Legal Notices 9-18
ADVERTISEMENT FOR BIDS
Subject to conditions prescribed by
the Nueta Hidatsa Sahnish College,
sealed bids for a lump-sum contract
are invited for the following work:
modifying the existing fire alarm sys-
tem and adding additional devices
throughout the facility
Description of Work:
Install conduit and wire for new and
existing device locations as shown
on drawing provided by Nick
Semmler from Johnson Controls Inc.
Install new devices provided by JC!
as shown on drawing provided by
Nick Semmler from Johnson Con-
trols Inc. Remove existing devices in
place for new devices. Remove ca-
ble that will not work for new system
speaker strobes.
Install devices as follows:
Smoke Detectors – 128
Heat Detectors -60
Speaker Strobes – 25
Strobe -42
Hom/Strobe – I 0
Duct Detector – 16
Pull Station – 14
4009 Annunciator Panel
The quotation must include all labor,
necessary materials, and applicable
permits.
Procedures: Contractors can contact
the Maintenance and Facilities Su-
pervisor, Wes Davidson at
wdavid@nhsc.edu or call
701-421-1523 to schedule time to
procure a copy of the drawing from
Johnson Controls, Inc. for the bid.
Bids will be received only through
the mail addressed to: Dr. Jennifer
Janecek-Hartman, VP Campus Ser-
vices Nueta Hidatsa Sahnish Col-
lege PO Box 490 New Town ND
Bid Deadline: Sealed bids must be
received on or before 11 am, Friday,
September 25, 2020.
The successful Bidder will be re-
quired to have a North Dakota
current and active contractor’s
license and a Mandan Hidatsa Ari-
kara Nation TERO license at the
time of submission of the Bid. Every
effort will be made to ensure that all
persons have equal access to con-
tracts and other business opportun-
ities with NHSC within the limits im-
posed by law or NHSC policy. Each
Bidder may be required to show evi-
dence of its equal employment op-
portunity policy.
(September 14-15-16-17-18-
19-21-22-23-24, 2020)
ADVERTISEMENT FOR
CONSTRUCTION BIDS
Separate sealed Bids for construc-
tion of the Snake Creek Pumping
Plant Cable and XFMR Replace-
ment will be received at the office of
Garrison Diversion Conservancy
District, 401 Hwy 281 NE, Carring-
ton, ND 58421, until 2:00 p.m., local
time, on the 29th day of September,
2020, where and at which time they
will be publicly opened and read
aloud.
Bids can be mailed to:
“Snake Creek Pumping Plant Cable
and XFMR Replacement
Project Bid”
Garrison Diversion Conservancy
District
PO Box 140
Carrington, ND 58421
The scope of work will generally
consist of a lump sum bid for the re-
moval and replacement of over
9,000 feet of 15kV Rated Cable, the
installation of an 800A, 277/480V
Rated Generator Docking Station,
and the removal of two (2) 750kVA
Sealed CO2 Gas Insulated
Transformers. One of the removed
transformers will be replaced with
the noted generator docking station
while the other will be replaced with
a 750kVA Dry Type Transformer.
Bid Alternate No. 1 includes a lump
sum bid cost deduct for excluding
the removal of one (1) 750 kVA
Sealed CO2 Gas Insulated
Transformer and excluding the in-
stallation of one (1) 750 kVA Dry
Type Transformer from the Base
Bid. Only the Base Bid or the Base
Bid and Bid Alternate No. 1 will be
awarded:
Contract No. 1. – Electrical Con-
struction Base Bid: Work generally
includes mobilization, bonding, and
insurance; Removal and installation
of approximately 9,000 feet of 15kV
Rated Cable, the installation of an
800A, 277/480V Rated Generator
Docking Station, and the removal of
two (2) 750kVA Sealed CO2 Gas In-
sulated Transformers. One of the
removed transformers will be re-
placed with the noted generator
docking station while the other will
be replaced with a 750kVA Dry Type
Transformer. Work may also in-
clude electrical site work and con-
trols, and miscellaneous related con-
struction, equipment, and appurte-
nances.
Bid Alternate No. 1 to Contract
No. 1. – Electrical Transformer
Deduct: Excludes the removal of
one (1) 750 kVA Sealed CO2 Gas
Insulated Transformer and excludes
the installation of one (1) 750 kVA
Dry Type Transformer and all electri-
cal transformer associated work
from Contract No. 1 – Base Bid.
All Bids shall be prepared according
to the Instruction to Bidders con-
tained within the Project Manual. All
Bidders shall attend the MANDATO-
RY Pre-Bid walkthrough/conference
at the project site on September
22nd, 2020 at 2:00 pm. Each Bid
shall be accompanied by a
separate envelope containing a Bid
Security in the form of a Bidder’s
Bond executed by the Bidder as
principal and by a surety company
authorized to do business in the
State of North Dakota, payable to
the Garrison Diversion Conservancy
District, in a sum equal to five per-
cent (5%) of the full amount of the
Bid. This is to serve as a guarantee
that the successful Bidder will enter
into a Contract within fifteen (15)
days of Notice of Award, in accor-
dance with the terms of the
principal’s Bid and Contractor’s
Bond as required by law and regula-
tions and determinations of Garrison
Diversion Conservancy District, for
the performances of such Work.
Only Bids that are accompanied by
such a Bond will be considered. All
Work shall be performed in accor-
dance with the Bidding Documents
on file in the Office of Garrison
Diversion Conservancy District, Car-
rington, ND, where they may be
seen and examined. Bidders must
be licensed for the full amount of the
Bid as required by North Dakota
Century Code 43-07-12. Each Bid
shall contain a copy of the
Contractor’s license or certificate of
renewal thereof issued by the Secre-
tary of State. All Bids must be sub-
mitted on the Bid Form furnished by
the Engineer. No Bid will be read or
considered that does not fully com-
ply with the above provisions and
other provisions contained within the
Bidding Documents, and any defi-
cient Bid submitted will be returned
to the Bidder unopened. Contracts
shall be awarded on the basis of the
low Bid submitted by a responsible
and responsive Bidder deemed most
favorable to Garrison Diversion’s in-
terest. All Bids shall be contained in
a sealed envelope plainly marked
showing that such envelope con-
tains a Bid for the Project. In addi-
tion, the Bidder shall place upon the
exterior of such envelope the follow-
ing information:
1. Project Name and Work covered
by the Bidder (General).
