems, Inc., as Mort-
gagee, as nominee for Reverse
Mortgage Funding LLC, its succes-
sors and assigns, and recorded in
the office of the Clerk and Recorder
of Ward County, North Dakota, on
March 2, 2015, Instrument Number
2983529, is subject to the entered
Judgment. Said Mortgage was as-
signed to Plaintiff, its successors or
assigns, by Assignment of Mortgage
recorded September 13, 2017, In-
strument Number 3012033.
3. In order to realize the amount of
$197,606.49, as of December 7,
2020, plus interest accruing
thereafter on said amount at the rate
of $9.97 per day together with the
costs and expenses of sale, the pro-
perty will be sold subject to redemp-
tion as provided by law as one par-
cel of land at public auction, subject
to any lien for unpaid real estate
taxes and assessments of Ward
County, North Dakota, and ease-
ments and restrictions of record, to
the highest bidder for cash under the
direction of the Sheriff of Ward
County, North Dakota, at the main
entrance of the Ward County Court-
house located at 315 SE 3rd Street,
Minot, North Dakota 58701, on April
28, 2021 (“Sale Date”), at 10:00 AM.
4. If the sale is set aside for reason,
the Purchaser at the sale shall be
entitled only to a return of the depo-
sit paid. The purchaser shall have
no further recourse against the Mort-
gagor, the Mortgagee or the
Mortgagee’s attorney.
DATED this 9th day of March, 2021.
For: Robert Roed
/s/Jamie Williams
Deputy Sheriff of Ward County
Halliday, Watkins & Mann, P.C.
/s/ Scott S. Skeen
Attorneys for Plaintiff
376 East 400 South, Suite 300
Salt Lake City, UT 84111
801-355-2886
Email: scott@hwmlawfirm.com
ND Bar No.: 09334
(March 16-23-30, 2021)
NOTICE OF REAL ESTATE SALE
CIVIL NUMBER: 51-2020-CV-01280
IN THE STATE OF NORTH
DAKOTA, COUNTY OF WARD
IN THE DISTRICT COURT, NORTH
CENTRAL JUDICIAL DISTRICT
Lakeview Loan Servicing, LLC,
Plaintiff,
v.
Shaun D. Welsch; Unknown Heirs
and Devisees of the Estate of Shaun
D. Welsch; any person in posses-
sion, and all persons unknown,
claiming any estate or interest in, or
lien or encumbrance upon, the real
estate described in the complaint,
Defendants.
1. Judgment in the amount of
$209,424.05, having been entered in
favor of Plaintiff and against Defen-
dants, which Judgment was filed
with the Clerk of Courts of Ward
County, North Dakota, on January
29, 2021, for the foreclosure of a
real estate mortgage.
2. Notice is hereby given pursuant to
said Judgment that the real property
described as:
Lot 15, Burlington Heights Addition
to the City of Burlington, Ward
County, North Dakota.
Real Property address:102 Soo
Street, Burlington, ND 58722
The above real property is the sub-
ject of the Mortgage dated June 28,
2017, which Mortgagor, Shaun D.
Welsch, executed and delivered to
Mortgage Electronic Registration
Systems, Inc., as Mortgagee, as
nominee for Rubicon Mortgage Advi-
sors, LLC, its successors and as-
signs, and recorded in the office of
the Clerk and Recorder of Ward
County, North Dakota, on June 29,
2017, Instrument Number 3009857,
which is subject to the entered Judg-
ment. Said Mortgage was assigned
to Plaintiff, its successors or as-
signs, by Assignment of Mortgage
recorded January 6, 2020, Instru-
ment Number 3035397.
3. In order to realize the amount of
$209,424.05, as of January 29,
2021, plus interest accruing
thereafter on said amount at the rate
of 4.25% per year together with the
costs and expenses of sale, the pro-
perty will be sold subject to redemp-
tion as provided by law as one par-
cel of land at public auction, subject
to any lien for unpaid real estate
taxes and assessments of Ward
County, North Dakota, and ease-
ments and restrictions of record, to
the highest bidder for cash under the
direction of the Sheriff of Ward
County, North Dakota, at the main
entrance of the Ward County Court-
house located at 315 SE 3rd Street,
Minot, North Dakota 58701, on April
28, 2021 (“Sale Date”), at 10:00 AM.
