Legal Notices 8-3
INVITATION NO: IFB 20-20
GENERAL CONSTRUCTION
IFB 20-21
MECHANICAL CONSTRUCTION
IFB 20-22
ELECTRICAL CONSTRUCTION
IFB 20-23
TOTAL COMBINED
CONSTRUCTION
INVITATION TO BID
BUILDING REMODEL
Bldg. 3800
Camp Gilbert C. Grafton
Devils Lake, North Dakota
Sealed bids for Building Remodel,
Bldg. 3800, Camp Gilbert C. Graf-
ton, Devils Lake, North Dakota will
be received by the Adjutant General
of the State of North Dakota at
Fraine Barracks, Building 030,
Bismarck, North Dakota, until 2:00
PM, August 13, 2020, and will be
opened and publicly read that date
and hour in the location designated.
All bids received after the scheduled
opening time will be returned to the
bidders unopened. The deadline for
technical questions from contractors
is close of business on August 6,
2020. Bidders may submit separate
bids for General Construction work
(IFB 20-20), Mechanical Construc-
tion work (IFB 20-21) and/or Electri-
cal Construction work (IFB 20-22). In
addition, the Office of the Adjutant
General will allow the submission of
a Total Combined Construction Bid
(single prime) for the complete pro-
ject (IFB 20-23). In compliance with
NDCC 48-01.2-06, the combined bid
(from a single prime) will not be ac-
cepted unless that bid is lower than
the combined total of the lowest
responsible, multiple bids for the
project. IMPORTANT: Davis-Bacon
Wage Rates are required for this
project. ATTENTION PERSONS
WITH DISABILITIES: If you require
special assistance, please contact
the National Guard ADA Coordinator
at 701-333-2296 by August 6, 2020.
Electronic bidding documents may
be requested. Emails must be ac-
companied by a copy of your current
North Dakota Contractor’s License
or Certificate of Renewal and your
request must be written on business
letterhead. No requests will be ack-
nowledged without receipt of both
documents. Submit request to
ng.nd.ndarng.list.dfe-contract-
management@mail.mil.
OWNER
Office of the Adjutant General
Contract Management Branch
P.O. Box 5511
Bismarck, North Dakota 58506-5511
Telephone: (701) 333-2068
Copies of the bidding documents are
on file at the Construction Plans Ex-
change in Bismarck; Builders Ex-
changes in Dickinson, Fargo, Grand
Forks, Mandan, and Minot, North
Dakota; Impact Procurement Techn-
ical Assistance Center, Fargo, North
Dakota, Minnesota Builders Ex-
change in Minneapolis, Minnesota,
and at the office of the Architect.
Each bid shall be submitted in dupli-
cate copy on the forms provided by
the Owner and enclosed in a sealed
opaque envelope upon which there
is disclosed the necessary informa-
tion as required by the Supplemen-
tary Instructions to Bidders. Each bid
shall be accompanied by a separate
sealed opaque envelope containing
a bidder’s bond made payable to
The Adjutant General, State of North
Dakota, and executed by the bidder
as principle and by a surety com-
pany authorized to do business in
North Dakota, in a sum equal to five
percent (5%) of the bidder’s highest
total bid combination, including all
add alternates to the bid items; con-
ditioned that if the bidder’s proposal
be accepted and the contract award-
ed to him, he within ten (10) days
after notice of such award, will effect
and execute a contract in accor-
dance with the terms of his bid and a
contractor’s bond as required by law
and the regulations and determina-
tions of the Owner. AIA Document
A310, Bid Bond, is provided in the
electronic project manual and should
be used to execute the bid guaran-
tee. In compliance with Section
43-07-12 of the North Dakota Centu-
ry Code, each contractor submitting
a bid must have a copy of his North
Dakota Contractor’s License or certi-
ficate of renewal thereof issued by
the Secretary of State enclosed in
the bid bond envelope; must be
licensed for the highest amount of
his total bid combination including
add alternates; and such license
must have been in effect at least ten
(10) days prior to the date of the bid
opening. No bid will be read or con-
sidered which does not fully comply
with the provisions herein as to bid
bond and contractor license, and
any deficient bid submitted will be
resealed and returned to the bidder
immediately. The Owner reserves
the right to hold all legitimate bids for
a period of thirty (30) days after the
date fixed for the opening thereof. It
is the intent of the Owner to award a
contract to the lowest and best
bidder. The Owner further reserves
the right to reject any and all bids
and to waive irregularities, and shall
incur no legal liability for the State
for the payment of any monies until
the contract is awarded and ap-
proved by the proper authorities. In
compliance with Section 48-01.2-10
of the North Dakota Century Code,
the successful bidder shall be re-
quired to furnish payment and per-
formance bonds covering the faithful
performance of the Contract and the
payment of all obligations
thereunder, and all additional obliga-
tions required by the laws of the
State of North Dakota. Each bond
shall be in an amount equal to the
full contract sum.