2.The name of the Bidder.
3.Federal ID Number
4.Separate envelope containing Bid
Bond, a copy of Contractor’s
License or Renewal Certificate, and
proof of insurance.
5.Acknowledgement of all Addenda.
The Garrison Diversion Conservan-
cy District reserves the right to reject
any and all Bids, to waive any infor-
mality in any Bid, to hold all Bids for
a period not to exceed thirty (30)
days from the date of opening Bids,
and to accept the Bid deemed most
favorable to the interest of the Own-
er. After the Bid opening, the Owner
will return Bid Security of all except
the three lowest responsible
Bidders. When a Contract is award-
ed, the remaining unsuccessful
Bidder’s Bonds will be returned.
Complete digital project bidding do-
cuments, pursuant to which labor,
materials, or services must be fur-
nished, are available at
www.AE2S.com or www.questcdn
.com. You may download the digital
plan documents for Thirty Dollars
and No Cents ($30.00) by inputting
Quest project 7273534 on the
website’s Project Search page.
Please contact QuestCDN.com at
952-233-1632 or info@questcdn
.com for assistance in free member-
ship registration, downloading, and
working with this digital project infor-
mation. Copies of the Bidding Docu-
ments may also be seen and exam-
ined at the office of the Engineer,
Advanced Engineering and En-
vironmental Services, Inc., 4170
28th Ave S, Fargo, ND 58104. The
Bidding Documents are available in
the form of printed plans and specifi-
cations by request from Advanced
Engineering and Environmental Ser-
vices, Inc., 4170 28th Ave S, Fargo,
ND 58104. The cost is $350.00 for
printed documents, for each set of
Documents obtained. Payment for
Bidding Documents is
NON-REFUNDABLE. All Work
shall be done according to the Bid-
ding Documents. Bidding Docu-
ments may also be examined at the
following locations:
Plans and Specifications are on file
and may be seen and examined at
the following locations:
Advanced Engineering and Environ-
mental Services, Inc.
4170 28th Ave. S
Fargo, ND 58104
Bismarck-Mandan Builders Ex-
change
805 Adobe Trail SE
Mandan, ND 58554
Construction Plans Exchange
215 Airport Rd
Bismarck, ND 58504
Minot Builders Exchange
2424 Burdick Expwy E
Minot, ND 58701
Grand Forks Builders Exshange
3311 South Washington St.
Grand Forks, ND 58201
Fargo Builders Exchange
1010 Page Drive
Fargo, ND 58102
Dated this 3rd day of September
2020.
(September 11-18-25, 2020)
INVITATION TO BID
PROJECT. Broadway Circle
BIDS CLOSE. Tuesday, October 13,
2020 at 2PM CST
EAPC PROJECT #. 20204440
DATE OF ISSUE. September 18,
2020
BY. EAPC Architects Engineers
300 3rd Ave SW, Suite A
Minot, ND 58701
PHONE: (701) 839- 4547
OUTLINE OF PROJECT. Demoli-
tion of existing motels buildings at
1901 S Broadway Ave, Minot, North
Dakota.
TYPE OF BIDS. Single combined
Bids will be received from qualified
Bidders for all portions of the work.
The successful Bidder will be the
single Prime Contractor for the Pro-
ject.
THE OWNER.
Lutheran Social Services of North
Dakota
412 DeMers Ave
Grand Forks, ND 58201
BID PLACE.
EAPC Architects Engineers
300 3rd Ave SW, Suite A
Minot, ND 58701
Bids received after the designated
time will not be accepted. All in-
terested parties are invited to attend.
Bids will be opened and publicly
read aloud. It is the Bidder’s respon-
sibility to see that mailed or
delivered Bids are in the hands of
the Owner prior to the time of the
Bid opening.
OBTAINING DOCUMENTS. Draw-
ings and Specifications may be ex-
amined at the Architect/Engineer’s
office, and the Owner’s office at the
address shown above and:
QuestCDN (www.questcdn.com)
CMD (Construction Market Data)
Dodge Plan Room and SCAN in
Minneapolis.
Minnesota Builders Exchanges at
Duluth, St. Cloud, Minnesota Build-
ers Exchange in Minneapolis.
North Dakota Builders Exchanges at
Bismarck, Dickinson, Fargo, Grand
Forks, Minot, Williston.
Montana Builders Exchange at Bil-
lings.
If Contractor receives the bidding
documents from a plans exchange,
it is the Contractors responsibility to
contact EAPC Architects Engineers
to be added to the plan holders list.
Complete digital project bidding do-
cuments are available at
www.questcdn.com. You may
download the digital plan documents
for $15.00 by inputting Quest project
# 7318451 on the website’s Project
Search page. Please contact
QuestCDN.com at 952-233-1632 or
info@questcdn.com for assistance
in free membership registration,
downloading, and working with this
digital project information.
An optional paper set of project do-
cuments is also available for a re-
fundable price of $40 per set from
EAPC Architects Engineers, 300 3rd
Ave SW, Suite A, Minot, ND
58701.If the Bidder returns the set of
documents, in good condition, within
10 days following the Bid Date, the
deposit will be refunded. If the
Bidder does not return the set of do-
cuments within the designated time,
none of the deposit will be refunded.
Please allow 2 days for printing.