4. If the sale is set aside for reason,
the Purchaser at the sale shall be
entitled only to a return of the depo-
sit paid. The purchaser shall have
no further recourse against the Mort-
gagor, the Mortgagee or the
Mortgagee’s attorney.
DATED this 9th day of March, 2021.
For: Robert Roed
/s/Jamie Williams
Deputy Sheriff of Ward County
Halliday, Watkins & Mann, P.C.
/s/ Scott S. Skeen
Attorneys for Plaintiff
376 East 400 South, Suite 300
Salt Lake City, UT 84111
801-355-2886
Email: scott@hwmlawfirm.com
ND Bar No.: 09334
(March 16-23-30, 2021)
NOTICE TO CREDITORS
Probate No. 51-2021-PR-00025
IN THE DISTRICT COURT OF
WARD COUNTY, STATE OF
NORTH DAKOTA
In the Matter of the Estate of Dion
J. Palen, Deceased.
NOTICE IS HEREBY GIVEN that
Robert A Bohrer has been appointed
personal representative of the above
estate. All persons having claims
against Dion J. Palen are required to
present their claims within three (3)
months after the date of the first
publication or mailing of this notice
or said claims will be forever barred.
Claims must either be presented to
Robert A. Bohrer, personal
representative of the estate, at 2765
Highway 25, Mandan, ND 58554 or
filed with the Court. Dated this 17th
day of March, 2021.
/s/Robert A. Bohrer
Robert A. Bohrer,
Personal Representative
(March 23-30; April 6, 2021)
SUMMONS
Civil No. 51-2021-CV-00417
STATE OF NORTH DAKOTA,
COUNTY OF WARD, IN DISTRICT
COURT, NORTH CENTRAL
JUDICIAL DISTRICT
ProCollect Services, LLC,
Plaintiff,
vs.
Robert Clark,
Defendant.
THE STATE OF NORTH DAKOTA
TO THE ABOVE-NAMED DEFEN-
DANT:
YOU ARE HEREBY SUMMONED
and required to appear and defend
against the Complaint in this action,
which is herewith served upon you,
by serving on the undersigned an
Answer or other proper response
within twenty-one days after service
of this Summons upon you, ex-
clusive of the day of service. If you
fail to do so, judgment by default will
be taken against you for the relief
demanded in the complaint.
Dated March 11, 2021.
/s/Christopher A. Carlson
Chistopher A. Carlson (ID #03378)
PO Box 1097
Bismarck, North Dakota 58502-1097
701-258-4800
carlsonlaw@qwestoffice.net
Attorney for the Plaintiff
(March 16-23-30, 2021)
SUMMONS
Civil No. 51-2021-CV-00464
STATE OF NORTH DAKOTA,
COUNTY OF WARD, IN DISTRICT
COURT, NORTH CENTRAL
JUDICIAL DISTRICT
ProCollect Services, LLC,
Plaintiff,
vs.
Adelard and Paige Hoffarth,
Defendant.
THE STATE OF NORTH DAKOTA
TO THE ABOVE-NAMED DEFEN-
DANT:
YOU ARE HEREBY SUMMONED
and required to appear and defend
against the Complaint in this action,
which is herewith served upon you,
by serving on the undersigned an
Answer or other proper response
within twenty-one days after service
of this Summons upon you, ex-
clusive of the day of service. If you
fail to do so, judgment by default will
be taken against you for the relief
demanded in the complaint.
Dated March 18, 2021.
/s/Christopher A. Carlson
Chistopher A. Carlson (ID #03378)
PO Box 1097
Bismarck, North Dakota 58502-1097
701-258-4800
carlsonlaw@qwestoffice.net
Attorney for the Plaintiff
(March 23-30; April 6, 2021)