DATED: 20 July 2020
OFFICE OF THE ADJUTANT
GENERAL
Bismarck, North Dakota
By: /s/ JACKIE A. HUBER
Brigadier General, NDNG
Deputy Adjutant General
Contracting Officer
(July 20-27; August 3, 2020)
INVITATION NO: IFB 20-25
GENERAL CONSTRUCTION
IFB 20-26
MECHANICAL CONSTRUCTION
IFB 20-27
ELECTRICAL CONSTRUCTION
IFB 20-28
TOTAL COMBINED
CONSTRUCTION
INVITATION TO BID
BUILDING CONVERSION
Bldg. 2370
Camp Gilbert C. Grafton
Devils Lake, North Dakota
Sealed bids for Building Conversion,
Bldg. 2370, Camp Gilbert C. Graf-
ton, Devils Lake, North Dakota will
be received by the Adjutant General
of the State of North Dakota at
Fraine Barracks, Building 030,
Bismarck, North Dakota, until 2:00
PM, August 27, 2020, and will be
publicly read that date and hour in
the location designated. All bids re-
ceived after the scheduled opening
time will be returned to the bidders
unopened. The deadline for receipt
of technical questions is no later
than August 20, 2020. Due to CO-
VID 19, the bid opening will not be
open to the public. The front gate
entrance to Fraine Barracks is
closed to the general public. A
representative from Facilities En-
gineering Division will be at the gate
from 12:00 p.m. until 1:30 p.m. CST
on August 27, 2020. Bidders may
hand deliver their bids during that
time only. Delivery by courier ser-
vice or U.S. Mail are the preferred
methods for delivery. Modifications
to bids are allowed in accordance
with the instructions in AGND Docu-
ment 411, Subparagraph 4.4.2. Bid
modifications must be received no
later than 2:00 p.m. CST. Be ad-
vised, the receipt of emails and
faxed transmissions have a delay
time due to data security restrictions
and military firewalls. Allow ade-
quate time for emailed and faxed
transmissions to travel through our
security system. The OWNER is not
responsible for bid modifications that
arrive later than 2:00 p.m. CST on
the day of the bid opening. To listen
to the bid opening, you may dial in:
701-333-2840; ID No. 32089#; Pin
No. 32089#
Bidders may submit separate bids
for General Construction work (IFB
20-25), Mechanical Construction
work (IFB 20-26) and/or Electrical
Construction work (IFB 20-27). In
addition, the Office of the Adjutant
General will allow the submission of
a Total Combined Construction Bid
(single prime) for the complete pro-
ject (IFB 20-28). In compliance with
NDCC 48-01.2-06, the combined bid
(from a single prime) will not be ac-
cepted unless that bid is lower than
the combined total of the lowest
responsible, multiple bids for the
project. IMPORTANT: Davis-Bacon
Wage Rates are required for this
project. Electronic bidding docu-
ments may be requested. Emails
must be accompanied by a copy of
your current North Dakota
Contractor’s License or Certificate of
Renewal and your request must be
written on business letterhead. No
requests will be acknowledged
without receipt of both documents.
Submit request to
ng.nd.ndarng.list.dfe-contract-mana
gement@mail.mil.
