Legal Notices 3-23
ADVERTISEMENT FOR BIDS
Bids for the design of the new joint
Crosby Rural Fire Protection District
and Divide County Ambulance Dis-
trict Fire and EMS Hall:
The work will include designing a
new Fire and EMS Hall located
within the city limits of Crosby, North
Dakota.
Bids must be received no later than
5 p.m., April 1, 2021. Mailed bids
must be sent to Crosby Rural Fire
Proctection District Architect Bids,
P.O.Box 84, Crosby, ND, 58730.
1. The bids will be opened at the
Crosby Rural Fire Protection District
above the Crosby City Hall on April
1, 2021 at 7:00 p.m.
2. That each bid must be accompa-
nied by a separate envelope con-
taining the contractor’s license and
bid security. The bid security must
be in a sum equal to five percent of
the full amount of the bid and must
be in the form of a bidder’s bond. A
bidder’s bond must be executed by
the bidder as principal and by a
surety, conditioned that if the
principal’s bid is accepted and the
contract awarded to the principal,
the principal, within ten days after
notice of the award, shall execute a
contract in accordance with the
terms of the bid and the bid bond
and any condition of the governing
body. A countersignature of a bid
bond is not required under this sec-
tion. If a successful bidder does not
execute a contract within the ten
days allowed, the bidder’s bond
must be forfeited to the governing
body and the project awarded to the
next lowest responsible bidder.
3. That a bidder, except a bidder on
a municipal, rural, and industrial wa-
ter supply project using funds pro-
vided under Public Law No. 99-294
[100 Stat. 426; 43 U.S.C. 390a],
must be licensed for the full amount
of the bid as required by section
43-07-12. For projects using funds
provided under Public Law No.
99-294 [100 Stat. 426; 43 U.S.C.
390a], the advertisement must state
that, unless a bidder obtains a
contractor’s license for the full
amount of its bid within twenty days
after it is determined the bidder is
the lowest responsible bidder, the
bid must be rejected and the con-
tract awarded to the next lowest
responsible bidder
4. That no bid may be read or con-
sidered if the bid does not fully com-
ply with the requirements of section
48-01.2 of the North Dakota Century
Code and that any deficient bid sub-
mitted must be resealed and re-
turned to the bidder immediately.
5. That the governing body reserves
the right to reject any and all bids
and rebid the project until a satis-
factory bid is received.
6. This project is a time sensitive
project and therefore will require a
projected completion date. The
Crosby Rural Fire Protection District
would like this project to be complet-
ed by November 30, 2021.
7.The bidder will also be required to
provide proof of insurance.
(March 19-20-22-23-24-25-26-
27-29-30-31; April 1, 2021)
INVITATION TO BID
PROJECT. Infection Control / Pan-
demic Preparedness Unit
BIDS CLOSE. Tuesday, April 6th,
2021 2:00 PM CST
EAPC PROJECT #. 20202030
DATE OF ISSUE. March 5th, 2021
BY. EAPC Architects Engineers
300 3rd Ave SW Suite A
Minot, ND 58701
PHONE: (701) 839-4547
OUTLINE OF PROJECT.
A 9,500 SF addition to the existing
Mountrail County Health Center with
a roof helipad. The one story addi-
tion will add a clinic space with
exam rooms and offices and an
operating room suite. Also included
a new entrance to the existing Emer-
gency room, an addition to the exist-
ing ambulance bay. and a partial
basement area for a mechanical
equipment room.
TYPE OF BIDS. Single combined
Bids will be received from qualified
Bidders for all portions of the work.
The successful Bidder will be the
single Prime Contractor for the Pro-
ject.
THE OWNER.
Mountrail County Medical Center
615 6th St SE
Stanley, ND 58784
BID PLACE.
Mountrail County Medical Center
Executive Conference Room
615 6th St SE
Stanley, ND 58784
Bids received after the designated
time will not be accepted. All in-
terested parties are invited to attend.
Bids will be opened and publicly
read aloud. It is the Bidder’s respon-
sibility to see that mailed or
delivered Bids are in the hands of
the Owner prior to the time of the
Bid opening.
OBTAINING DOCUMENTS. Draw-
ings and Specifications may be ex-
amined at the Architect/Engineer’s
office, and the Owner’s office at the
address shown above and:
QuestCDN (www.questcdn.com)
CMD (Construction Market Data)
Dodge Plan Room and SCAN in
Minneapolis.
Minnesota Builders Exchanges at
Duluth, St. Cloud, Minnesota Build-
ers Exchange in Minneapolis.