Partial or complete sets of prints and
specifications may be obtained from
EAPC by other than the above. The
sets or partial sets will be distributed
upon receipt of payment for the in-
formation charged at the current
reproduction rate. None of this pay-
ment will be refunded. Complete-
ness and adequacy of the list of do-
cuments requested shall be the
responsibility of the person making
the request.
FEDERAL REGULATIONS. This
contract is Federally assisted. The
Contractor must comply with the
Davis- Bacon Act, the Anti- Kickback
Act, and the Contract Work Hours
Standards. Contracts for work under
this bid will obligate the Contractor
and Subcontractors not to discrim-
inate in employment practices.
Bidders must submit a compliance
report in conformity with the
President’s Executive Order No.
11246.
BID SECURITY. Bid Security in the
amount of five (5%) percent of the
Bid including all add alternates, must
accompany each Bid in accord with
00 1000 – Instructions to Bidders.
Cash, Bidders Bond, cashier’s
checks or certified checks will not be
accepted.
NORTH DAKOTA LAW. All bidders
must be licensed for the highest
amount of their bids, as provided by
North Dakota Century Code Section
43-07-05; and no bid will be read or
considered which does not fully
comply with the above provisions as
to bond and licenses, and any bid
deficient in these respects submitted
will be re-sealed and returned to the
bidder immediately.
PRE-BID MEETING. There will be a
meeting of prospective Bidders at
10:00 AM, Thursday, October 1,
2020 at 1901 S Broadway Ave,
Minot, North Dakota All those with
questions for the Owner and A/E are
invited to attend.
Attendance by prospective Bidders
is not a mandatory prerequisite for
submitting a Bid for this project
BID SUBMISSION: Bids shall be
submitted to the person and place,
and by the time indicated in the In-
structions to Bidders. Bids shall be
packaged in accordance with 00
1000 – Instructions to Bidders.
THE OWNER reserves the right to
waive irregularities, to reject Bids
and to hold all Bids for a period of 30
days after the date fixed for the
opening thereof.
By order of: Eric Monson, Interim
CEO
(September 18-25; October 2, 2020)
Minot Public School District #1
Regular School Board Meeting
September 3, 2020
Members Present
Jim Rostad
Bonny Berryman
Mike Gessner
Laura Mihalick
Miranda Schuler
Members Absent
The Regular Board Meeting was
called to order by President Rostad
at 4:00 P.M.
The board was presented with a
petition from patrons of the district
regarding the use of student lockers.
President Rostad directed Superin-
tendent Vollmer to forward the peti-
tion to the reintegration committee
for review.
Superintendent Dr. Mark Vollmer
gave the board a COVID-19 update
and an enrollment report. The total
enrollment as of 8-31-2020 was
7,658; down 66 students from the
same time last year.
Moved by Schuler, seconded by
Gessner, to approve the Consent
Agenda to include the August 13,
2020, Regular Meeting and August
18 & August 25, 2020 Special Meet-
ing Minutes and the Financial Re-
ports to include the August Accounts
Payable in the amount of
$2,030,525.40.
Roll Call: All members voted “Yes.”
Business Manager Scott Moum
presented the 2020-2021 budget for
approval on second reading. Moum
noted that based on action at previ-
ous meetings the projected budget
deficit has increased to $3.5 million
and the estimated total mills levied
would be reduced by approximately
2 mills. Moved by Mihalick, second-
ed by Berryman, to approve on
second reading the 2020-2021 MPS
General Fund Budget as presented.
Roll Call: All members voted “Yes.”
Moved by Schuler, seconded by
Mihalick, to approve 2020-2021 New
Teacher Report #8.
Roll Call: All members voted “Yes.”
Moved by Mihalick, seconded by
Berryman, to approve the
2020-2021 DPI Compliance Report
as presented.
Roll Call: All members voted “Yes.”
Moved by Schuler, seconded by
Berryman, to approve the Fall
Calendar Report as presented.
Roll Call: All members voted “Yes.”
The board was presented with a
recommendation to change the MPS
health insurance provider to United
Health Care effective January 1,
2021. The board heard presenta-
tions and in turn asked questions
and heard answers from Business
Manager Scott Moum and MPS
Benefits Consultant Dave Middaugh.
The board was also given a presen-
tation, including questions and
answers from United Health regional
CEO Brett Edelson and Account Ex-
ecutive Jeff Fredrickson. They re-
viewed what UHC is and how they
operate including enhanced services
that would be available to MPS. The
presentation also explained that the
plan design would not change but
that the administration of the plan
would change from BCBSND to
UHC. The board directed the ad-
ministration to request that
representatives from BCBSND
come to a meeting on Wednesday
September 9 at 4:00 p.m. to give a
presentation on the BCBSND health
insurance plan.
The NDSBA Fall convention is set
for October 29 & 30 in Bismarck.
The October regular school board
meeting will be held on October 8,
2020 at 6:00 p.m.
The Regular Meeting adjourned at
5:54 P.M.
Scott Moum, Business Manager
Jim Rostad, President
These minutes are not approved un-
til the next regular board meeting.
Bills List can be found on this link:
https://drive.google.com/drive/folder
s/1mlmigjx9NyywxO_StszFzb5Eebd
48Cna?usp=sharing
(September 18, 2020)
Minot Public School District #1
Special School Board Meeting
September 9, 2020
Members Present
Jim Rostad
Bonny Berryman
Mike Gessner
Laura Mihalick
Miranda Schuler
Members Absent
The Special Board Meeting was
called to order by President Rostad
at 4:00 P.M.
The board was given a presentation,
including questions and answers,
from Blue Cross Blue Shield of N.D.
Chief Marketing Officer Pat Bellmore
and Director Employer Consulting &
Wellness Mike Carlson, regarding
the current health insurance plan as
administered by BCBSND. The
Board set Monday, September 14 at
12:00 p.m. as the date and time of
special board meeting with the
district’s health insurance plan as an
agenda item.
The meeting adjourned at 5:12 p.m.
