Legal Notices 1-14
ADVERTISEMENT FOR BIDS
CITY OF MINOT, NORTH DAKOTA
2022 NUSIANCE ABATEMENT
CITY PROJECT 4671
NOTICE IS HEREBY GIVEN that
the City of Minot (Owner) is re-
questing Bids for the construction of
the following Project:2022 Nuisance
Abatement
Bids for the construction of the Pro-
ject will be received at theoffice of
the City Clerk located at 515 Second
Avenue SW (Second Floor), Minot,
North Dakota 58701, until Tuesday,
February 1, 2022 at 11:00am local
time. At that time the Bids received
will be publicly opened and read.
The Project includes the following
Work:Inert Debris Removal per
TON, Individual Landfill Items per
EA, and other associated items.
Complete digital project bidding do-
cuments are available at
www.questcdn.com. You may down-
load the digital plan documents for
$40by inputting eBidDoc
#8098740on the website’s Project
Search page. Please contact
QuestCDN.com at 952-233-1632 or
info@questcdn.com for assistance
in free membership registration,
downloading, and working with this
digital project information. Project
bidding documents are also avail-
able at the Issuing Office – City of
Minot Engineering Department 1025
31st St SE and are available for pur-
chase for $75. Potential bidders may
contact the Assistant City Engineer
at 701-857-4100 with any questions.
Each bid must be accompanied by a
separate envelope containing the
bid security in a sum equal to five
percent of the full amount of the bid
and must be in the form of a bidder’s
bond. A bidder’s bond must be exe-
cuted by the bidder as principal and
by a surety, conditioned that if the
principal’s bid is accepted and the
contract awarded to the principal,
the principal, within ten days after
notice of the award, shall execute a
contract in accordance with the
terms of the bid and the bid bond,
and any condition of the City of
Minot, as required by law. A counter-
signature of a bid bond is not re-
quired. If the City of Minot elects to
award a contract to the lowest
responsible bidder, and the lowest
responsible bidder does not execute
a contract within the ten days al-
lowed, the bidder’s bond must be
forfeited to the City of Minot and the
project awarded to the next lowest
responsible bidder.
Each bidder must possess a valid
North Dakota contractor’s license for
the full amount of their bid, as re-
quired by Section 43-07-07 of the
North Dakota Century Code. Each
bidder MUST enclose a copy of their
Contractor’s License or Certificate of
Renewal, issued by the North Dako-
ta Secretary of State, in their bid
bond envelope, and each license
must be valid and dated at least 10
days prior to the date set for bid
opening, as required under Section
43-07-12 of the North Dakota Centu-
ry Code.
No bid may be read or considered if
it does not fully comply with the re-
quirements of Section 48-01.2-05 of
the North Dakota Century Code, and
any deficient bid submitted will be
resealed and returned to the bidder
immediately.
All Bids submitted and all Work
completed must be as stipulated in
the Contract.
The City of Minot reserves the right
to hold all Bids for a period of 30
days after the date of the bid open-
ing, to reject any or all Bids and to
rebid the project until a satisfactory
bid is received, and to waive any in-
formality or irregularity in any Bid.
For all further requirements regard-
ing bid submittal, qualifications, pro-
cedures, and contract award, refer to
the Instructions to Bidders that are
included in the Bidding Documents.
By order of the City Council of the
City of Minot, North Dakota.
Owner: City of Minot
By: Mikayla McWilliams
Title: City Clerk
Date: January 7, 2022
(January 7-14-21, 2022)
ADVERTISEMENT FOR BIDS
CITY OF MINOT, NORTH DAKOTA
2022 PAVEMENT MARKINGS
CITY PROJECT 4628
NOTICE IS HEREBY GIVEN that
the City of Minot (Owner) is re-
questing Bids for the construction of
the following Project:2022 Pavement
Markings. Bids for the construction
of the Project will be received at
theoffice of the City Clerk located at
515 Second Avenue SW (Second
Floor), Minot, North Dakota 58701,
until Tuesday, February 1, 2022 at
11:00 AM local time. At that time the
Bids received will be publicly opened
and read. The Project includes the
following Work: Pavement Markings.
