Legal Notices 3-24
ADVERTISEMENT FOR BID
Children’s Museum of Minot, Inc.
New Magic City Discovery Center
BP #2
Kraus-Anderson Construction Com-
pany is presently soliciting competi-
tive Lump Sum Bids for the
Children’s Museum of Minot, Inc. –
New Magic City Discovery Center,
Minot, ND – BP #2 (WS 3-A Con-
crete, WS 7-F Metal Panel, WS 7-L
Sealant, WS 9-G Resinous Flooring,
WS 12-B Window Treatments, WS
14-B Elevator). Sealed bids will be
received until 2:00 PM Central time
on Thursday, April 8th, 2021 at the
address noted below. Bids received
after this time will not be considered.
Bids will be publicly opened at 3:00
PM Central time on Thursday, April
8th, 2021 and publicly read aloud at
the following location: Minot Park
Community Room located in the Au-
ditorium at 420 3rd Ave SW, Minot,
ND 58701 and via Zoom.
Kraus-Anderson Construction Com-
pany is the only authorized agent to
receive bids.
Bids may be mailed or hand
delivered to:
Magic City Discovery Center
c/o Kraus-Anderson Construction
Company
Attn: Curt Janssen
615 South Broadway
Suite L2
Minot, ND 58701
The complete bid form shall be
without alterations, additions, or
erasures. All bids shall be on a lump
sum basis. No bid may be with-
drawn for a period of 60 days after
bid receipt without consent of the
Owner. Kraus-Anderson Construc-
tion Company reserves the right to
reject any or all bids and to waive
any irregularities in bids.
Direct all communications regarding
this Project to the office of the Con-
struction Manager: Curt Janssen
(curt.janssen@krausanderson.com)
(701) 989-7150.
Procurement of Documents for
bidders on prime contracts: Obtain
the bidding documents, including the
Bid Form, Drawings and Specifica-
tions, via iSqft.com. Plans can be
purchased by contacting Franz
Reprographics at (701) 258-5060. In
order to receive all addenda, please
request to be added to the distribu-
tion list by emailing linda.
house@krausanderson.com. Bid
Documents are also available thru
many of the regional builders’ ex-
changes.
(March 24-31; April 7, 2021)
ADVERTISEMENT FOR BIDS
Bids for the design of the new joint
Crosby Rural Fire Protection District
and Divide County Ambulance Dis-
trict Fire and EMS Hall:
The work will include designing a
new Fire and EMS Hall located
within the city limits of Crosby, North
Dakota.
Bids must be received no later than
5 p.m., April 1, 2021. Mailed bids
must be sent to Crosby Rural Fire
Proctection District Architect Bids,
P.O.Box 84, Crosby, ND, 58730.
1. The bids will be opened at the
Crosby Rural Fire Protection District
above the Crosby City Hall on April
1, 2021 at 7:00 p.m.
2. That each bid must be accompa-
nied by a separate envelope con-
taining the contractor’s license and
bid security. The bid security must
be in a sum equal to five percent of
the full amount of the bid and must
be in the form of a bidder’s bond. A
bidder’s bond must be executed by
the bidder as principal and by a
surety, conditioned that if the
principal’s bid is accepted and the
contract awarded to the principal,
the principal, within ten days after
notice of the award, shall execute a
contract in accordance with the
terms of the bid and the bid bond
and any condition of the governing
body. A countersignature of a bid
bond is not required under this sec-
tion. If a successful bidder does not
execute a contract within the ten
days allowed, the bidder’s bond
must be forfeited to the governing
body and the project awarded to the
next lowest responsible bidder.
3. That a bidder, except a bidder on
a municipal, rural, and industrial wa-
ter supply project using funds pro-
vided under Public Law No. 99-294
[100 Stat. 426; 43 U.S.C. 390a],
must be licensed for the full amount
of the bid as required by section
43-07-12. For projects using funds
provided under Public Law No.
