Legal Notices 9-11
ADVERTISEMENT FOR
CONSTRUCTION BIDS
Separate sealed Bids for construc-
tion of the Snake Creek Pumping
Plant Cable and XFMR Replace-
ment will be received at the office of
Garrison Diversion Conservancy
District, 401 Hwy 281 NE, Carring-
ton, ND 58421, until 2:00 p.m., local
time, on the 29th day of September,
2020, where and at which time they
will be publicly opened and read
aloud.
Bids can be mailed to:
“Snake Creek Pumping Plant Cable
and XFMR Replacement
Project Bid”
Garrison Diversion Conservancy
District
PO Box 140
Carrington, ND 58421
The scope of work will generally
consist of a lump sum bid for the re-
moval and replacement of over
9,000 feet of 15kV Rated Cable, the
installation of an 800A, 277/480V
Rated Generator Docking Station,
and the removal of two (2) 750kVA
Sealed CO2 Gas Insulated
Transformers. One of the removed
transformers will be replaced with
the noted generator docking station
while the other will be replaced with
a 750kVA Dry Type Transformer.
Bid Alternate No. 1 includes a lump
sum bid cost deduct for excluding
the removal of one (1) 750 kVA
Sealed CO2 Gas Insulated
Transformer and excluding the in-
stallation of one (1) 750 kVA Dry
Type Transformer from the Base
Bid. Only the Base Bid or the Base
Bid and Bid Alternate No. 1 will be
awarded:
Contract No. 1. – Electrical Con-
struction Base Bid: Work generally
includes mobilization, bonding, and
insurance; Removal and installation
of approximately 9,000 feet of 15kV
Rated Cable, the installation of an
800A, 277/480V Rated Generator
Docking Station, and the removal of
two (2) 750kVA Sealed CO2 Gas In-
sulated Transformers. One of the
removed transformers will be re-
placed with the noted generator
docking station while the other will
be replaced with a 750kVA Dry Type
Transformer. Work may also in-
clude electrical site work and con-
trols, and miscellaneous related con-
struction, equipment, and appurte-
nances.
Bid Alternate No. 1 to Contract
No. 1. – Electrical Transformer
Deduct: Excludes the removal of
one (1) 750 kVA Sealed CO2 Gas
Insulated Transformer and excludes
the installation of one (1) 750 kVA
Dry Type Transformer and all electri-
cal transformer associated work
from Contract No. 1 – Base Bid.
All Bids shall be prepared according
to the Instruction to Bidders con-
tained within the Project Manual. All
Bidders shall attend the MANDATO-
RY Pre-Bid walkthrough/conference
at the project site on September
22nd, 2020 at 2:00 pm. Each Bid
shall be accompanied by a
separate envelope containing a Bid
Security in the form of a Bidder’s
Bond executed by the Bidder as
principal and by a surety company
authorized to do business in the
State of North Dakota, payable to
the Garrison Diversion Conservancy
District, in a sum equal to five per-
cent (5%) of the full amount of the
Bid. This is to serve as a guarantee
that the successful Bidder will enter
into a Contract within fifteen (15)
days of Notice of Award, in accor-
dance with the terms of the
principal’s Bid and Contractor’s
Bond as required by law and regula-
tions and determinations of Garrison
Diversion Conservancy District, for
the performances of such Work.
Only Bids that are accompanied by
such a Bond will be considered. All
Work shall be performed in accor-
dance with the Bidding Documents
on file in the Office of Garrison
Diversion Conservancy District, Car-
rington, ND, where they may be
seen and examined. Bidders must
be licensed for the full amount of the
Bid as required by North Dakota
Century Code 43-07-12. Each Bid
shall contain a copy of the
Contractor’s license or certificate of
renewal thereof issued by the Secre-
tary of State. All Bids must be sub-
mitted on the Bid Form furnished by
the Engineer. No Bid will be read or
considered that does not fully com-
ply with the above provisions and
other provisions contained within the
Bidding Documents, and any defi-
cient Bid submitted will be returned
to the Bidder unopened. Contracts
shall be awarded on the basis of the
low Bid submitted by a responsible
and responsive Bidder deemed most
favorable to Garrison Diversion’s in-
terest. All Bids shall be contained in
a sealed envelope plainly marked
showing that such envelope con-
tains a Bid for the Project. In addi-
tion, the Bidder shall place upon the
exterior of such envelope the follow-
ing information:
1. Project Name and Work covered
by the Bidder (General).
