Legal Notices 9-13
ADVERTISEMENT FOR BIDS
FOR THE CONDITION ASSESS-
MENT OF RAW WATER PIPELINE
FROM LAKE SAKAKAWEA TO
NAWS PRS STATION (CONTRACT
SA No. 80) FOR THE NORTH
DAKOTA STATE WATER COM-
MISSION
NOTICE IS HEREBY GIVEN that
the State of North Dakota, acting
through the State Water Commis-
sion, invites and will receive sealed
proposals (bids) up to the hour of
2:00 p.m., local time, on September
25, 2019, for the furnishing to the
State of North Dakota of all transpor-
tation, labor, materials, tools, equip-
ment, services, permits, utilities, and
other items necessary to construct
said work, in accordance with the
drawings and contract documents
on file in the office the North Dakota
State Water Commission. At said
time, said proposals will be publicly
opened and read aloud in the North
Dakota State Water Commission lo-
cated at: North Dakota State Water
CommissionState Office Building
900 East Boulevard Avenue
Bismarck, North Dakota
58505-0850. Bids shall conform to
and be responsive to the Contract
Documents for the work. The Con-
tract Documents will be available
after August 30, 2019. Copies of the
Contract Documents will be on file
and may be examined during normal
office hours in the office of the North
Dakota State Water Commission
and at the following locations: Hous-
ton Engineering, Inc. 18 3rd Street
SE Suite 100 Minot, ND 58701-3700
Telephone (701) 852-7931 Fax
(701) 858-5655. The scope of Work
generally consists of the following:
Mobilization; pump water out of and
exercise existing valves in 111
vaults (58 air release valve
vaultsand 53 blowoff vaults); fill and
pressure test the existing ductile
iron line, flush water out of exist-
ing pipeline blowoffs, and incidental
items. The Contractor will not per-
form work or permit the performance
of Work by subcontractors outside
regular dusk to dawn working
hours or on Saturdays, Sundays,
or legal State holidays without pro-
viding written notice of proposed
work to the Engineer a minimum of
5 days in advance and contingent on
the Owner’s written consent. In ac-
cordance with of the current Energy
and Water Development Appropria-
tions Act, to the greatest extent
practicable, all equipment and pro-
ducts purchased for use in this con-
tract should be American-made.
Printed copies of plans and specifi-
cations may be obtained following
receipt of payment of $500.00 per
set, non-refundable, or a CD may be
obtained with the documents in elec-
tronic (pdf) format following receipt
of payment of $40 per set, nonre-
fundable, from the following: Hous-
ton Engineering, Inc. 18 3rd Street
SE Suite 100 Minot, ND
58701-3700. The contract docu-
ments may also be viewed free of
charge online at
www.houstoneng.com, or down-
loaded for a fee of $25.00. Please
contact us at 701-852-7931 if you
have any questions. The Advertise-
ment for Bids, Planholders List, Ad-
dendums, and Bid Results will be
available from the “Bid Info” link lo-
cated on the Houston Engineering,
Inc. web site. Each bid shall be sub-
mitted on a form furnished as part of
the contract documents and must be
accompanied by a separate en-
velope containing a Bidder’s Bond
with Acknowledgement of Surety in
an amount not less than 5% of the
full amount of the bid made payable
to the order of or for the benefit of
the North Dakota State Water
Commission. The bid bond shall be
executed by the bidder as principal
and by a surety company authorized
to do business in the State of North
Dakota, conditioned that if the
principal’s Bid be accepted and the
contract awarded to the principal,
within ten (10) days after Notice of
Award, the Principal shall execute a
contract in accordance with the
terms of the bid and contractor’s
performance and payment bonds as
required by law and the regulations
and determinations of the North
Dakota State Water Commission. A
bid submitted without this informa-
tion properly enclosed in the bid
bond envelope shall not be read nor
considered and the envelope shall
be resealed and bid returned to the
bidder immediately. Each bid shall
be sealed and delivered to the North
Dakota State Water Commission at
the location designated in this notice
for the opening of bidsat or before
the time in this notice provided. Un-
less a bidder obtains a contractor’s
license for the full amount of its bid
within twenty days after it is deter-
mined the bidder is the lowest
responsive and responsible bidder,
the bid must be rejected and the
contract awarded to the next lowest,
responsive, responsible, and
LICENSED bidder. A Pre-Bid
Conference Call with the Engineer
will be held on September 18, 2019
at 2:00 p.m. local time. Attendance
at the pre-bid conference is strongly
encouragedfor all Bidders. The con-
ferencing details are provided in the
Bidding Documents. Interim Mile-
stone Substantial Completion dates
for the WORK are stipulated in the
AGREEMENT (Document No.