Scott Moum, Business Manager
Jim Rostad, President
These minutes are not approved un-
til the next regular board meeting.
(September 18, 2020)
Minot Public School District #1
Special School Board Meeting
September 14, 2020
Members Present
Jim Rostad
Bonny Berryman
Mike Gessner
Laura Mihalick
Miranda Schuler
Members Absent
The Special Board Meeting was
called to order by President Rostad
at 12:00 P.M.
Business Manager Scott Moum and
MPS Benefits Consultant Dave Mid-
daugh presented information
relevant to the MPS health in-
surance program. Following ques-
tion, answer and discussion, Gess-
ner moved to change the MPS
Health Insurance Administration
from BCBSND to United HealthCare
effective January 1, 2021. Schuler
seconded by the motion.
Roll call vote: Mihalick-no,
Gessner-yes, Schuler-yes, Berry-
man- no and Rostad-yes. Motion
carried 3-2.
Rostad adjourned the meeting at
12:49 p.m.
Scott Moum, Business Manager
Jim Rostad, President
These minutes are not approved un-
til the next regular board meeting.
(September 18, 2020)
Minutes of the Board of Ward
County Commissioners
September 1, 2020
The regular meeting of the Ward
County Commission was called to
order by Chairman Fjeldahl, at 9:03
AM with Commissioners, Rostad,
Walter, Pietsch and Weppler
present. Also present were depart-
ment heads Bradley Starnes, Dana
Larsen, Jennifer Weichmann, Kerri-
anne Boetcher, Kristin Kowalczyk,
Leona Lochthowe, Marisa Haman,
Melissa Bliss, Noreen Barton,
Robert Roed and Tammy Terras.
Roza Larson arrived at 10:40 AM.
Move by Comm. Walter, seconded
by Comm. Weppler to approve the
agenda. Roll call; all voted yes; mo-
tion carried.
Moved by Comm. Weppler, second-
ed by Comm. Rostad to approve the
minutes of the Regular Commission
Meeting on August 18, 2020 and the
Special Commission Meetings on
August 19, 2020. Roll call; all voted
yes; motion carried.
Moved by Comm. Rostad, seconded
by Weppler to approve the regular
bills totaling $501,363.77 and Hu-
man Service Zone Direct cost bills
totaling $3,610.96. Roll call; all voted
yes; motion carried.
County Highway Engineer Dana Lar-
sen appeared and presented High-
way Department employee Stacy
Zietz with a County Centennial Coin
for his twenty years of service.
Moved by Comm. Walter, seconded
by Comm. Weppler to open the pub-
lic hearing at 9:11 AM regarding the
moving permit application for Tam-
my Holen. Roll call; all voted yes;
motion carried.
Building Inspector Leo Schmidt ap-
peared. Applicant, Tammy Holen, is
requesting to move a 28’x40
manufactured home from 1520 3rd
Ave SE, Minot, to 311 North Rice
Lake Road, Douglas.
No one from the public came for-
ward for or against the moving per-
mit.
Moved by Comm. Weppler, second-
ed by Comm. Walter to close the
public hearing at 9:13 AM. Roll call;
all voted yes; motion carried.
Moved by Comm. Weppler, second-
ed by Comm. Pietsch to approve the
moving permit for Tammy Holen.
Roll call; all voted yes; motion car-
ried.
County Engineer Dana Larsen ap-
peared requesting authorization to
request federal funding to replace
three County bridges over the next
six years and for federal funding to
complete a detailed study of the fu-
ture SW/SE Connector Route
around Minot.
Moved by Comm. Walter, seconded
by Comm. Pietsch to approve the
Highway Department’s request for
authorization to submit a request to
the ND-DOT for funding to replace
the following bridges: Bridge
51-156-49.0 (East of Sawyer across
the Souris River); Bridge
51-134-34.0 (Near US 2 & 52 Inter-
change and crosses the Des Lacs
River); and Bridge 51-136-31.0
(Upstream of Burlington across the
Souris River) and funding to com-
plete a study of a future SW/SE
Connector Corridor around Minot.
Roll call; all voted yes; motion car-
ried.
Noreen Barton, Director of Tax
Equalization appeared with Tax Roll
Adjustments for the Commission ap-
proval.
Moved by Comm. Weppler, second-
ed by Comm. Walter to approve the
Tax Roll Adjustments as presented.
Roll call; all vote yes; motion carried.
Ms. Barton continued with a request
to fill the vacant Deputy Tax Director
position. She would like to open and
fill the position internally. After this
vacant position is filled she would
like to then eliminate the backfilled
position.
Barry Renner appeared with interest
in the Deputy Tax Director position.
Comm. Fjeldahl directed him to con-
tact HR if he is interested in employ-
ment with the County.
Moved by Comm. Weppler, second-
ed by Comm. Walter to approve the
request to fill the Deputy Tax Direc-
tor position as presented. Roll call;
all voted yes; motion carried.
Planning and Zoning Administrator
Doug Diedrichsen appeared with a
variance application and several plat
applications for approval.
Penny Knutson is requesting a vari-
ance for the following described pro-
perty: proposed Sublot F of Outlot 4
13-154-82. The applicant is request-
ing a relief of right of way dedication
on a new outlot plat. A previous vari-
ance for a relief of setback was is-
sued in September 2015. The
current home is 54.5′ from the road
centerline and right of way dedica-
tion should go out to 75′ from center-
line. The County Highway Depart-
ment is requesting the property’s ap-
proach be redone to a standard ap-
proach size to meet County Ordi-
nances.
Moved by Comm. Weppler, second-
ed by Comm. Pietsch to approve the
variance to include staff recommen-
dations. Roll call; all voted yes; mo-
tion carried.
Christopher Nelson representing the
State’s Attorney appeared to inform
the Commission a hardship needs to
be stated for the approval of the vari-
ance application.