2.The name of the Bidder.
3.Federal ID Number
4.Separate envelope containing Bid
Bond, a copy of Contractor’s
License or Renewal Certificate, and
proof of insurance.
5.Acknowledgement of all Addenda.
The Garrison Diversion Conservan-
cy District reserves the right to reject
any and all Bids, to waive any infor-
mality in any Bid, to hold all Bids for
a period not to exceed thirty (30)
days from the date of opening Bids,
and to accept the Bid deemed most
favorable to the interest of the Own-
er. After the Bid opening, the Owner
will return Bid Security of all except
the three lowest responsible
Bidders. When a Contract is award-
ed, the remaining unsuccessful
Bidder’s Bonds will be returned.
Complete digital project bidding do-
cuments, pursuant to which labor,
materials, or services must be fur-
nished, are available at
www.AE2S.com or www.questcdn
.com. You may download the digital
plan documents for Thirty Dollars
and No Cents ($30.00) by inputting
Quest project 7273534 on the
website’s Project Search page.
Please contact QuestCDN.com at
952-233-1632 or info@questcdn
.com for assistance in free member-
ship registration, downloading, and
working with this digital project infor-
mation. Copies of the Bidding Docu-
ments may also be seen and exam-
ined at the office of the Engineer,
Advanced Engineering and En-
vironmental Services, Inc., 4170
28th Ave S, Fargo, ND 58104. The
Bidding Documents are available in
the form of printed plans and specifi-
cations by request from Advanced
Engineering and Environmental Ser-
vices, Inc., 4170 28th Ave S, Fargo,
ND 58104. The cost is $350.00 for
printed documents, for each set of
Documents obtained. Payment for
Bidding Documents is
NON-REFUNDABLE. All Work
shall be done according to the Bid-
ding Documents. Bidding Docu-
ments may also be examined at the
following locations:
Plans and Specifications are on file
and may be seen and examined at
the following locations:
Advanced Engineering and Environ-
mental Services, Inc.
4170 28th Ave. S
Fargo, ND 58104
Bismarck-Mandan Builders Ex-
change
805 Adobe Trail SE
Mandan, ND 58554
Construction Plans Exchange
215 Airport Rd
Bismarck, ND 58504
Minot Builders Exchange
2424 Burdick Expwy E
Minot, ND 58701
Grand Forks Builders Exshange
3311 South Washington St.
Grand Forks, ND 58201
Fargo Builders Exchange
1010 Page Drive
Fargo, ND 58102
Dated this 3rd day of September
2020.
(September 11-18-25, 2020)
NOTICE
All land owners must have ditches
mowed to a minimum 4 inch stubble
height and a minimum 9 foot mower
width between Sept. 15 – Oct. 1st,
2020. Sundre Township will con-
tract mowing for ditches not com-
pleted by October 1, 2020 and ex-
penses will be levied as taxes
against land owner.
Cari Morey, Sundre Township Clerk
(September 4-5-8-9-10-11-12, 2020)
NOTICE INVITING SEALED PRO-
POSALS (BIDS)
FOR THE CONSTRUCTION OF
THE VALLEY ZONE IMPROVE-
MENTS 3RD STREET TANK
DEMOLITION AND PIPING IM-
PROVEMENTS PROJECT
CITY OF MINOT, WARD COUNTY,
NORTH DAKOTA
NOTICE IS HEREBY GIVEN that
the City of Minot, North Dakota, in-
vites and will receive sealed propo-
sals (bids) up to the hour of 10:00
a.m., local time, on September
23rd, 2020, for the furnishing to the
City of Minot of all transportation, la-
bor, materials, tools, equipment, ser-
vices, permits, utilities, and other
items necessary to construct said
work, in accordance with the draw-
ings and contract documents on file
in the office of the City Clerk, Minot,
North Dakota. At said time, said pro-
posals will be publicly opened and
read aloud at Council Chambers at
City Hall of the City of Minot, North
Dakota located at 515 2nd Ave SW,
Minot, ND 58701.