Complete digital project bidding do-
cuments are available at
www.questcdn.com. You may down-
load the digital plan documents for
$40by inputting eBidDoc #8102973
on the website’s Project Search
page. Please contact
QuestCDN.com at 952-233-1632 or
info@questcdn.com for assistance
in free membership registration,
downloading, and working with this
digital project information. Project
bidding documents are also avail-
able at the Issuing Office – City of
Minot Engineering Department 1025
31st St SE and are available for pur-
chase for $75. Potential bidders may
contact the Assistant City Engineer
at 701-857-4100 with any questions.
Each bid must be accompanied by a
separate envelope containing the
bid security in a sum equal to five
percent of the full amount of the bid
and must be in the form of a bidder’s
bond. A bidder’s bond must be exe-
cuted by the bidder as principal and
by a surety, conditioned that if the
principal’s bid is accepted and the
contract awarded to the principal,
the principal, within ten days after
notice of the award, shall execute a
contract in accordance with the
terms of the bid and the bid bond,
and any condition of the City of
Minot, as required by law. A counter-
signature of a bid bond is not re-
quired. If the City of Minot elects to
award a contract to the lowest
responsible bidder, and the lowest
responsible bidder does not execute
a contract within the ten days al-
lowed, the bidder’s bond must be
forfeited to the City of Minot and the
project awarded to the next lowest
responsible bidder. Each bidder
must possess a valid North Dakota
contractor’s license for the full
amount of their bid, as required by
Section 43-07-07 of the North Dako-
ta Century Code. Each bidder MUST
enclose a copy of their Contractor’s
License or Certificate of Renewal, is-
sued by the North Dakota Secretary
of State, in their bid bond envelope,
and each license must be valid and
dated at least 10 days prior to the
date set for bid opening, as required
under Section 43-07-12 of the North
Dakota Century Code. No bid may
be read or considered if it does not
fully comply with the requirements of
Section 48-01.2-05 of the North
Dakota Century Code, and any de-
ficient bid submitted will be resealed
and returned to the bidder immedi-
ately. All Bids submitted and all
Work completed must be as stipulat-
ed in the Agreement. The City of
Minot reserves the right to hold all
Bids for a period of 30 days after the
date of the bid opening, to reject any
or all Bids and to rebid the project
until a satisfactory bid is received,
and to waive any informality or irre-
gularity in any Bid. For all further re-
quirements regarding bid submittal,
qualifications, procedures, and con-
tract award, refer to the Instructions
to Bidders that are included in the
Bidding Documents. By order of the
City Council of the City of Minot,
North Dakota.
Owner:City of Minot
By:Mikayla McWilliams
Title:City Clerk
Date:January 7, 2022
(January 7-14-21, 2022)
ADVERTISEMENT FOR BIDS
SOURIS RIVER JOINT WATER
RESOURCES BOARD MOUSE
RIVER ENHANCED FLOOD
PROTECTION PROJECT PHASE
MI-5A, 4TH AVENUE NE LEVEE
EXTENSION
MINOT, WARD COUNTY, NORTH
DAKOTA
NOTICE IS HEREBY GIVEN that
the Souris River Joint Water
Resources Board will receive sealed
Bids for the construction of the
Mouse River Enhanced Flood Pro-
tection Project Phase MI-5, 4th Ave-
nue NE Levee Extension, at Minot
City Hall in the Council Chambers,
515 2nd Avenue Southwest, Minot,
North Dakota, 58702, until 11:00AM
CDT, February 16, 2022, at which
time all Bids will be publicly opened
and read aloud. All Bids must be
submitted, and all work shall be
done, in full and strict compliance
with the Plans and Specifications for
this Project. Complete digital project
bidding documents are available at
www.questcdn.com. You may down-
load the digital plan documents for
$100.00 by inputting Quest project
#8097075 on the website’s Project
Search page. Please contact
QuestCDN.com at (952) 233-1632
or info@questcdn.com for assis-
tance in a free membership registra-
tion, downloading, and working with
this digital project information. An
optional paper set of project docu-
ments is also available for a nonre-
fundable price of $500 per set. Make
checks payable to Houston En-
gineering, Inc. and send to 1401
21st Avenue North, Fargo, ND
58102. Potential bidders may con-
tact Bjorn Berg of Houston En-
gineering, Inc. at (701) 237-5065
with any questions. Copies of the
documents are available for viewing
at the following locations during nor-
mal business hours of 8:00 am to
4:30 pm, Monday through Friday,
excluding holidays:
Houston Engineering, Inc.
1401 21st Avenue North
Fargo, ND
Houston Engineering, Inc.