Moved by Comm. Weppler, second-
ed by Comm. Pietsch to amended
the original motion to include appro-
val of the variance application due to
topographical hardships (hillside
behind home) and existing home’s
location. Roll call; all voted yes; mo-
tion carried.
Penny Knutson submitted a plat ap-
plication for the following described
property: Proposed Sublot F, Lying
in Outlot 4, 16-154-82, The applicant
is proposing to parcel sublot F a
2.08 acre outlot. This outlot is future
residential purposes. Ward County
zoning applies with Sundre Town-
ship recommending approval. The
proposed sublot meets the zoning
requirements in Ward Counties R1
district.
Moved by Comm. Walter, seconded
by Comm. Rostad to approve the
plat application for Penny Knutson
and include all of staff recommenda-
tions. Roll call; all voted yes; motion
carried.
Susan Thomas submitted a plat ap-
plication for the following described
property: Proposed Outlot 8 lying in
the NENW, 33-154-82. The appli-
cant is proposing to parcel Outlot 8 a
6.44 acre outlot. This outlot is for fu-
ture residential purposes. Ward
County zoning requirements applies
with Sundre Township recommend-
ing approval. The proposed outlot
meets zoning requirements in Ward
Counties A1 district.
Moved by Comm. Pietsch, second-
ed by Comm. Walter to approve the
plat application for Susan Thomas
and include all of staff recommenda-
tions. Roll call; all voted yes; motion
carried.
Jesse Starr submitted a plat appli-
cation for the following described
property: Proposed Outlots 11 & 12
lying in the NESE, 32-156-82. The
applicant is proposing to parcel out
two outlots. Outlot 11 is 21.91 acres
and Outlot 12 is 4.22 acres. Both
outlots are for future residential pur-
poses. Ward County zoning applies
with McKinley Township recom-
mending approval. The proposed
outlots meet the zoing requirements
in Ward Counties Rural district (Arti-
cle 6, Section 1).
Moved by Comm. Rostad, seconded
by Comm. Walter to approve the plat
application for Jess Starr and in-
clude all of staff recommendations.
Roll call; all voted yes; motion car-
ried.
Jana Fjeldahl submitted a plat ap-
plication for the following described
property: Proposed Outlots 1 & 2 ly-
ing in the SENE and the NWNE,
12-153-87. The applicant is propos-
ing to parcel out two outlots. Outlot 1
is 10.0 acres and Outlot 2 is 11.85
acres. Both outlots are for future
residential purposes. Ward County
zoning applies with Lund Township
recommending approval. The pro-
posed outlots meet the zoning re-
quirements in Ward Counties Rural
district (Article 6, Section 1).
Moved by Comm. Walter, seconded
by Comm. Weppler to approve the
plat application for Jana Fjeldahl to
include staff recommendations and
the Planning and Zoning recom-
mended condition that no additional
access approach permits will be
given. Roll call; all voted yes; motion
carried.
Ward County Water Resource Board
submitted an application for four
plats for the following describe pro-
perty: proposed Outlot 1 of the
NENE sec 21-154-83; Outlot 1 of the
NWNW sec 22-154-83; Outlot 2 of
the SESE sec 16-154-83 and Outlot
16 of the SWSW sec 15-154-83.
The Water Resource Board is pro-
posing to parcel out four outlots.
Outlots 1, sec 21 is 2.10 acres;
Outlot 1, sec 22 is 1.61 acres; Outlot
2, sec 16 is 1.54 acres; and Outlot
16, sec 16 is 1.55 acres. All outlots
are for future right of way purposes.
Ward County zoning applies with Af-
ton Township recommending appro-
val. Variances were issued by Ward
County for the 3 outlots smaller than
2 acres and Afton Township vari-
ances have been issued for all four
lots because they are smaller than
the townships 5 acres minimum.
Moved by Comm. Pietsch, second-
ed by Comm. Walter to approve the
plat applications for Ward County
Water Resource Board and include
all staff recommendations and the
stipulation the outlots are for Water
Board purposes only and cannot be
used for residential purposes. Roll
call; all voted yes; motion carried.
Human Resource Director Tammy
Terras appeared and presented the
Commission with the County Nepo-
tism Policy draft.
Moved by Comm. Weppler, second-
ed by Comm. Pietsch to approve the
County Nepotism Policy draft as
presented.
A brief discussion was held. Comm.
Weppler and Comm. Pietsch with-
drew the motion.
Moved by Comm. Weppler, second-
ed by Comm. Walter to table the ap-
proval of the County Nepotism Poli-
cy. Roll call; all voted yes; motion
carried.
Ms. Terras requested a decision re-
garding the employee health in-
surance renewal. Several options
were given to the Commission.
Moved by Comm. Weppler, second-
ed by Comm. Walter to approve
staying with the current health in-
surance plan with no changes for
the 2021 calendar year. Roll call; all
voted yes, except Comm. Rostad
who voted no; motion carried.
Moved by Comm. Weppler, second-
ed by Comm. Walter to approve the
following payroll amendments: T.
Ness- Auditor/Treasurer; L. Pletch-
er- Sheriff/Jail; A. Alt-Sheriff/Jail; B.
Brazell- IT; T. Scheig-Sheriff/Jail; S.
Eslinger-Highway; K. Schaefer-
State’s Attorney. Roll call; all voted
yes; motion carried.
Ms. Terras reviewed President
Trump’s executive order for the
IRS-Guidance: Employee Social
Security Deferral.
Moved by Comm. Weppler, second-
ed by Comm. Pietsch to receive and
file with no action the IRS-Guidance:
Employee Social Security Deferral.
Roll call; all voted yes; motion car-
ried.
Comm. Rostad informed the Com-
mission that he has not heard from
the legal representative for the own-
er of the Hall Apartments.
The Commission continued with a
brief discussion regarding the Salary
Structure Review. Moved by Comm.