OWNER
Office of the Adjutant General
Contract Management Branch
P.O. Box 5511
Bismarck, North Dakota 58506-5511
Telephone: (701) 333-2068
Copies of the bidding documents are
on file at the Construction Plans Ex-
change in Bismarck; Builders Ex-
changes in Dickinson, Fargo, Grand
Forks, Mandan, and Minot, North
Dakota; Impact Procurement Techn-
ical Assistance Center, Fargo, North
Dakota, Minnesota Builders Ex-
change in Minneapolis, Minnesota,
and at the offices of the Architect
and the Owner. Each bid shall be
submitted in duplicate copy on the
forms provided by the Owner and
enclosed in a sealed opaque en-
velope upon which there is disclosed
the necessary information as re-
quired by the Supplementary In-
structions to Bidders. Each bid shall
be accompanied by a separate
sealed opaque envelope containing
a bidder’s bond made payable to
The Adjutant General, State of North
Dakota, and executed by the bidder
as principle and by a surety com-
pany authorized to do business in
North Dakota, in a sum equal to five
percent (5%) of the bidder’s highest
total bid combination, including all
add alternates to the bid items; con-
ditioned that if the bidder’s proposal
be accepted and the contract award-
ed to him, he within ten (10) days
after notice of such award, will effect
and execute a contract in accor-
dance with the terms of his bid and a
contractor’s bond as required by law
and the regulations and determina-
tions of the Owner. AIA Document
A310, Bid Bond, is provided in the
electronic project manual and should
be used to execute the bid guaran-
tee. In compliance with Section
43-07-12 of the North Dakota Centu-
ry Code, each contractor submitting
a bid must have a copy of his North
Dakota Contractor’s License or certi-
ficate of renewal thereof issued by
the Secretary of State enclosed in
the bid bond envelope; must be
licensed for the highest amount of
his total bid combination including
add alternates; and such license
must have been in effect at least ten
(10) days prior to the date of the bid
opening. No bid will be read or con-
sidered which does not fully comply
with the provisions herein as to bid
bond and contractor license, and
any deficient bid submitted will be
resealed and returned to the bidder
immediately. The Owner reserves
the right to hold all legitimate bids for
a period of thirty (30) days after the
date fixed for the opening thereof. It
is the intent of the Owner to award a
contract to the lowest and best
bidder. The Owner further reserves
the right to reject any and all bids
and to waive irregularities, and shall
incur no legal liability for the State
for the payment of any monies until
the contract is awarded and ap-
proved by the proper authorities. In
compliance with Section 48-01.2-10
of the North Dakota Century Code,
the successful bidder shall be re-
quired to furnish payment and per-
formance bonds covering the faithful
performance of the Contract and the
payment of all obligations
thereunder, and all additional obliga-
tions required by the laws of the
State of North Dakota. Each bond
shall be in an amount equal to the
full contract sum.
DATED: 3 August 2020
OFFICE OF THE ADJUTANT GEN-
ERAL
Bismarck, North Dakota
By: /s/ JACKIE A. HUBER
Brigadier General, NDNG
Deputy Adjutant General
Contracting Officer
(August 3-10-17, 2020)
NOTICE OF HEARING
Probate No. 51-2020-PR-00134
IN DISTRICT COURT, WARD
COUNTY, STATE OF NORTH
DAKOTA
In the Matter of the Estate of
Lori M. King, Deceased.
NOTICE IS HEREBY GIVEN that
Norman F. King, Jr. has filed herein
a Petition for Adjudication of Intes-
tacy, Adjudication of Priority for Ap-
pointment of Personal Representa-
tive, and Appointment of Personal
Representative for the estate of Lori
M. King, deceased.
Hearing has been set upon said
Petition on the 11th day of Sep-
tember, 2020, at 10:00 a.m. at the
Courtroom of the above named
Court in the City of Minot, County of
Ward, State of North Dakota, and
any person may appear and be
heard.
IT IS FURTHER ORDERED that in
order for any objection to be con-
sidered, objections to the Adju-
dication of Intestacy, Adjudica-
tion of Priority for Appointment of
Personal Representative, and Ap-
pointment of Personal Represen-
tative must be in writing and must
be filed with the Court and the at-
torney for the Petitioner no later
than seven (7) days prior to the
date set for hearing. Any such
written objection must contain a
concise and thorough account of
the facts upon which the objec-
tion is based.
Dated this 22nd day of July, 2020.
/s/Laura Wheeles
Laura Wheeles (#09319)
Boppre Law Firm, PLLC
2151 36th Ave. SW, Suite B
Minot, ND 58701
Office: 701-852-5224
Fax: 701-852-5229
lwheeles@bopprelawfirm.com
Attorney for the Personal
Representative
(July 27; August 3-10, 2020)
Notice of Public Hearing
A public hearing of an application by
Penny Knutson for a variance will be
held during the Ward County Plan-
ning Commission meeting on Thurs-
day, August 20, 2020 at 7:00 pm in
Room 106 & 108 of the Ward Coun-
ty Administration Building.
The purpose of the request relief of
right of way dedication on an outlot
plat on the following described pro-
perty:
Sublot F being a portion of Outlot
4 13-154-82
Persons wishing to be heard on the
proposed variance will have the op-
portunity to address the Planning
Commission during the hearing. In-
formation and input may also be
presented in writing by addressing
the Ward County Planning Com-
mission, PO Box 5005, Minot, ND
58702-5005. All written materials
must reach the Planning Commis-
sion before the end of the hearing.
The text of the application is avail-
able for public inspection in the of-
fice of the Ward County Planning
and Zoning Administrator at the
Ward County Highway Administra-
tive Building during regular business
hours.