00520). Final Completion for all
WORK shall be July 31, 2020. The
State of North Dakota, acting
through the State Water Commis-
sion, reserves the right to select the
schedule(s) under which the bids
are to be compared and contract(s)
awarded, to reject any and all bids,
to determine whether a bidder is
responsive and responsible and to
waive any and all irregularities in
any bid. BY THE ORDER OF THE
NORTH DAKOTA STATE WATER
COMMISSION.
Dated: August 27, 2019
/s/ Garland Erbele
Garland Erbele, PE,
Chief Engineer/Secretary
(August 30; September 6-13, 2019)
Notice of a Special Meeting
Notice is now given that a special
meeting of the Minot Park Board will
take place on September 17 at
6:30pm in the Community Room at
the Minot Municipal Auditorium lo-
cated at 420 3rd Ave SW, Minot ND,
for the following purpose: 2020
Minot Parks Budget Hearing. This
meeting will be followed by the Sep-
tember Minot Park Board Meeting.
(September 13, 2019)
NOTICE OF DEMOLITION OF A
CERTAIN BUILDING
Application has been made to the
City Council for orders to demolish
the following structure:
Parcel ID: MI13.152.040.0030
Legal Description: Hendrecksons
Second Addn Lot 3 Block 4
Street Address: 512 8th Street NE,
Minot, ND
A public hearing will be held on Sep-
tember 16, 2019 at 5:30 p.m. in City
Council Chambers at City Hall (515
2nd Avenue SW). Anyone objecting
to the orders to demolish these
structures should make their protest
known. Further information can be
obtained from Mitch Flanagan,
Building Official, at 857-4102.
(September 13-14, 2019)
NOTICE OF EXECUTION SALE
IN DISTRICT COURT, WARD
COUNTY, NORTH DAKOTA
Civil No. 51-2019-CV-00273
The Industrial Commission of North
Dakota, acting as the North Dakota
Housing Finance Agency,
Plaintiff,
vs.
Chad A. Cook and Michelle Cook,
husband and wife; any other person
in possession; and ProCollect Ser-
vices, LLC;
Defendants.
NOTICE IS HEREBY GIVEN, that
by virtue of a judgment and decree
of foreclosure rendered and given in
the District Court in and for the
County of Ward, North Dakota,
North Central Judicial District, en-
tered and docketed in the Office of
the Clerk of said Court on July 24,
2019, in an action wherein The In-
dustrial Commission of North Dakota
acting as the North Dakota Housing
Finance Agency, was Plaintiff and
Chad A. Cook and Michelle Cook,
husband and wife; any other person
in possession; and ProCollect Ser-
vices, LLC were the Defendants; on
which day it was adjudged that there
was due and owing the Plaintiff from
the Defendants, Chad A. Cook and
Michelle Cook, husband and wife;
together with costs and disburse-
ments of said action, the sum of
$112,481.31, and by virtue of a Spe-
cial Execution issued to me by the
Clerk of said Court, I will sell the real
property described in said judgment
and hereafter described to the
highest bidder for cash at public
auction at the front door of the
Courthouse in the City of Minot,
County of Ward, North Dakota, on
October 16, 2019, at the hour of
10:00 a.m. of that day to satisfy the
amount due with accrued costs and
interest at the date of sale, or so
much thereof as the proceeds of
said sale applicable thereto will
satisfy. The premises to be sold as
aforesaid are situated in the County
of Ward, State of North Dakota, and
are more particularly described as
follows:
Lot 14, Rearrangement of W 1/2 of
Block 1, Home Acres Addition to
the City of Minot, Ward County,
North Dakota
(Street Address: 1641 Main Street
South, Minot, ND 58701)
Dated at Minot, North Dakota, this
4th day of September, 2019.