Walter, seconded by Comm. Pietsch
to approve Ms. Terras bringing a
proposal to the Commission for a full
Compensation Study. Roll call; all
voted yes; motion carried.
Comm. Fjeldahl gave the Commis-
sion images of the property the
County is selling at Rice Lake. He is
requesting the Commission approve
the language of the quit claim deed
before he signs the document.
Moved by Comm. Pietsch, second-
ed by Comm. Walter to approve the
Right of Way language and remove
the mineral and oil rights language
in the quit claim deed for Rice Lake
lots 6, 7 and 30 feet of lot 8. Roll
call; all voted yes, except Commis-
sioners Weppler and Rostad; motion
carried.
Auditor/Treasurer Marisa Haman ap-
peared.
Moved by Comm. Pietsch, second-
ed by Comm. Weppler to receive
and file the following correspon-
dence: NDDEQ-Rice Lake Water
Quality; AARP-letter regarding elec-
tion; First District Health
Unit-Nuisance Notification letter;
Secretary of State-Election Perfor-
mance. Roll call; all voted yes; mo-
tion carried.
Ms. Haman requested clarification
from the Commission regarding how
to proceed with advertising and sel-
ling the old radio tower property in
Berthold.
Moved by Comm. Walter, seconded
by Comm. Weppler to approve ad-
vertising for sealed bids the selling
of the Berthold radio tower property.
A brief discussion was held. Com-
missioners Walter and Weppler with-
drew the motion.
Moved by Comm. Pietsch, second-
ed by Comm. Weppler to approve
advertising the Berthold tower pro-
perty to be sold at a live auction with
a minimum bid of $1,000, on Oc-
tober 2, 2020 at 2:30 PM in the
Commission Chambers. Roll call; all
voted yes, except Comm. Walter
who voted no; motion carried.
Moved by Comm. Walter, seconded
by Comm. Weppler to approve and
sign the Legal Service agreement
with Schweigert, Klemin, McBride,
P.C for collecting of outstanding
debts. Roll call; all voted yes; motion
carried.
Moved by Comm. Rostad, seconded
by Comm. Walter to approve the raf-
fle permit for the Bishop Ryan
Catholic School Parents Activities
Association. Roll call; all voted yes;
motion carried.
Moved by Comm. Weppler, second-
ed by Comm. Pietsch to appoint
Kandi Mikkelson as the Ward Coun-
ty delegate to the ND State Fair As-
sociation. Roll call; all voted yes;
motion carried.
Moved by Comm. Rostad, seconded
by Comm. Pietsch to appoint
Comm. Fjeldahl as the second Ward
County delegate to the ND State
Fair Association. Roll call; all voted
yes; motion carried.
Moved by Comm. Walter, to change
the November 3, 2020 Commission
meeting to November 4, 2020.
Comm. Weppler stated she was
unavailable that day. Comm. Walter
withdrew his motion.
Moved by Comm. Walter, seconded
by Comm. Weppler to change the
November 3, 2020 Commission
meeting to November 10, 2020. Roll
call; all voted yes; motion carried.
Ms. Haman informed the Commis-
sion the County has received
$1,312,084.66 from the CARES
ACT for reimbursement of law en-
forcement salaries.
At 11:31 PM with no further busi-
ness, the meeting was adjourned.
(September 18, 2020)
N O T I C E T O B I D D E R S
The City Clerk of the City of Minot
will receive sealed bids at her office
at City Hall until 11:00 a.m. on
Thursday, October 1, 2020 for fur-
nishing the City of Minot the follow-
ing:
“Water and Wastewater
Treatment Chemicals”
Specifications and general instruc-
tions to bidders are available at the
Public Works Building at 1025 31st
St. S.E and on the City website at
www.minotnd.org.
The bid envelope shall be clearly
marked:
Project #4232
“Bid for Water and Wastewater
Treatment Chemicals”
The City Council of the City of Minot
reserves the right to reject any or all
bids and to award the contract as it
deems to be in the best interest of
the City of Minot.
Bidders are invited to be present at
the above-mentioned time and place
for the opening of the bids.
Kelly Matalka
City Clerk
(September 18-25, 2020)
N O T I C E T O B I D D E R S
The City Clerk of the City of Minot
will receive sealed bids at her office
at City Hall until 11:00 a.m. on
Thursday, October 1, 2020 for fur-
nishing the City of Minot the follow-
ing:
“6,000 Tons of Washed Sand”
Specifications and general instruc-
tions to bidders are available at the
Public Works Building at 1025 31st
St. S.E and on the City website at
www.minotnd.org.
The bid envelope shall be clearly
marked:
Project #4229
“Bid for 6,000 Tons of Washed
Sand”
The City Council of the City of Minot
reserves the right to reject any or all
bids and to award the contract as it
deems to be in the best interest of
the City of Minot. In addition, a gra-
dation of the material proposed to be
supplied shall be provided.
Bidders are invited to be present at
the above-mentioned time and place
for the opening of the bids.
Kelly Matalka
City Clerk
(September 18, 2020)
NOTICE TO CREDITORS
51-2020-PR-00151
IN THE DISTRICT COURT OF
WARD COUNTY, STATE OF
NORTH DAKOTA
In the Matter of the Estate of
Rueben Hoffer, Deceased.
NOTICE IS HEREBY GIVEN that
the undersigned has been appointed
Personal Representatives of the
above estate. All persons having
claims against the deceased are re-
quired to present their claims within
three months after the date of the
first publication of this notice or said
claims will be forever barred. Claims
must be presented to Lyle Erhardt,
in care of Thomas Law Firm, 114
South Main Street, P.O. Box 2298,
Minot, North Dakota 58702, or filed
with the Court.
Dated this 1st day of September,
2020.