99-294 [100 Stat. 426; 43 U.S.C.
390a], the advertisement must state
that, unless a bidder obtains a
contractor’s license for the full
amount of its bid within twenty days
after it is determined the bidder is
the lowest responsible bidder, the
bid must be rejected and the con-
tract awarded to the next lowest
responsible bidder
4. That no bid may be read or con-
sidered if the bid does not fully com-
ply with the requirements of section
48-01.2 of the North Dakota Century
Code and that any deficient bid sub-
mitted must be resealed and re-
turned to the bidder immediately.
5. That the governing body reserves
the right to reject any and all bids
and rebid the project until a satis-
factory bid is received.
6. This project is a time sensitive
project and therefore will require a
projected completion date. The
Crosby Rural Fire Protection District
would like this project to be complet-
ed by November 30, 2021.
7.The bidder will also be required to
provide proof of insurance.
(March 19-20-22-23-24-25-26-
27-29-30-31; April 1, 2021)
CALL FOR BIDS
Harrison Township will accept bids
for year-round road maintenance in-
cluding blading, plowing, mowing,
sanding & other maintenance as
needed. Written and sealed bids
should be submitted to: Harrison
Township Clerk at 4520 46 St NW,
Minot, ND 58703, and are due April
15, 2021. Harrison Township
reserves the right to refuse any and
all bids. Bids not submitted properly
will not be considered.
(March 24-25-26-27-29-30-31, 2021)
NOTICE
Burlington Planning Commission will
hold a public hearing Mar. 30, 2021
at 5:00pm at Burlington City Hall,
225 N Wallace Street. The following
public hearings will be opened: Di-
viding lots for Michael & Angela
Christianson- The NW 57′ of Lot 17
and all of Lot 18,25& 26, Parkway
1st Addition to the City of Burlington,
Ward Co, ND located in the City of
Burlington. This property will be
street right of way and easement for
public use.
Mary Lynn Brooks, Auditor
(March 17-24, 2021)
NOTICE
Effective immediately Harrison
Township will conduct meetings on
the second Tuesday in May, July,
Sept, Nov, Jan and Mar. All meet-
ings will begin at 6:30 pm at the
Minot Rural Fire Dept, 400 31st Ave
SW, Minot, ND 58701.
Cindy Whitesell
Harrison Township Clerk
(March 24-25-26-27-29-30-31, 2021)
NOTICE
Located at Ole Olson’s Towing 420
41st St SE, Minot 701-852-2525.
The owner, lien holder and second
parties have the right to reclaim said
vehicle; failure to reclaim said vehi-
cle will be deemed a waiver of all
rights, title, and interest in the vehi-
cle consenting to the disposal of the
vehicle pursuant to North Dakota
Century Code Chapter 39-26-08.
Location and Date of Impound incl
2003 Chevy Tahoe
1GNEC13T63J248428
1612 20th Ave NW 02/04/21
(March 24, 2021)
NOTICE OF HEARING OF
PETITION FOR FORMAL
PROBATE OF WILL AND
APPOINTMENT OF PERSONAL
REPRESENTATIVE
Probate No. 51-2021-PR-00055
In the matter of the estate of James
R. Dougall, deceased.
In The District Court for Ward
County, State of North Dakota
(Formal Proceeding)
[1] NOTICE IS HEREBY GIVEN,
that David J. Dougall has filed herein
a petition for formal probate of will
and appointment of petitioner as
Personal Representative.
[2] Hearing has been set upon said
petition on the 19th day of April,
2021, at 9:00 a.m. (local time), at the
courtroom of said Court at the Ward
County Courthouse at 315 3rd St
SE, Minot, County of Ward, State of
North Dakota, and any person in-
terested may appear and contest the
said will and may object to the ap-
pointment of petitioner as Personal
Representative.
Dated this 11th day of March, 2021.
