Legal Notices 9-6
ADVERTISEMENT FOR BIDS
FOR THE CONDITION ASSESS-
MENT OF RAW WATER PIPELINE
FROM LAKE SAKAKAWEA TO
NAWS PRS STATION (CONTRACT
SA No. 80) FOR THE NORTH
DAKOTA STATE WATER COM-
MISSION
NOTICE IS HEREBY GIVEN that
the State of North Dakota, acting
through the State Water Commis-
sion, invites and will receive sealed
proposals (bids) up to the hour of
2:00 p.m., local time, on September
25, 2019, for the furnishing to the
State of North Dakota of all transpor-
tation, labor, materials, tools, equip-
ment, services, permits, utilities, and
other items necessary to construct
said work, in accordance with the
drawings and contract documents
on file in the office the North Dakota
State Water Commission. At said
time, said proposals will be publicly
opened and read aloud in the North
Dakota State Water Commission lo-
cated at: North Dakota State Water
CommissionState Office Building
900 East Boulevard Avenue
Bismarck, North Dakota
58505-0850. Bids shall conform to
and be responsive to the Contract
Documents for the work. The Con-
tract Documents will be available
after August 30, 2019. Copies of the
Contract Documents will be on file
and may be examined during normal
office hours in the office of the North
Dakota State Water Commission
and at the following locations: Hous-
ton Engineering, Inc. 18 3rd Street
SE Suite 100 Minot, ND 58701-3700
Telephone (701) 852-7931 Fax
(701) 858-5655. The scope of Work
generally consists of the following:
Mobilization; pump water out of and
exercise existing valves in 111
vaults (58 air release valve
vaultsand 53 blowoff vaults); fill and
pressure test the existing ductile
iron line, flush water out of exist-
ing pipeline blowoffs, and incidental
items. The Contractor will not per-
form work or permit the performance
of Work by subcontractors outside
regular dusk to dawn working
hours or on Saturdays, Sundays,
or legal State holidays without pro-
viding written notice of proposed
work to the Engineer a minimum of
5 days in advance and contingent on
the Owner’s written consent. In ac-
cordance with of the current Energy
and Water Development Appropria-
tions Act, to the greatest extent
practicable, all equipment and pro-
ducts purchased for use in this con-
tract should be American-made.
Printed copies of plans and specifi-
cations may be obtained following
receipt of payment of $500.00 per
set, non-refundable, or a CD may be
obtained with the documents in elec-
tronic (pdf) format following receipt
of payment of $40 per set, nonre-
fundable, from the following: Hous-
ton Engineering, Inc. 18 3rd Street
SE Suite 100 Minot, ND
58701-3700. The contract docu-
ments may also be viewed free of
charge online at
www.houstoneng.com, or down-
loaded for a fee of $25.00. Please
contact us at 701-852-7931 if you
have any questions. The Advertise-
ment for Bids, Planholders List, Ad-
dendums, and Bid Results will be
available from the “Bid Info” link lo-
cated on the Houston Engineering,
Inc. web site. Each bid shall be sub-
mitted on a form furnished as part of
the contract documents and must be
accompanied by a separate en-
velope containing a Bidder’s Bond
with Acknowledgement of Surety in
an amount not less than 5% of the
full amount of the bid made payable
to the order of or for the benefit of
the North Dakota State Water
Commission. The bid bond shall be
executed by the bidder as principal
and by a surety company authorized
to do business in the State of North
Dakota, conditioned that if the
principal’s Bid be accepted and the
contract awarded to the principal,
within ten (10) days after Notice of
Award, the Principal shall execute a
contract in accordance with the
terms of the bid and contractor’s
performance and payment bonds as
required by law and the regulations
and determinations of the North
Dakota State Water Commission. A
bid submitted without this informa-
tion properly enclosed in the bid
bond envelope shall not be read nor
considered and the envelope shall
be resealed and bid returned to the
bidder immediately. Each bid shall
be sealed and delivered to the North
Dakota State Water Commission at
the location designated in this notice
for the opening of bidsat or before
the time in this notice provided. Un-
less a bidder obtains a contractor’s
license for the full amount of its bid
within twenty days after it is deter-
mined the bidder is the lowest
responsive and responsible bidder,
the bid must be rejected and the
contract awarded to the next lowest,
responsive, responsible, and
LICENSED bidder. A Pre-Bid
Conference Call with the Engineer
will be held on September 18, 2019
at 2:00 p.m. local time. Attendance
at the pre-bid conference is strongly
encouragedfor all Bidders. The con-
ferencing details are provided in the
Bidding Documents. Interim Mile-
stone Substantial Completion dates
for the WORK are stipulated in the
AGREEMENT (Document No.
00520). Final Completion for all
WORK shall be July 31, 2020. The
State of North Dakota, acting
through the State Water Commis-
sion, reserves the right to select the
schedule(s) under which the bids
are to be compared and contract(s)
awarded, to reject any and all bids,
to determine whether a bidder is
responsive and responsible and to
waive any and all irregularities in
any bid. BY THE ORDER OF THE
NORTH DAKOTA STATE WATER
COMMISSION.