/s/Lyle Erhardt
Lyle Erhardt
c/o THOMAS LAW FIRM
114 South Main Street
P.O. Box 2298
Minot, ND 58702
(September 4-11-18, 2020)
NOTICE
Ward County is currently accepting
applications for an unexpired term
on the Ward County Planning &
Zoning Commission. The term effec-
tive immediately through July 1,
2022. The position is open to all ci-
tizens of Ward County.
The Planning Commission meets
monthly to review and act upon sub-
division plats, zoning changes and
other planning related matters.
Members of the Ward County Plan-
ning & Zoning Commission receive
a $50 per meeting attended stipend
and are eligible for reappointment to
subsequent four-year terms.
Deadline to apply for the position is
October 6, 2020 at 4:00 p.m. Appli-
cations may be picked up at the
Ward County Auditor/Treasurer’s of-
fice or on the County website at
wardnd.com
(September 18, 2020)
PETITION FOR NAME CHANGE
IN DISTRICT COURT, WARD
COUNTY, NORTH DAKOTA
In the Matter of the Petition for
Name Change of Ryan Michael
Vanferson.
PLEASE TAKE NOTICE that a Peti-
tion in the above-entitled matter will
be filed with the Clerk of District
Court for Ward County, North Dako-
ta, requesting an Order changing the
name of Ryan Michael Vanferson
(current full, legal name) to Ryan
Michael Miraballes (requested full,
legal name).
Pursuant to N.D.C.C. 32-28-02, thir-
ty days previous notice of the in-
tended application must be given in
the official newspaper printed in this
county. You are hereby notified that
thirty days after publication, peti-
tioner intends to file a petition re-
questing entry of the Court’s Order
changing the name of Ryan Michael
Vanferson(current full, legal name)
to Ryan Michael Miraballes (request-
ed full, legal name). Any objection to
granting this name change must be
given in writing to the address listed
below within 30 days of the date of
this publication. The written objec-
tion must also be filed with the
Court. If no objections are given, the
Court may respond to the Petition
without further hearing.
Dated this 7th day of September,
2020.
/s/Ryan Vanferson
Ryan Vanferson
P.O. Box 457
Surrey, ND 58785
(September 18, 2020)
PETITION FOR NAME CHANGE
IN DISTRICT COURT, WARD
COUNTY, NORTH DAKOTA
In the Matter of the Petition for
Name Change of Alexander David
Blankenship.
PLEASE TAKE NOTICE that a Peti-
tion in the above-entitled matter will
be filed with the Clerk of District
Court for Ward County, North Dako-
ta, requesting an Order changing the
name of Alexander David Blanken-
ship (current full, legal name) to
Alexander David Schenker (request-
ed full, legal name).
Pursuant to N.D.C.C. 32-28-02, thir-
ty days previous notice of the in-
tended application must be given in
the official newspaper printed in this
county. You are hereby notified that
thirty days after publication, peti-
tioner intends to file a petition re-
questing entry of the Court’s Order
changing the name of Alexander Da-
vid Blankenship (current full, legal
name) to Alexander David Schenker
(requested full, legal name). Any ob-
jection to granting this name change
must be given in writing to the ad-
dress listed below within 30 days of
the date of this publication. The writ-
ten objection must also be filed with
the Court. If no objections are given,
the Court may respond to the Peti-
tion without further hearing.
Dated this 15th day of September,
2020.
/s/Alexander David Blankenship
Alexander David Blankenship
2213 33rd St. NW
Minot, ND 58703
(September 18, 2020)
REQUEST FOR QUALIFICATIONS
FOR
Engineering Services
North Prairie Regional Water District
(NPRWD), in accordance with the
State Water Commission Funding
requirements, is soliciting a Request
for Qualifications (RFP). The RFQ
will be for engineering design and
construction services for expansion
of the NPRWD system in 2020.
NPRWD may utilize the selected
firm for only this project or may elect
to utilize the selected firm for a
multi-year period for all of its en-
gineering needs.
Respondents are prohibited from
contacting any representative of
NPRWD regarding this RFQ. Any
questions on this RFQ shall be in
writing and will be shared with any
other interested firm. All responses
must be received by 5:00 p.m. Mon-
day, September 28, 2020.
Responses shall include:
1. Written proof that applicant has
been engaged in full-timebusiness
operations, for profit, in its existing
form(whether sole proprietorship,
partnership, joint venture orcorpora-
tion) for not less than five (5) years
prior to thedate of this notice.
2. Applicant’s principle place of busi-
ness of the staff whichwill be pri-
marily involved and the location of
theheadquarters of the firm.
3. The experience and qualifications
of the staff to be assignedto and pri-
marily working on the NPRWD pro-
ject.
4. At least three references with ex-
perience regarding thefirm’s capa-
bilities and past work performance.
5. A listing and description of the
firm’s current and projectedworkload
for the next two (2) years and a nar-
rative on howthe NPRWD project
would be staffed and work allocated.
Conditions of Proposal Considera-
tion:
Points will be awarded for these cri-
teria:
1. Prior experience of applicant in its
present form as engineerfor rural
water systems construction projects
involving notless than $3 million in
construction costs. (maximum of
20points)
2. Prior experience of applicant in its
present form with StateWater Com-
mission and ND State Revolving
Loan Program (Maximumof 25
points.)
3. Professional credentials of the ap-
plicant in its present form(or the
applicant’s key personnel who will
work on thisproject). Points will be
awarded for owners/employees of
theapplicant who have been with the
applicant firm as an owneror
full-time employee for not less than
two (2) years priorto the date of this
notice and only for persons who
arepracticing in the states in which
their principle place ofbusiness is lo-
cated. (maximum of 15 points)
4. Prior experience of applicant in its
present form for NPRWDprojects.
(maximum of 20 points)
5. Work load capacity of the appli-
cant in its present form -ability to
complete the project with existing
staff withinthe required time limits.