North Dakota Builders Exchanges at
Bismarck, Dickinson, Fargo, Grand
Forks, Minot, Williston.
South Dakota Builders Exchanges at
Aberdeen, Plains Builders in Sioux
Falls, Rapid City,
Sioux Falls Builders Exchange.
Montana Builders Exchange at Bil-
lings.
If Contractor receives the bidding
documents from a plans exchange,
it is the Contractors responsibility to
contact EAPC Architects Engineers
to be added to the plan holders list.
Complete digital project bidding do-
cuments are available at www.
questcdn.com. You may download
the digital plan documents for
$15.00 by inputting Quest project
#7644676 on the website’s Project
Search page. Please contact
QuestCDN.com at 952-233-1632 or
info@questcdn.com for assistance
in free membership registration,
downloading, and working with this
digital project information.
An optional paper set of project do-
cuments is also available for a re-
fundable price of $125 per set from
EAPC Architects Engineers, 300 3rd
Ave SW, Suite A, Minot, ND 58701.
If the Bidder returns the set of docu-
ments, in good condition, within 10
days following the Bid Date, the
deposit will be refunded. If the
Bidder does not return the set of do-
cuments within the designated time,
none of the deposit will be refunded.
Please allow 2 days for printing.
Partial or complete sets of prints and
specifications may be obtained from
EAPC by other than the above. The
sets or partial sets will be distributed
upon receipt of payment for the in-
formation charged at the current
reproduction rate. None of this pay-
ment will be refunded. Complete-
ness and adequacy of the list of do-
cuments requested shall be the
responsibility of the person making
the request.
FEDERAL REGULATIONS. This
contract is Federally assisted. The
Contractor must comply with the
Davis- Bacon Act, the Anti- Kickback
Act, and the Contract Work Hours
Standards. Contracts for work under
this bid will obligate the Contractor
and Subcontractors not to discrim-
inate in employment practices.
Bidders must submit a compliance
report in conformity with the
President’s Executive Order No.
11246.
BID SECURITY. Bid Security in the
amount of five (5%) percent of the
Bid including all add alternates, must
accompany each Bid in accord with
00 1000 – Instructions to Bidders.
Bidders Bond, cashier’s checks or
certified checks will beaccepted.
NORTH DAKOTA LAW. All bidders
must be licensed for the highest
amount of their bids, as provided by
North Dakota Century Code Section
43-07-05; and no bid will be read or
considered which does not fully
comply with the above provisions as
to bond and licenses, and any bid
deficient in these respects submitted
will be re-sealed and returned to the
bidder immediately.
PRE-BID MEETING. There will be a
meeting of prospective Bidders at
2:00 PM, March 22, 2021 at Moun-
trail County Medical Center. We will
meet at the ER Entrance. All those
with questions for the Owner and
A/E are invited to attend.
Attendance by prospective Bidders
is not a mandatory prerequisite for
submitting a Bid for this project
BID SUBMISSION: Bids shall be
submitted to the person and place,
and by the time indicated in 00
02000 – Invitation to Bid. Bids shall
be packaged in accordance with 00
1000 – Instructions to Bidders.
THE OWNER reserves the right to
waive irregularities, to reject Bids
and to hold all Bids for a period of 30
days after the date fixed for the
opening thereof.
By order of: Steph Everett, CEO
(March 9-16-23, 2021)
NOTICE OF REAL ESTATE SALE
CIVIL NUMBER: 51-2018-CV-00127
IN THE STATE OF NORTH
DAKOTA, COUNTY OF WARD
IN THE DISTRICT COURT, NORTH
CENTRAL JUDICIAL DISTRICT
Reverse Mortgage Funding, LLC,
Plaintiff,
v.
Cheryl D. Lane; Heirs & Devisees of
the Estate of Cheryl D. Lane; United
States of America, acting by and
through the Secretary of Housing
and Urban Development; Unknown
Spouse of Cheryl D. Lane; Unknown
Spouse of Ruth Lane; any person in
possession, and all persons unk-
nown, claiming any estate or interest
in, or lien or encumbrance upon, the
real estate described in the com-
plaint,
Defendants.
1. Judgment in the amount of
$197,606.49, having been entered in
favor of Plaintiff and against Defen-
dants, which Judgment was filed
with the Clerk of Courts of Ward
County, North Dakota, on December
7, 2020, for the foreclosure of a real
estate mortgage.