Bids shall conform to and be respon-
sive to the Contract Documents for
the work. The Contract Documents
will be available after August 28th,
2020. Copies of the Contract Docu-
ments will be on file and may be ex-
amined by appointment during nor-
mal office hours at the following lo-
cation:
Houston Engineering, Inc.
18 3rd Street SE, Suite 100
Minot, ND 58701-3700
Telephone (701) 852-7931
Fax (701) 858-5655
The scope of work consists of, but is
not limited to, the demolition and re-
moval of an existing 1 MG steel
ground water storage reservoir in-
cluding a pre and post construction
lead-based paint risk assessment,
pump house with underground pump
pit, building foundation, reservoir
gate chambers, overflow pipe
headwall, and underground site pip-
ing and valves; abandonment of ex-
isting water main and overflow pipe
with CLSM; removal of bituminous
and concrete roadway, curb and
gutter, water main, gate valves,
valve manholes, and fire hydrant as-
semblies; installation of 131 LF of 12
inch water main, (4) 12 inch gate
valves, (1) fire hydrant assembly, (1)
hydraulic control valve manhole, bi-
tuminous pavement patch, concrete
pavement patches, curb and gutter;
imported topsoil; seed bed prepara-
tion and seeding with hydro-mulch;
earthwork and site grading; erosion
control; traffic control; with appurte-
nances and incidental items.
Printed copies of plans and specifi-
cations may be obtained following
receipt of payment of $500.00 per
set, non-refundable, or a CD may
be obtained with the documents in
electronic (pdf) format following re-
ceipt of payment of $40 per set,
nonrefundable, from the following:
Houston Engineering, Inc.
18 3rd Street SE, Suite 100
Minot, ND 58701-3700
The contract documents may also
be viewed free of charge online at
www.houstoneng.com, or down-
loaded for a fee of $25.00. Please
contact Houston Engineering at
701-852-7931 if you have any ques-
tions. The Advertisement for Bids,
Planholders List, Addendums, and
Bid Results will be available from
the “Bid Info” link located on the
Houston Engineering, Inc. web site.
Each bid shall be submitted on a
form furnished as part of the con-
tract documents and must be ac-
companied by a separate envelope
containing a Bidder’s Bond with Ack-
nowledgement of Surety in an
amount not less than 5% of the full
amount of the bid made payable to
the order of or for the benefit of the
City of Minot, North Dakota. The bid
bond shall be executed by the bidder
as principal and by a surety com-
pany authorized to do business in
the State of North Dakota, condi-
tioned that if the principal’s Bid be
accepted and the contract awarded
to the principal, within ten (10) days
after Notice of Award, the Principal
shall execute a contract in accor-
dance with the terms of the bid and
contractor’s performance and pay-
ment bonds as required by law and
the regulations and determinations
of the City of Minot. A bid submitted
without this information properly en-
closed in the bid bond envelope
shall not be read nor considered and
the envelope shall be resealed and
bid returned to the bidder immedi-
ately. Each bid shall be sealed and
delivered to the City of Minot at the
location designated in this notice for
the opening of proposals at or before
the time in this notice provided.
All Bidders shall hold a valid North
Dakota Contractor’s license of the
proper class and shall enclose a
copy of the license or Certificate of
Renewal of the license in the same
envelope as the Bidder’s Bond.
The work is to be substantially com-
pleted and operational by June 1,
2021. Final completion shall be
July 1, 2021.
The City of Minot will award the con-
tract to the lowest responsive and
responsible Bidder. The City of
Minot reserves the right to reject any
and all bids, and to waive any and
all irregularity in any bid.
BY THE ORDER OF THE CITY
COUNCIL OF THE CITY OF
MINOT, NORTH DAKOTA.