/s/William C. Black
William C. Black (ID 07284)
Larson Latham Huettl LLP
1100 College Drive
PO Box 2056
Bismarck ND 58502
(701) 223-5300
William C. Black (07284)
wblack@bismarcklaw.com
(March 17-24-31, 2021)
NOTICE OF PETITION FOR NAME
CHANGE
IN DISTRICT COURT, WARD
COUNTY, NORTH DAKOTA
In the Matter of the Petition for
Name Change of Brittany Rose
Dewey.
PLEASE TAKE NOTICE that a Peti-
tion in the above-entitled matter will
be filed with the Clerk of District
Court for Ward County, North Dako-
ta, requesting an Order changing the
name of Brittany Rose Dewey
(current full, legal name) to Robin
Bryce Allister (requested full, legal
name).
Pursuant to N.D.C.C. 32-28-02, thir-
ty days previous notice of the in-
tended application must be given in
the official newspaper printed in this
county. You are hereby notified that
thirty days after publication, peti-
tioner intends to file a petition re-
questing entry of the Court’s Order
changing the name of Brittany Rose
Dewey(current full, legal name) to
Robin Bryce Allistar (requested full,
legal name). Any objection to grant-
ing this name change must be given
in writing to the address listed below
within 30 days of the date of this
publication. The written objection
must also be filed with the Court. If
no objections are given, the Court
may respond to the Petition without
further hearing.
Dated this 17th day of March, 2021.
/s/ Brittany Rose Dewey
Brittany Rose Dewey
1008 11th St. NW Apt. 7B
Minot, ND 58703
(March 24, 2021)
NOTICE OF SALE
Case No. 51-2020-CV-01651
IN DISTRICT COURT, NORTH
CENTRAL JUDICIAL DISTRICT,
STATE OF NORTH DAKOTA,
COUNTY OF WARD
Capital Credit Union,
Plaintiff,
v.
Hotel Ventures, LLC,
Defendant.
NOTICE IS HEREBY GIVEN that by
virtue of a Judgment and decree in
foreclosure, rendered by the District
Court of the North Central Judicial
District, in and for the County of
Ward, State of North Dakota, and
entered and docketed in the office of
the Clerk of the District Court, in and
for said County, on the 11th day of
February, 2021, in an action wherein
Capital Credit Union was Plaintiff,
and Hotel Ventures, LLC was Defen-
dant, in favor of the Plaintiff and
against the Defendant for the sum of
$2,622,223.69, as of December 23,
2020, plus interest at the rate of
$294.705479, per day for actual
Judgment amount of $2,636,958.96,
plus interest on the judgment
amount according to North Dakota
law, plus costs and expenses of the
sale, which Judgment and decree,
among other things, directs the sale
of the real estate hereinafter
described, and by virtue of a writ is-
sued to me by the Clerk of said
Court, in and for Ward County, and
under the seal of said Court, direct-
ing me to sell said real property, pur-
suant to said Judgment and decree,
I, Robert Roed, Sheriff of Ward
County will sell the hereinafter
described real estate to the highest
bidder for cash, at public auction at
the front door of the courthouse in
the City of Minot, Ward County,
North Dakota, on the 21st day of
April, 2021, at 10:00 a.m. of that
day, to satisfy the said Judgment
with interest and costs thereon, and
the costs and expenses of such
sale, or so much thereof as the
proceeds of such sale applicable
thereto will satisfy.
The premises to be sold pursuant to
said Judgment and decree and to
said writ and to this notice, are
described in said Judgment, decree
and writ as follows:
Lot 2 of Southgate Addition to the
City of Minot, North Dakota, being
outlot 9, Section 35, Township 155
North, Range 83 West, Ward Coun-
ty, ND
Commonly referred to as 1609 35th
Ave. SW, Minot, North Dakota
58701.
Dated this 18th day of March, 2021.