2. Notice is hereby given pursuant to
said Judgment that the real property
described as:
The following described parcel of
land, and improvements and ap-
purtenances thereto in the County of
Ward, State of ND, to wit:
Countryside Villas, 3rd Addition Lot
2, Nedrose-S4 A 2
Together with: Used 2000 Bonnavil-
la 52 x 28 Manufactured Home Seri-
al No. NEB00A28052S.
MORE CORRECTLY DESCRIBED
AS FOLLOWS:
The following described parcel of
land, and improvements and ap-
purtenances thereto in the County of
Ward, State of ND, to wit:
Countryside Villas, 3rd Addition Lot
2, Nedrose-S4 A 2
Together with: Used 2000 Bonne-
ville 52 x 28 Manufactured Home
Serial No. NEB00A28052S.
With an address of 2105 55th Street
SE, Minot, ND 58701, and being the
subject of the Mortgage dated
February 13, 2015, which Mortga-
gor, Cheryl D. Lane, executed and
delivered to Mortgage Electronic
Registration Systems, Inc., as Mort-
gagee, as nominee for Reverse
Mortgage Funding LLC, its succes-
sors and assigns, and recorded in
the office of the Clerk and Recorder
of Ward County, North Dakota, on
March 2, 2015, Instrument Number
2983529, is subject to the entered
Judgment. Said Mortgage was as-
signed to Plaintiff, its successors or
assigns, by Assignment of Mortgage
recorded September 13, 2017, In-
strument Number 3012033.
3. In order to realize the amount of
$197,606.49, as of December 7,
2020, plus interest accruing
thereafter on said amount at the rate
of $9.97 per day together with the
costs and expenses of sale, the pro-
perty will be sold subject to redemp-
tion as provided by law as one par-
cel of land at public auction, subject
to any lien for unpaid real estate
taxes and assessments of Ward
County, North Dakota, and ease-
ments and restrictions of record, to
the highest bidder for cash under the
direction of the Sheriff of Ward
County, North Dakota, at the main
entrance of the Ward County Court-
house located at 315 SE 3rd Street,
Minot, North Dakota 58701, on April
28, 2021 (“Sale Date”), at 10:00 AM.
4. If the sale is set aside for reason,
the Purchaser at the sale shall be
entitled only to a return of the depo-
sit paid. The purchaser shall have
no further recourse against the Mort-
gagor, the Mortgagee or the
Mortgagee’s attorney.
DATED this 9th day of March, 2021.
For: Robert Roed
/s/Jamie Williams
Deputy Sheriff of Ward County
Halliday, Watkins & Mann, P.C.
/s/ Scott S. Skeen
Attorneys for Plaintiff
376 East 400 South, Suite 300
Salt Lake City, UT 84111
801-355-2886
Email: scott@hwmlawfirm.com
ND Bar No.: 09334
(March 16-23-30, 2021)
NOTICE OF REAL ESTATE SALE
CIVIL NUMBER: 51-2020-CV-01280
IN THE STATE OF NORTH
DAKOTA, COUNTY OF WARD
IN THE DISTRICT COURT, NORTH
CENTRAL JUDICIAL DISTRICT
Lakeview Loan Servicing, LLC,
Plaintiff,
v.
Shaun D. Welsch; Unknown Heirs
and Devisees of the Estate of Shaun
D. Welsch; any person in posses-
sion, and all persons unknown,
claiming any estate or interest in, or
lien or encumbrance upon, the real
estate described in the complaint,
Defendants.
1. Judgment in the amount of
$209,424.05, having been entered in
favor of Plaintiff and against Defen-
dants, which Judgment was filed
with the Clerk of Courts of Ward
County, North Dakota, on January
29, 2021, for the foreclosure of a
real estate mortgage.
2. Notice is hereby given pursuant to
said Judgment that the real property
described as:
Lot 15, Burlington Heights Addition
to the City of Burlington, Ward
County, North Dakota.
Real Property address:102 Soo
Street, Burlington, ND 58722
The above real property is the sub-
ject of the Mortgage dated June 28,
2017, which Mortgagor, Shaun D.
Welsch, executed and delivered to
Mortgage Electronic Registration
Systems, Inc., as Mortgagee, as
nominee for Rubicon Mortgage Advi-
sors, LLC, its successors and as-
signs, and recorded in the office of
the Clerk and Recorder of Ward
County, North Dakota, on June 29,
2017, Instrument Number 3009857,
which is subject to the entered Judg-
ment. Said Mortgage was assigned
to Plaintiff, its successors or as-
signs, by Assignment of Mortgage
recorded January 6, 2020, Instru-
ment Number 3035397.