Dated: August 17, 2020
/s/ Kelly Matalka
Kelly Matalka, City Clerk
(August 28; September 4-11, 2020)
NOTICE
Shealy Township Fall Road Mowing
All landowners are responsible for
mowing road ditches. It will need to
be done by Oct 1st. If the roads are
not mowed the township will hire it
done & the cost will be added to the
landowner’s taxes. By order of the
Shealy Township supervisors.
June Myers /Clerk
(September 11, 2020)
NOTICE TO CREDITORS
51-2020-PR-00151
IN THE DISTRICT COURT OF
WARD COUNTY, STATE OF
NORTH DAKOTA
In the Matter of the Estate of
Rueben Hoffer, Deceased.
NOTICE IS HEREBY GIVEN that
the undersigned has been appointed
Personal Representatives of the
above estate. All persons having
claims against the deceased are re-
quired to present their claims within
three months after the date of the
first publication of this notice or said
claims will be forever barred. Claims
must be presented to Lyle Erhardt,
in care of Thomas Law Firm, 114
South Main Street, P.O. Box 2298,
Minot, North Dakota 58702, or filed
with the Court.
Dated this 1st day of September,
2020.
/s/Lyle Erhardt
Lyle Erhardt
c/o THOMAS LAW FIRM
114 South Main Street
P.O. Box 2298
Minot, ND 58702
(September 4-11-18, 2020)
NOTICE TO LAND OWNERS
Hiddenwood Township Ditch Mow-
ing- ALL land owners and/or renters
are required to mow ditches-two
passes- in Hiddenwood Township by
October 3rd, 2020. If the township
hires mowing the cost will be ac-
cessed to your taxes. Anyone sub-
mitting a mowing bid should contact
the township chairman.
Janice J Warner, Clerk
(September 11-16-23, 2020)
REQUEST FOR QUALIFICATIONS
FOR
Engineering Services
North Prairie Regional Water District
(NPRWD), in accordance with the
State Water Commission Funding
requirements, is soliciting a Request
for Qualifications (RFP). The RFQ
will be for engineering design and
construction services for expansion
of the NPRWD system in 2020.
NPRWD may utilize the selected
firm for only this project or may elect
to utilize the selected firm for a
multi-year period for all of its en-
gineering needs.
Respondents are prohibited from
contacting any representative of
NPRWD regarding this RFQ. Any
questions on this RFQ shall be in
writing and will be shared with any
other interested firm. All responses
must be received by 5:00 p.m. Mon-
day, September 28, 2020.
Responses shall include:
1. Written proof that applicant has
been engaged in full-timebusiness
operations, for profit, in its existing
form(whether sole proprietorship,
partnership, joint venture orcorpora-
tion) for not less than five (5) years
prior to thedate of this notice.
2. Applicant’s principle place of busi-
ness of the staff whichwill be pri-
marily involved and the location of
theheadquarters of the firm.
3. The experience and qualifications
of the staff to be assignedto and pri-
marily working on the NPRWD pro-
ject.
4. At least three references with ex-
perience regarding thefirm’s capa-
bilities and past work performance.
5. A listing and description of the
firm’s current and projectedworkload
for the next two (2) years and a nar-
rative on howthe NPRWD project
would be staffed and work allocated.
Conditions of Proposal Considera-
tion:
Points will be awarded for these cri-
teria:
1. Prior experience of applicant in its
present form as engineerfor rural
water systems construction projects
involving notless than $3 million in
construction costs. (maximum of
20points)
2. Prior experience of applicant in its
present form with StateWater Com-
mission and ND State Revolving
Loan Program (Maximumof 25
points.)
3. Professional credentials of the ap-
plicant in its present form(or the
applicant’s key personnel who will
work on thisproject). Points will be
awarded for owners/employees of
theapplicant who have been with the
applicant firm as an owneror
full-time employee for not less than
two (2) years priorto the date of this
notice and only for persons who
arepracticing in the states in which
their principle place ofbusiness is lo-
cated. (maximum of 15 points)
4. Prior experience of applicant in its
present form for NPRWDprojects.