3900 13th Avenue SE
Minot, ND
A mandatory pre-bid conference for
interested bidders will be held on
January 26, 2022, from 9:00 AM
CDT until 10:30 AM CDT on Micro-
soft Teams, and will also be acces-
sible via a call-in conference line.
All bidders planning on attending the
meeting by Microsoft Teams or
conference line shall send an invite
request, via email, with the subject
“MI-5A Pre-Bid” to Bjorn Berg at
bberg@houstoneng.com prior to
Noon on January 25th, 2022.
Any companies/teams/joint ventures
planning to submit a bid are required
to have at least one representative
present at the pre-bid conference. In
general, the Work included in the
Project includes the labor, materials,
tools and equipment required to con-
struct MREFPP Phase MI-5A 4th
Avenue NE Levee Extension as fully
depicted in the Drawings and Project
Manual for the Project. The Project
is located within the City of Minot
and Ward County, North Dakota. All
Bids are to be submitted on the
basis of cash payment for the Work,
and are to be enclosed in a sealed
envelope addressed to the under-
signed Chairman, endorsed as re-
quired below. The bid security must
be in a sum equal to five percent
(5%) of the full amount of the Bid
and must be in the form of a bidder’s
bond. A bidder’s bond must be exe-
cuted by the bidder as principal and
by a surety, conditioned that if the
principal’s bid is accepted and the
contract awarded to the principal,
the principal, within ten days after
notice of the award, shall execute a
contract in accordance with the
terms of the Bid and the bid bond
and any condition of the governing
body. A countersignature of a bid
bond is not required. If a successful
bidder does not execute a contract
within the ten days allowed, the
bidder’s bond must be forfeited to
the governing body and the project
awarded to the next lowest responsi-
ble bidder. The bidder must be
licensed for the full amount of the
bid as required by Section 43-07-12
of the North Dakota Century Code.
The outside of the sealed envelope
containing the bid and other required
items shall be endorsed with the fol-
lowing verbiage:
1.”Souris River Joint Water
Resource Board, Mouse River
Enhanced Flood Protection Project,
Phase MI-5A 4th Avenue NE Levee
Extension”
2.The name of the person, firm, cor-
poration, or joint venture submitting
the Bid.
3.The Bidder’s Contractor’s License
or Contractor’s License Renewal
Number.
4.Acknowledgement of Addenda.
A copy of the Bid Bond and Bidder’s
Contractor’s License or Contractor’s
License Renewal shall be included a
separate envelope from the bid. No
Bid may be read or considered if it
does not fully comply with the re-
quirements of Section 48-01.2-05 of
the North Dakota Century Code.
Any deficient Bid received will be
resealed and returned to the Bidder
immediately. The Owner reserves
the right to hold all bids for 75 days,
to reject any or all Bids and to waive
any informality or irregularity in any
Bid and to accept the Bid deemed in
the best interest of the Owner. The
Owner reserves the right to rebid the
project until a satisfactory Bid is re-
ceived. The Work shall be substan-
tially complete by October 1, 2024.
All Work shall be complete and
ready for final payment in accor-
dance with the General Conditions
by May 1, 2025. Should the Contrac-
tor fail to complete its obligations
under the Contract within the time
required herein or within such extra
time as may have been granted by
formal extensions of time approved
by the Owner, there will be deducted
from any amount due to the Con-
tractor the sum of $5,000 per calen-
dar day (with no suspension for
winter work) for each and every
calendar day that the substantial or
final completion of the Work is de-
layed. The Contractor and its Surety
will be liable for any excess. Such
payment will be as and for liquidated
damages and not as a penalty.
By order of the Souris River Joint
Water Resources Board,
Dated this 14 Day of November,
2021
Souris River Joint Water Resources
Board
David Ashley, Chairman
(January 14-21-28; February 4,
2022)
NOTICE
Notification is given that Bremer
Bank, National Association, Lawson
Building, 372 St. Peter Street, St.
Paul, MN 55102, has filed an appli-
cation with the Office of the Comp-
troller of the Currency on January
10, 2022, as specified in 12 CFR 5
for permission to relocate a branch
office currently located at 20 1st
Street Southwest, Minot, ND 58701,
to its new location at 1615 36th Ave-
nue Southwest, Minot, ND 58701.