Dated: August 27, 2019
/s/ Garland Erbele
Garland Erbele, PE,
Chief Engineer/Secretary
(August 30; September 6-13, 2019)
NOTICE TO CREDITORS
Case No. 51-2019-PR-00089
IN THE DISTRICT COURT OF
WARD COUNTY, STATE OF
NORTH DAKOTA
In the Matter of the Estate of
Vincent Arthur Jensen, Deceased.
NOTICE IS HEREBY GIVEN that
the undersigned have been appoint-
ed co-personal representatives of
the above estate. All persons having
claims against the said deceased
are required to present their claims
within three (3) months after the date
of the first publication or mailing of
this notice or said claims will be for-
ever barred. Claims must either be
presented to Joyce Berg and Keith
Jensen, co-personal representatives
of the above-named estate, in care
of Louser & Zent, P.C., Town &
Country Center, 1015 South Broad-
way, Suite 15, Minot, North Dakota
58701, or filed with the Court.
Dated this 15th day of August, 2019.
/s/Joyce Berg
Joyce Berg
1608 – 35th Avenue Southeast
Minot, ND 58701
/s/Keith Jensen
Keith Jensen
1912 Eighth Street Northwest
Minot, ND 58701
Diane R. Louser (ID #03882)
LOUSER & ZENT, P.C.
Town & Country Center
1015 South Broadway, Suite 15
Minot, ND 58701
Telephone No. (701) 837-4846
Attorneys for the Personal
Representative
(August 23-30; September 6, 2019)
NOTICE TO CREDITORS
PROBATE NO. 51-2019-PR-00115
IN THE COUNTY COURT OF
WARD COUNTY, STATE OF
NORTH DAKOTA
In the Matter of the Estate of JOYCE
ANN O’CONNELL, Deceased.
NOTICE IS HEREBY GIVEN that
the undersigned has been appointed
Personal Representative of the
above estate. All persons having
claims against the said deceased
are required to present their claims
within three months after the date of
the first publication or mailing of this
notice or said claims will be forever
barred. Claims must either be
presented to JAMES R. THOMP-
SON, 2950 – 121st Ave. NW, Coon
Rapids, MN 55433, or filed with the
Court.
Dated this 20th day of August, 2019.
/s/James R. Thompson
Personal Representative
James R. Thompson
MCINTEE LAW FIRM
Michael S. McIntee
116 West 5th Street
Bottineau, ND 58318
701-228-3624
Attorney for Personal Representa-
tives
(August 23-30; September 6, 2019)
NOTICE TO CREDITORS
Probate No. 51-2019-PR-117
IN THE DISTRICT COURT OF
WARD COUNTY, STATE OF
NORTH DAKOTA
In the Matter of the Estate of
Winifred A. Hankla,
Deceased.
NOTICE IS HEREBY GIVEN that
the undersigned has been appointed
personal representative of the Estate
of Winifred A. Hankla. All persons
having claims against Winifred A.
Hankla are required to present their
claims within three (3) months after
the date of the first publication of this
notice or said claims will be forever
barred. Claims must either be
presented to Walfrid B. Hankla, per-
sonal representative of the estate, at
P.O. Box 998, Minot, ND
58702-0998, or filed with the Court.
Dated this 20th day of August, 2019.
Walfrid B. Hankla
Personal Representative
Peter B. Hankla (ID #04919)
phankla@mcgeelaw.com
McGEE, HANKLA & BACKES, P.C.
2400 Burdick Expy. E., Suite 100
P.O. Box 998
Minot, ND 58702-0998
(701) 852-2544
Attorneys for Personal
Representative
(August 23-30; September 6, 2019)
SUMMONS
Civil No. 51-2019-CV-01420
IN DISTRICT COURT
OF WARD COUNTY,
STATE OF NORTH DAKOTA
Deborah Schultz,
Plaintiff,
vs.
Charles Schultz deceased, C.
Schultz, LLC, Schultz Electric, Inc,
and all other persons Unknown
claiming any estate or interest in, Or
lien or encumberance upon, the pro-
perty described in the complaint,
Defendants.
THE STATE OF NORTH DAKOTA
TO THE ABOVE NAMED DEFEN-
DANTS: YOU ARE HEREBY SUM-
MONED to answer the Complaint of
the Plaintiff in the above-entitled ac-
tion, which is filed in the office of the
Clerk of the District Court of the
North Central Judicial District in and
for the County of Ward and State of
North Dakota, and to serve a copy of
your answer to said Complaint on
the subscriber within twenty-one
(21) days after the service of this
Summons upon you, exclusive of
the day of service, and in case of
your failure to appear or answer,
judgment will be taken against you
by default for the relief demanded in
the Complaint. Notice is hereby
given that the above entitled action
is brought to quiet title in the follow-
ing described property situated in
Ward County, North Dakota, to-wit:
Outlot 37 LESS Outlot 41 of the
NENE Section 27, Township 155
North, Range 83 West of the 5th
P.M, Ward County, North Dakota.
Dated this 12th day of August, 2019.
/s/Dean A. Frantsvog
Dean A. Frantsvog (ID #05753)
Attorney for Plaintiff
P.O. Box 667
Minot, ND 58702-0667
(701) 833-1985
frantsvoglaw@srt.com
(August 23-30; September 6, 2019)