(maximum of 20 points)
5. Work load capacity of the appli-
cant in its present form -ability to
complete the project with existing
staff withinthe required time limits.
Applicant must demonstrate how
andwith what staff it proposes to
perform the project
managementfunctions. Only staff
who are full-time employed by
theapplicant for not less than twelve
(12) months prior to thedate of this
notice will be considered in awarding
pointsunder this criteria, although
applicant may hire otherpersonnel
after selection. (Maximum of 15
points)
6. Location. Preference given to
firms headquartered in NorthDakota.
(maximum of 5 points)
Proposals will be reviewed by
NPRWD with selection based upon
the evaluation of the written propo-
sals. NPRWD may elect to hold in-
terviews with applicants.
One (1) copy of the Proposals shall
be mailed to:
Teresa Sundsbak General Manager
North Prairie Regional Water District
3811 Burdick Expy E Minot, ND
58701-5357
Once the selection process is com-
plete, NPRWD will evaluate fee
structures of the selected engineer
and negotiate an agreement for the
scope of work and services pro-
posed. In the event NPRWD cannot
negotiate an agreement to its satis-
faction, NPRWD reserves the right
to negotiate with other firm(s) who
have responded or to resolicit for
Request for Qualifications.
All costs involved in responding to
this Request for Qualifications are
the responsibility of the firm submit-
ting the Request for Qualifications.
(September 4-11-18, 2020)
SUMMONS AND NOTICE
Case No. 51-2019-CV-01128
STATE OF NORTH DAKOTA,
COUNTY OF WARD, IN DISTRICT
COURT, NORTH CENTRAL
JUDICIAL DISTRICT
Tyler Anderson, Franklin D. Ander-
son and Kathy L. Anderson,
Trustees under the Franklin D.
Anderson Living Trust, dated June
1, 2015,
Plaintiffs,
vs.
Mike C. Meeken; Joseph St. Aubin,
a/k/a Joseph A. St. Aubin; and all
other persons unknown claiming any
estate or interest in, or lien or en-
cumbrance upon, the property
described in the Complaint,
Defendants.
THE STATE OF NORTH DAKOTA
TO THE ABOVE NAMED DEFEN-
DANTS:
YOU AND EACH OF YOU ARE
HEREBY SUMMONED to answer
the Complaint in the above-entitled
action, which Complaint is filed in
the Office of the Clerk of the District
Court of Ward County, North Dako-
ta, and to serve a copy of your
Answer to said Complaint on the un-
dersigned at their offices in the City
of Minot, Ward County, North Dako-
ta, within twenty-one (21) days after
such service of this Summons upon
you, exclusive of the day of such
service; and in case of your failure to
answer or appear, Judgment will be
taken against you by default for the
relief demanded in the Complaint.
The Complaint in this action is to be
filed in the office of the Clerk of
Court of Ward County, North Dako-
ta. The object of the action is to ex-
clude the Defendants from any
estate or interest in or lien or encum-
brance upon the land involved in this
action.
Dated this 28th day of August, 2020.
OLSON & BURNS P.C.
/s/Jessica L. Merchant
Jessica L. Merchant (ID 06169)
Attorneys for Plaintiff
17 First Avenue SE
P. O. Box 1180
Minot, ND 58702-1180
(701) 839-1740
jmerchant@srt.com
NOTICE
This notice is a description of the
real property at issue in the
above-entitled action, which is si-
tuated in the above-named county
and state, to-wit:
Lots 1, 2, 3, and 4, Less the
Northeasterly 40 feet thereof for
highway, Block 1, Powers 1st Addi-
tion to Donnybrook
This action will be filed in the office
of the Ward County Clerk of Court in
Minot, North Dakota.
Dated this 28th day of August, 2020.
OLSON & BURNS P.C.
/s/Jessica L. Merchant
Jessica L. Merchant (ID 06169)
Attorney for Plaintiff
17 First Avenue SE
P.O. Box 1180
Minot, ND 58702-1180
(701) 839-1740
jmerchant@srt.com
(September 4-11-18, 2020)