Any person desiring to comment on
this application may file comments
in writing with the Director of District
Licensing at 425 South Financial
Place, Suite 1700, Chicago, Illinois
6060 or CE.Licensing@
occ.treas.gov within 30 days of the
date of this publication.
(January 14, 2022)
NOTICE
Notification is given that Bremer
Bank, National Association, Lawson
Building, 372 St. Peter
Street, St. Paul, MN 55102, has filed
an application with the Office of the
Comptroller of the Currency on
January 10, 2022, as specified in 12
CFR 5 for permission to relocate a
branch office currently located at
925 31st Avenue Southwest, Minot,
ND 58701, to its new location at 15
South Broadway, Minot, ND 58701.
Any person desiring to comment on
this application may file comments
in writing with the Director of District
Licensing at 425 South Financial
Place, Suite 1700, Chicago, Illinois
6060 or CE.Licensing@
occ.treas.gov within 30 days of the
date of this publication.
(January 14, 2022)
Notice of Annual Meeting
Kenmare Rural Fire Protection Dis-
trict Annual Meeting, January 24,
2022 at 7:00 pm at the Kenmare
Fire Station (use West door). Elec-
tion of one officer, vote on mill levy
and any business brought before the
meeting. Please bring voter identifi-
cation. In case of inclement weath-
er, meeting will be held the following
Monday at the same time and place.
Everyone welcome.
Layne O’Neill
Secretary/Treasurer
(January 14, 2022)
NOTICE OF HEARING PETITION
FOR ADJUDICATION OF
INTESTACY, APPOINTMENT OF
PERSONAL REPRESENTATIVES
AND FOR DETERMINATION OF
HEIRS
Probate No. 51-2021-PR-00203
IN THE DISTRICT COURT OF
WARD COUNTY, STATE OF
NORTH DAKOTA
In the Matter of the Estate of
Lloyd Herbert Emmel, Deceased.
NOTICE IS HEREBY GIVEN that
Mitchel L. Emmel has filed herin a
Petition for adjudication of Intestacy,
Appointment of Personal Represen-
tative, and for Determination of Heirs
of the estate of Lloyd Herbert Em-
mel, deceased. Hearing has been
set upon said petition on the 16th
day of February, 2022 at 9:00
o’clock a.m., at the Courtroom of the
above-named Court in the City of
Minot, County of Ward, State of
North Dakota.
Dated january 4, 2022
/s/Mitchel L. Emmel
Mitchel L. Emmel, Petitioner
10665 59th Ave. NW
Kenmare, ND 58746
Peter B. Hankla (ID #04919)
McGEE, HANKLA & BAKES, P.C.
2400 E. Burdick Expy.,
P.O. Box 998
Minot, ND 58702-0998
(701) 852-2544
(January 7-14-21, 2022)
NOTICE OF REAL ESTATE SALE
CIVIL NUMBER: 51-2020-CV-01722
IN THE STATE OF NORTH
DAKOTA, COUNTY OF WARD
IN THE DISTRICT COURT, NORTH
CENTRAL JUDICIAL DISTRICT
Freedom Mortgage Corporation
Plaintiff,
v.
Jean P. Chegwidden; Michael
Chegwidden; Unknown Spouse of
Jean P. Chegwidden; Elda Evenson
Living Trust; Evenson Properties,
L.L.P.; Mitchell B. Evenson; Syn-
chrony Bank; any person in posses-
sion, and all persons unknown,
claiming any estate or interest in, or
lien or encumbrance upon, the real
estate described in the complaint;
any person in possession,
Defendants.
Judgment in the amount of
$232,530.89 having been entered in
favor of Plaintiff and against Defen-
dants, which Judgment was filed
with the Clerk of Courts of Ward
County, North Dakota, on November
1, 2021, for the foreclosure of a real
estate mortgage. Notice is hereby
given pursuant to said Judgment
that the real property described as:
Lot 2, Clock 3, Valli Hai Addition
to the City of Minot, Ward County
North Dakota. Real Property
address: 1209 12th St. NW, Minot,
ND 58703
The above real property is the sub-
ject of the Mortgage dated June 24,
2013, which Mortgagor, Jean P.
Chegwidden, executed and
delivered to Mortgage Electronic
Registration Systems, Inc., as Mort-
gagee, as nominee for Mortgage
Research Center, LLC DBA
Veterans United Home Loans, its
successors and assigns, and record-
ed in the office of the Clerk and
Recorder of Ward County, North
Dakota, on June 26, 2013, as Instru-
ment Number 2960023, which is
subject to the entered Judgment.