3. In order to realize the amount of
$209,424.05, as of January 29,
2021, plus interest accruing
thereafter on said amount at the rate
of 4.25% per year together with the
costs and expenses of sale, the pro-
perty will be sold subject to redemp-
tion as provided by law as one par-
cel of land at public auction, subject
to any lien for unpaid real estate
taxes and assessments of Ward
County, North Dakota, and ease-
ments and restrictions of record, to
the highest bidder for cash under the
direction of the Sheriff of Ward
County, North Dakota, at the main
entrance of the Ward County Court-
house located at 315 SE 3rd Street,
Minot, North Dakota 58701, on April
28, 2021 (“Sale Date”), at 10:00 AM.
4. If the sale is set aside for reason,
the Purchaser at the sale shall be
entitled only to a return of the depo-
sit paid. The purchaser shall have
no further recourse against the Mort-
gagor, the Mortgagee or the
Mortgagee’s attorney.
DATED this 9th day of March, 2021.
For: Robert Roed
/s/Jamie Williams
Deputy Sheriff of Ward County
Halliday, Watkins & Mann, P.C.
/s/ Scott S. Skeen
Attorneys for Plaintiff
376 East 400 South, Suite 300
Salt Lake City, UT 84111
801-355-2886
Email: scott@hwmlawfirm.com
ND Bar No.: 09334
(March 16-23-30, 2021)
NOTICE TO CREDITORS
Probate No. 51-2021-PR-00025
IN THE DISTRICT COURT OF
WARD COUNTY, STATE OF
NORTH DAKOTA
In the Matter of the Estate of Dion
J. Palen, Deceased.
NOTICE IS HEREBY GIVEN that
Robert A Bohrer has been appointed
personal representative of the above
estate. All persons having claims
against Dion J. Palen are required to
present their claims within three (3)
months after the date of the first
publication or mailing of this notice
or said claims will be forever barred.
Claims must either be presented to
Robert A. Bohrer, personal
representative of the estate, at 2765
Highway 25, Mandan, ND 58554 or
filed with the Court. Dated this 17th
day of March, 2021.
/s/Robert A. Bohrer
Robert A. Bohrer,
Personal Representative
(March 23-30; April 6, 2021)
SUMMONS
Civil No. 51-2021-CV-00417
STATE OF NORTH DAKOTA,
COUNTY OF WARD, IN DISTRICT
COURT, NORTH CENTRAL
JUDICIAL DISTRICT
ProCollect Services, LLC,
Plaintiff,
vs.
Robert Clark,
Defendant.
THE STATE OF NORTH DAKOTA
TO THE ABOVE-NAMED DEFEN-
DANT:
YOU ARE HEREBY SUMMONED
and required to appear and defend
against the Complaint in this action,
which is herewith served upon you,
by serving on the undersigned an
Answer or other proper response
within twenty-one days after service
of this Summons upon you, ex-
clusive of the day of service. If you
fail to do so, judgment by default will
be taken against you for the relief
demanded in the complaint.
Dated March 11, 2021.
/s/Christopher A. Carlson
Chistopher A. Carlson (ID #03378)
PO Box 1097
Bismarck, North Dakota 58502-1097
701-258-4800
carlsonlaw@qwestoffice.net
Attorney for the Plaintiff
(March 16-23-30, 2021)
SUMMONS
Civil No. 51-2021-CV-00464
STATE OF NORTH DAKOTA,
COUNTY OF WARD, IN DISTRICT
COURT, NORTH CENTRAL
JUDICIAL DISTRICT
ProCollect Services, LLC,
Plaintiff,
vs.
Adelard and Paige Hoffarth,
Defendant.
THE STATE OF NORTH DAKOTA
TO THE ABOVE-NAMED DEFEN-
DANT:
YOU ARE HEREBY SUMMONED
and required to appear and defend
against the Complaint in this action,
which is herewith served upon you,
by serving on the undersigned an
Answer or other proper response
within twenty-one days after service
of this Summons upon you, ex-
clusive of the day of service. If you
fail to do so, judgment by default will
be taken against you for the relief
demanded in the complaint.
Dated March 18, 2021.
/s/Christopher A. Carlson
Chistopher A. Carlson (ID #03378)
PO Box 1097
Bismarck, North Dakota 58502-1097
701-258-4800
carlsonlaw@qwestoffice.net
Attorney for the Plaintiff
(March 23-30; April 6, 2021)