For: Robert Roed, Sheriff of Ward
County
/s/Jamie Williams
Lt. Jamie Williams
(March 24-31; April 7, 2021)
NOTICE TO CREDITORS
Probate No. 51-2021-PR-47
IN THE DISTRICT COURT,
STATE OF NORTH DAKOTA,
COUNTY OF WARD, NORTH
CENTRAL JUDICIAL DISTRICT
In the Matter of the Estate of
Roger L. Backes, Deceased.
NOTICE IS HEREBY GIVEN that
Brian Backes has been appointed
personal representative of the Estate
of Roger L. Backes. All persons hav-
ing claims against Roger L. Backes
are required to present their claims
within three (3) months after the date
of the first publication of this notice
or said claims will be forever barred.
Claims must either be presented to
Brian Backes, personal representa-
tive of the estate, at P.O. Box 998,
Minot, ND 58702-0998, or filed with
the Court.
Dated this 5th day of March, 2021.
/s/ Brian Backes
Brian Backes,
Personal Representative
(March 10-17-24, 2021)
NOTICE TO PROPOSERS
The City of Minot (herein after re-
ferred to as the “City” or “Airport”) is
issuing this Request for Proposals
(“RFP”) for qualified operators to
provide Airport Parking Management
Services for the parking facilities at
the Minot International Airport
(herein after referred to as “MOT”).
Sealed proposals shall be submitted
to the following:
City Clerk
City of Minot
515 2nd Ave. SW
Minot, ND 68702
Proposals MUST be received on or
before April 21, 2021 3:00 PM CDT.
There will be no public opening of
the proposals received. All Propo-
sals must be submitted in sealed en-
velopes and marked on the outside
of the envelope as follows:
REQUEST FOR PROPOSALS
AIRPORT PARKING FACILITIES
MANAGEMENT SERVICES
AGREEMENT
FOR THE MINOT
INTERNATIONAL AIRPORT
“DO NOT OPEN”
Any proposals received after the
time and date stated above will be
returned unopened and not con-
sidered as responsive. For more in-
formation, please visit www.minotnd.
org/Bids or www.motairport.com/
Bids.
A MANDATORY Pre-Proposal
Conference will be held March 31,
2021 at 10:00 AM CDT in the Airport
Conference Room located on the
second floor of the passenger termi-
nal at the Minot International Airport
or through a video link. A link will be
sent prior to the meeting to all par-
ties who request a copy of the RFP
All prospective proposers must have
a representative in attendance either
at the Airport or on the video call in
order to qualify to have a proposal
considered responsive. Once the
RFP is distributed, all written and/or
verbal communication regarding the
RFP must be directed to:
John DeCoster
Phone: (763) 234-1725
e-mail:john.decoster@landrumbrow
n.com
(March 17-24, 2021)
School Annexation Hearing
Notice is given that a public hearing
will be held by the Ward County
School District Reorganization Com-
mittee, Wednesday, April 14th, 2021
at 1:00 PM in the Commissioners’
Chambers, Ward County Adminis-
tration Building, Minot, North Dako-
ta, for the purpose of considering a
petition for annexing a territory to
Minot School District from the
Nedrose School District. Both
School Districts are located primarily
in Ward County.
The Petition describes the territory
to be annexed as the following:
Section 31: Woodside 15th Addition;
Lot 6; Block 1 of Nedrose Township
155 North-82 West of Ward County,
North Dakota
Section 31: Woodside 8th Addition;
Lot 6; Block 2 of Nedrose Township
155 North-82 West of Ward County,
North Dakota
Section 31: Woodside 8th Addition;
Lot 7; Block 2 of Nedrose Township
155 North-82 West of Ward County,
North Dakota
Section 31: Woodside 8th Addition;
Lot 2; Block 1 of Nedrose Township
155 North-82 West of Ward County,
North Dakota
This hearing is held in accordance
with the North Dakota Century
School Code Chapter 15.1-12 and
by order of the Ward School District
Reorganization Committee
Jodi Johnson, Ward County Super-
intendent of Schools
(March 24-31, 2021)