By orders of the Ward County Plan-
ning Commission, this 24day of July,
2020.
Doug Diedrichsen
Ward County Planning and Zoning
Administrator
(August 3, 2020)
NOTICE OF REAL ESTATE SALE
CIVIL NUMBER: 51-2019-CV-00243
IN THE STATE OF NORTH
DAKOTA, COUNTY OF WARD IN
THE DISTRICT COURT, NORTH
CENTRAL JUDICIAL DISTRICT
USAA Federal Savings Bank,
Plaintiff,
v.
Raymond E. Dill and Nichole Mack,
and any person in possession, and
all persons unknown, claiming any
estate or interest in, or lien or en-
cumbrance upon, the real estate
described in the complaint,
Defendants.
1. Judgment in the amount of
$282,117.60, having been entered in
favor of Plaintiff and against Defen-
dants, which Judgment was filed
with the Clerk of Courts of Ward
County, North Dakota, on October
25, 2019, for the foreclosure of a
real estate mortgage.
2. Notice is hereby given pursuant to
said Judgment that the real property
described in the Mortgage dated
May 14, 2013, which Mortgagors,
Raymond E. Dill, Nichole Mack, exe-
cuted and delivered to Mortgage
Electronic Registration Systems,
Inc., as Mortgagee, as nominee for
USAA Federal Savings Bank, its
successors and assigns.
Lot 1, Block 1, Heidrich Homes
1st Addition to the City of Minot,
Ward County, North Dakota.
3500 13th Street Northeast, Minot,
ND 58703
and recorded in the office of the
Clerk and Recorder of Ward County,
North Dakota, on May 17, 2013, In-
strument Number 2958101. Said
Mortgage was assigned to Plaintiff,
its successors or assigns, by As-
signment of Mortgage recorded De-
cember 26, 2018, Instrument
Number 3024519.
3. In order to realize the amount of
$282,117.60, as of October 25,
2019, plus interest accruing
thereafter on said amount at the rate
of 3.25000% per year together with
the costs and expenses of sale, will
be sold subject to redemption as
provided by law as one parcel of
land at public auction, subject to the
lien for unpaid real estate taxes and
assessments of Ward County, North
Dakota, and easements and restric-
tions of record, to the highest bidder
for cash under the direction of the
Sheriff of Ward County, North Dako-
ta, at the main entrance of the Ward
County Courthouse located at 315
SE 3rd Street, Minot, North Dakota
58701, on September 23, 2020
(“Sale Date”), at 10:00 AM.
4. If the sale is set aside for reason,
the Purchaser at the sale shall be
entitled only to a return of the depo-
sit paid. The purchaser shall have
no further recourse against the Mort-
gagor, the Mortgagee or the
Mortgagee’s attorney.
DATED this 29th day of July, 2020.
SHERIFF OF WARD COUNTY
For: /s/ Robert Roed
By: /s/ Jamie Williams
Sheriff/ Deputy Sheriff of Ward
Halliday, Watkins & Mann, P.C.
By: /s/ Benjamin J. Mann
Benjamin J. Mann
Attorneys for Plaintiff
376 East 400 South, Suite 300
Salt Lake City, UT 84111
8001-355-2886
Email: benjamin@hwmlawfirm.com
Bar: 08371
(August 3-10-17, 2020)
NOTICE TO CREDITORS
Case No. 51-2020-PR-00128
IN THE DISTRICT COURT OF
WARD COUNTY, STATE OF
NORTH DAKOTA
In the Matter of the Estate of
James Anton Duchsherer, a/k/a Jim
Duchsherer, Deceased.
NOTICE IS HEREBY GIVEN that
the undersigned have been appoint-
ed co-personal representatives of
the above estate. All persons having
claims against the said deceased
are required to present their claims
within three (3) months after the date
of the first publication or mailing of
this notice or said claims will be for-
ever barred. Claims must either be
presented to James B. Duchsherer
and Judy A. Duchsherer,
co-personal representatives of the
above-named estate, in care of
Louser & Zent, P.C., Town & Coun-
try Center, 1015 South Broadway,
Suite 15, Minot, North Dakota
58701, or filed with the Court.
Dated this 16th day of July, 2020.
/s/James B. Duchsherer
600 19th Street Northwest
Minot, ND 58701
/s/Judy A. Duchsherer
1521 Fourth Street Southwest
Minot, ND 58701
Brenda M. Zent (ID #04300)
LOUSER & ZENT, P.C.