Said Mortgage was assigned to
Plaintiff, its successors or assigns,
by Assignment of Mortgage record-
ed May 28, 2021, Instrument
Number 3052902 MTGASS. In order
to realize the amount of
$232,530.89, as of November 1,
2021, plus interest accruing
thereafter on said amount at the rate
of 3.37500% per year together with
the costs and expenses of sale, will
be sold subject to redemption as
provided by law as one parcel of
land at public auction, subject to the
lien for unpaid real estate taxes and
assessments of Ward County, North
Dakota, and easements and restric-
tions of record, to the highest bidder
for cash under the direction of the
Sheriff of Ward County, North Dako-
ta, at the main entrance of the Ward
County Courthouse located at 315
3rd Street SE, Minot, North Dakota
58701, on February 9, 2022 (“Sale
Date”), at 10:00 AM. If the sale is set
aside for reason, the Purchaser at
the sale shall be entitled only to a re-
turn of the deposit paid. The pur-
chaser shall have no further
recourse against the Mortgagor, the
Mortgagee or the Mortgagee’s attor-
ney.
DATED this 3rd day of January
2022.
SHERIFF OF WARD COUNTY
For:Robert Roed
By:Jamie Williams
Sheriff/Deputy Sheriff of Ward
Halliday, Watkins & Mann, P.C.
By:Zachary Nesbit
Zachary Nesbit
Attorneys for Plaintiff
376 East 400 South, Suite 300
Salt Lake City, UT 84111
Tel: 801-355-2886
Email: zach@hwmlawfirm.com
Bar: 07552
(January 7-14-21, 2022)
N O T I C E T O B I D D E R S
The City Clerk of the City of Minot
will receive sealed bids at her office
at City Hall until 11:00 a.m. on Tues-
day, January 25, 2022, for furnishing
the City of Minot the following:
“Remote Controlled 60” Rotary
Mower with Tracks”
Project #4638
Specifications and general instruc-
tions to bidders are available in the
Public Works Office at 1025 31st St
SE, on the City of Minot webpage
www.minotnd.orgunder City Clerk
department, or by calling
701-857-4140. The bid envelope
shall be plainly marked:
“Bid for One (1) RC Mower”
Project #4638
The City Council of the City of Minot
reserves the right to reject any or all
bids and to award the contract as it
deems to be in the best interest of
the City of Minot. Each bid must be
accompanied by a bidder’s bond, a
certified check, or a cashier’s check
in the amount of five percent (5%) of
the bid and must be in a separate
envelope marked “bid bond” and at-
tached to the outside of the bid.
Bidders are invited to be present at
the above-mentioned time and place
for the opening of bids.
Mikayla McWilliams
City Clerk
(January 7-14, 2021)
SECTION 00 01 11
ADVERTISEMENT FOR BIDS
SOURIS RIVER JOINT WATER
RESOURCES BOARD
MOUSE RIVER ENHANCED
FLOOD PROTECTION PROJECT
PHASE MI-5B.1, EQUIPMENT
STORAGE BUILDING
RELOCATION
MINOT, WARD COUNTY,
NORTH DAKOTA
NOTICE IS HEREBY GIVEN that
the Souris River Joint Water
Resources Board will receive sealed
Bids for the construction of the
Mouse River Enhanced Flood Pro-
tection Project Phase MI-5B.1,
Equipment Storage Building Reloca-
tion, at Minot City Hall in the Council
Chambers, 515 2nd Avenue
Southwest, Minot, North Dakota,
58702, until 10:00 AM CDT, January
31, 2022, at which time all Bids will
be publicly opened and read aloud.
All Bids must be submitted, and all
work shall be done, in full and strict
compliance with the Plans and
Specification for this Project. Com-
plete digital project bidding docu-
ments are available at
www.questcdn.com. You may down-
load the digital plan documents for
$100.00 by inputting Quest project
#8098185 on the website’s Project
Search page. Please contact
QuestCDN.com at (952) 233-1632
or info@questcdn.com for assis-
tance in a free membership registra-
tion, downloading, and working with
this digital project information. An
optional paper set of project docu-
ments is also available for a nonre-
fundable price of $500 per set.