Applicant must demonstrate how
andwith what staff it proposes to
perform the project
managementfunctions. Only staff
who are full-time employed by
theapplicant for not less than twelve
(12) months prior to thedate of this
notice will be considered in awarding
pointsunder this criteria, although
applicant may hire otherpersonnel
after selection. (Maximum of 15
points)
6. Location. Preference given to
firms headquartered in NorthDakota.
(maximum of 5 points)
Proposals will be reviewed by
NPRWD with selection based upon
the evaluation of the written propo-
sals. NPRWD may elect to hold in-
terviews with applicants.
One (1) copy of the Proposals shall
be mailed to:
Teresa Sundsbak General Manager
North Prairie Regional Water District
3811 Burdick Expy E Minot, ND
58701-5357
Once the selection process is com-
plete, NPRWD will evaluate fee
structures of the selected engineer
and negotiate an agreement for the
scope of work and services pro-
posed. In the event NPRWD cannot
negotiate an agreement to its satis-
faction, NPRWD reserves the right
to negotiate with other firm(s) who
have responded or to resolicit for
Request for Qualifications.
All costs involved in responding to
this Request for Qualifications are
the responsibility of the firm submit-
ting the Request for Qualifications.
(September 4-11-18, 2020)
SECOND AMENDED SUMMONS
Civil No. 51-2019-CV-01671
IN DISTRICT COURT, NORTH
CENTRAL JUDICIAL DISTRICT,
STATE OF NORTH DAKOTA,
COUNTY OF WARD
QUICKEN LOANS INC.,
Plaintiff,
vs.
Devon Wold (deceased): Unknown
Heirs; Devisees; Legatees; Adminis-
trators; Executors; Creditors of De-
von Wold; and Other Unknown Per-
sons Who Might have a Right of
Redemption from the Mortgage.;
Any Person in Possession; The Un-
ited States of America Acting by and
Through the Internal Revenue Ser-
vice;
Defendants.
THE STATE OF NORTH DAKOTA
TO THE ABOVE NAMED DEFEN-
DANTS:
1. You are hereby summoned to ap-
pear and defend against the Amend-
ed Complaint in this action, which
has been filed with the Clerk of
Court and is herewith served upon
you, by serving upon the under-
signed a copy of an Answer or other
proper response within twenty-one
(21) days after the service of this
Amended Summons upon you, ex-
clusive of the day of service. The
Defendant, United States of Ameri-
ca, alone shall have sixty (60) days
after the service of this Amended
Summons to answer, exclusive of
the day of service. If you fail to do
so, Judgment by default will be tak-
en against you for the relief demand-
ed in the Amended Complaint. The
original Complaint is filed with the
Clerk of the District Court in the
County in which this action is com-
menced.
2. This action relates to the foreclo-
sure of a mortgage upon the follow-
ing described real property in the
County of Ward, State of North
Dakota:
Lot 11, Bel Air 13th Addition to the
City of Minot, Ward County, North
Dakota
3. The Plaintiff is not seeking a per-
sonal judgment against the
above-named Defendants.
Dated July 30, 2020.
Halliday, Watkins & Mann, P.C.
376 East 400 South, Suite 300
Salt Lake City, UT 84111
Tel: 801-355-2886
Fax: 801-328-9714
Email: benjamin@hwmlawfirm.com
By: /s/ Benjamin J. Mann
Benjamin J. Mann, Attorney
Bar ID #08371
(September 18-25; October 2, 2020)
SUMMONS AND NOTICE
Case No. 51-2019-CV-01128
STATE OF NORTH DAKOTA,
COUNTY OF WARD, IN DISTRICT
COURT, NORTH CENTRAL
JUDICIAL DISTRICT
Tyler Anderson, Franklin D. Ander-
son and Kathy L. Anderson,
Trustees under the Franklin D.
Anderson Living Trust, dated June
1, 2015,
Plaintiffs,
vs.
Mike C. Meeken; Joseph St. Aubin,
a/k/a Joseph A. St. Aubin; and all
other persons unknown claiming any
estate or interest in, or lien or en-
cumbrance upon, the property
described in the Complaint,
Defendants.
THE STATE OF NORTH DAKOTA
TO THE ABOVE NAMED DEFEN-
DANTS:
YOU AND EACH OF YOU ARE
HEREBY SUMMONED to answer
the Complaint in the above-entitled
action, which Complaint is filed in
the Office of the Clerk of the District
Court of Ward County, North Dako-
ta, and to serve a copy of your
Answer to said Complaint on the un-
dersigned at their offices in the City
of Minot, Ward County, North Dako-
ta, within twenty-one (21) days after
such service of this Summons upon
you, exclusive of the day of such
service; and in case of your failure to
answer or appear, Judgment will be
taken against you by default for the
relief demanded in the Complaint.
The Complaint in this action is to be
filed in the office of the Clerk of
Court of Ward County, North Dako-
ta. The object of the action is to ex-
clude the Defendants from any
estate or interest in or lien or encum-
brance upon the land involved in this
action.
Dated this 28th day of August, 2020.
OLSON & BURNS P.C.
/s/Jessica L. Merchant
Jessica L. Merchant (ID 06169)
Attorneys for Plaintiff
17 First Avenue SE
P. O. Box 1180
Minot, ND 58702-1180
(701) 839-1740
jmerchant@srt.com
NOTICE
This notice is a description of the
real property at issue in the
above-entitled action, which is si-
tuated in the above-named county
and state, to-wit:
Lots 1, 2, 3, and 4, Less the
Northeasterly 40 feet thereof for
highway, Block 1, Powers 1st Addi-
tion to Donnybrook
This action will be filed in the office
of the Ward County Clerk of Court in
Minot, North Dakota.
Dated this 28th day of August, 2020.
OLSON & BURNS P.C.
/s/Jessica L. Merchant
Jessica L. Merchant (ID 06169)
Attorney for Plaintiff
17 First Avenue SE
P.O. Box 1180
Minot, ND 58702-1180
(701) 839-1740
jmerchant@srt.com
(September 4-11-18, 2020)