Town & Country Center
1015 South Broadway – Suite 15
Minot, ND 58701
Telephone No. (701) 837-4846
Attorneys for the Co-Personal
Representatives
(July 27; August 3-10, 2020)
NOTICE TO CREDITORS
Probate No. 51-2020-PR-00135
IN THE DISTRICT COURT OF
WARD COUNTY, STATE OF
NORTH DAKOTA
In the Matter of the Estate of
WANDA D. BORGEN,
Deceased.
NOTICE IS HEREBY GIVEN that
the undersigned has been appointed
personal representative of the above
estate. All persons having claims
against the said deceased are re-
quired to present their claims within
three months after the date of the
first publication or mailing of this no-
tice or said claims will be forever
barred. Claims must either be
presented to BYRON J. BORGEN,
Personal Representative of the
estate, at 2525 Elk Drive, P.O. Box
1000, Minot ND 58702-1000, or filed
with the Court.
Dated this 27th day of July, 2020.
/s/Byron J. Borgen
Byron J. Borgen
Debra L. Hoffarth – #05668
PRINGLE & HERIGSTAD, P.C.
2525 Elk Drive
P.O. Box 1000
Minot, ND 58702-1000
dhoffarth@pringlend.com
Attorneys for: Personal
Representative
(August 3-10-17, 2020)
Request for Bid
The Fort Berthold Housing Authority
is requesting bids for 8 foundations
to be built on the Fort Berthold Indi-
an reservation. Bids will include
demolition, partial excavation, water
and sewer stub-in, forms, footings,
poured footing wall, rebar, sealing,
insulation, drain tile, sump pit, sill
plate and backfill. Deadline for bids
will be August, 2020. For more de-
tailed information please contact
FBHA.
CONTACT: FOREST MANDAN
Cell: 701-421-7272
Office: 701-627-4731 Ext 228
Email: forest@fbha.org
CONTACT: Toni Parisien
Cell: 701-421-0479
Office: 701-627-4731 Ext 240
Email: tonip@fbha.org
FBHA has the right to reject any and
all proposals and/or solicitations
(August 1-3-4-5-6-7-8-10-11-
12-13-14-15-17-18-19-20, 2020)
SUMMONS
Civil No. 51-2020-CV-00933
IN DISTRICT COURT, WARD
COUNTY, NORTH DAKOTA
The Industrial Commission of North
Dakota, acting as the North Dakota
Housing Finance Agency,
Plaintiff,
vs.
Glenn Hanson, a single man, de-
ceased; and all persons unknown,
claiming any estate or interest in, or
lien or encumbrance upon, the real
estate described in the compliant;
Defendants.
THE STATE OF NORTH DAKOTA
TO THE ABOVE-NAMED DEFEN-
DANTS:
YOU ARE HEREBY summoned to
answer the Complaint of the Plaintiff
which is herewith served upon you
and which will be filed in the office of
the Clerk of District Court of Ward
County, North Dakota, and to serve
a copy of your answer thereto on the
undersigned at her office at 720
Main Avenue, in the City of Fargo,
County of Cass, State of North
Dakota, within twenty one (21) days
after service of this Summons upon
you, exclusive of the date of service,
and in case of your failure to appear
or answer as above directed, judg-
ment will be taken against you by
default for the relief demanded in the
Complaint herein.
MORTGAGOR IS NOTIFIED
FURTHER that this is a communi-
cation from a debt collector and this
is an attempt to collect a debt. Any
information obtained will be used for
that purpose.
Dated at Fargo, North Dakota, this
8th day of July, 2020.
/s/ Sarah A. Aaberg
Sarah A. Aaberg (ND ID #08393)
Special Assistant Attorney General
for the Industrial Commission of
North Dakota acting as the North
Dakota Housing Finance Agency
Attorney for Plaintiff
720 Main Avenue
Fargo, North Dakota 58103
701.235.8000
sarah@okeeffeattorneys.com
This action relates to the foreclosure
of a real estate mortgage owned by
above-named Plaintiff upon the fol-
lowing described property situated in
the County of Ward, State of North
Dakota, to-wit:
North 120 feet of Lot 34, Hecker’s
Addition to the City of Minot,
Ward County, North Dakota.
Parcel ID Number:
M1241450000341
(Street Address: 614 Valley Street,
Minot, ND 58701)
/s/ Sarah A. Aaberg
Sarah A. Aaberg (ND ID #08393)
Special Assistant Attorney General
for the Industrial Commission of
North Dakota acting as the North
Dakota Housing Finance Agency
Attorney for Plaintiff
720 Main Avenue
Fargo, North Dakota 58103
701.235.8000
sarah@okeeffeattorneys.com
(July 27; August 3-10, 2020)