Makes checks payable to Houston
Engineering, Inc. and send to 1401
21st Avenue North, Fargo, ND
58102. Potential bidders may con-
tact Rusten Roteliuk at Houston En-
gineering, Inc. at (701) 852-7931, or
by email at
rroteliuk@houstoneng.com, with any
questions. Copies of the documemts
are available for viewing at the fol-
lowing locations during normal busi-
ness hours of 8:00 am to 4:30 pm,
Monday through Friday, excluding
holidays:
Houston Engineering, Inc.
3900 13th Avenue SE
Minot, ND
Houston Engineering, Inc.
1401 21st Avenue North
Fargo, ND
A pre-Bid conference for interested
bidders will be held on January 13,
2022, from 10:00 AM CDT until
11:00 AM CDT. The conference will
be hosted in person at the office of
Houston Engineering at 3900 13th
Avenue SE, Minot, ND and on Mi-
crosoft Teams, and will also be ac-
cessible via a call-in conference line.
All bidders planning on attending
the meeting by Microsoft Teams
shall send an invite request, via
email, with the subject “MI-5B.1
Pre-Bid” to Rusten Roteliuk at
rroteliuk@houstoneng.com prior to
Noon on January 12th, 2022. The
Engineer will also be available, if re-
quested, to meet any prospective
bidders at the project site immedi-
ately following the pre-Bid meeting.
In general, the Work included in the
Project includes the labor, materials,
tools and equipment required to con-
struct MREFPP Phase MI-5B.1
Equipment Storage Building Relo-
cation as fully depicted in the Draw-
ings and Project Manual for the Pro-
ject. The Project is located within
the City of Minot, North Dakota.
All Bids are to be submitted on the
basis of cash payment for the Work,
and are to be enclosed in a sealed
envelope addressed to the under-
signed Chairman, endorsed as re-
quired below. The bid security must
be in a sum equal to five percent
(5%) of the full amount of the Bid
and must be in the form of a bidder’s
bond. A bidder’s bond must be exe-
cuted by the bidder as principal and
by a surety, conditioned that if the
principal’s bid is accepted and the
contract awarded to the principal,
the principal, within ten days after
notice of the award, shall execute a
contract in accordance with the
terms of the Bid and the bid bond
and any condition of the governing
body. A countersignature of a bid
bond is not required. If a successful
bidder does not execute a contract
within the ten days allowed, the
bidder’s bond must be forfeited to
the governing body and the project
awarded to the next lowest responsi-
ble bidder. The bidder must be
licensed for the full amount of the
bid as required by Section 43-07-12
of the North Dakota Century Code.
The outside of the sealed envelope
containing the bid and other required
items shall be endorsed with the fol-
lowing verbiage:
1.”Souris River Joint Water
Resource Board, Mouse River
Enhanced Flood Protection Project,
Phase MI-5B.1 Equipment Storage
Building Relocation”
2.The name of the person, firm, cor-
poration, or joint venture submitting
the Bid.
3.The Bidder’s Contractor’s License
or Contractor’s License Renewal
Number.
4.Acknowledgement of Addenda.
A copy of the Bid Bond and Bidder’s
Contractor’s License or Contractor’s
License Renewal shall be included a
separate envelope from the bid. No
Bid may be read or considered if it
does not fully comply with the re-
quirements of Section 48-01.2-05 of
the North Dakota Century Code. Any
deficient Bid received will be
resealed and returned to the Bidder
immediately. The Owner reserves
the right to hold all bids for 60 days,
to reject any or all Bids and to waive
any informality or irregularity in any
Bid and to accept the Bid deemed in
the best interest of the Owner. The
Owner reserves the right to rebid the
project until a satisfactory Bid is re-
ceived. All Work shall be complete
and ready for final payment in accor-
dance with the General Conditions
by July 1, 2022. Should the Contrac-
tor fail to complete its obligations
under the Contract within the time
required herein or within such extra
time as may have been granted by
formal extensions of time approved
by the Owner, there will be deducted
from any amount due to the Con-
tractor the sum of $500 per day (with
no suspension for winter work) for
each and every calendar day that
the substantial or final completion of
the Work is delayed. The Contractor
and its Surety will be liable for any
excess. Such payment will be as
and for liquidated damages and not
as a penalty. By order of the Souris
River Joint Water Resources Board,
Dated this 8th Day of December,
2021
Souris River Joint Water
Resources Board
David Ashley, Chairman
(January 7-14-21, 2022)