Robert Roed
Sheriff of Ward County,
North Dakota
/s/Jamie Williams
Lieutenant Jamie Williams
Dean A. Rindy ND ID# 04206
Special Assistant Attorney General
Attorney for Plaintiff
720 Main Avenue
Fargo, ND 58103
701.235.8000
dean@okeeffeattorneys.com.
(September 13-20-27, 2019)
NOTICE
Proposed Ordinance Changes
The Ward County Commissioners
will hold a public hearing on pro-
posed revisions to Chapters 1, 2, 3
and 4 of the Zoning ordinance. The
changes address Zoning Districts 1,
2, 6 and the Ward County Flood-
plain, to address consistency with
and to accomplish the goals and pol-
icies of the Ward County
Comprehensive Plan and any
amendments thereto. A full copy of
the ordinance can be obtained from
the Auditor’s office. The hearing will
be held during their regular commis-
sion meeting which begins at 9:00
am on October 15. The meeting will
be in the commission chambers on
2nd floor of the Administration Build-
ing, 225 3rd St SE Minot.
(September 13, 2019)
NOTICE
Sawyer City Council Meeting
Monday Aug 5th, 2019 7:00pm
Present: Mayor Redding, Council
members: Darkow, Dynes, Anfinson,
Beeter, Staff: Yarbrough, Folden &
Schmidt
Visitors: L. Heide, K&R Contracting,
J. Feil, S. Sys, R. Weltikol, K. Aho
Whiskey Bandits-Motion to approve
Special Use permit for FD Pig
Roast-MB, 2nd ED, MC. Senior
Housing discussion. Opp Property.
Council concurs to contact property
owner to find out plan of action. Old
Business: Motion to Approve
Minutes-GA, 2nd, KD, MC. Motion to
Approve Financial Reports -ED,
2nd-MB, MC. Weltikol property- As
of now R. Kongslie will do the work
in Sept. Council concurs Auditor
should contact banks that we do
business with and see about financ-
ing. Handicap sign in front of
Cowboy’s Corner- WC Highway
Dept has provided a diagram for
striping. County to pay 75%,
Sawyer 25%. Motion to move
forward-KD, 2nd-MB, MC. Prelim-
inary 2020 Budget went to County
on 8/9. Final Budget hearing will be
Oct. 7th to allow citizens to make
comments. Auditor directs Council
to the water fund in the red for pro-
posed 2020 budget, the infrastruc-
ture is continuing to deteriorate so
repairs will increase due to water
and sewer maintenance projects at
$20,000 each. Funding for these
repairs must be budgeted through
either property tax transfers, special
assessments or increase rates.
Council concurs that the repairs
have to be done. KD asks if money
from the General Fund is still being
transferred to the Highway Fund to
cover shortfalls in revenue receipts.
KD asks how much the tax levy will
increase property taxes=about $50
per $100,000 of value. Discussion
on Special Assessment to each pro-
perty taxes to raise money for the
maintenance of the water and sewer
repairs. Discussion on Sawyer not
qualifying for most grants because
the average income in the communi-
ty is too high=the majority of people
in the community are not low income
families. Bridge Design-graphic pro-
vided to Council with proposed
design. Citizens are encouraged to
contact Legislatures to vote for ap-
propriations. Levee Encroachments-
ED will be attending the meeting and
will be taking photos with her of the
wet & dry side of the levee. She will
also be asking the Corp and the
Board to come to Sawyer to speak
directly with the property owners to
give specific instructions on how to
handle each specific encroachment
identified. Dog complaint received
on Grad & Francis dogs running at
large and barks and/or incessantly
barking. CC asks if the owners can
be fined. Discussion on adding fund-
ing for a Judge into the budget
would be the best use of City funds.
KD suggests that we review the fine
schedule in each ordinance and ad-
just those prior to hiring any Judge.
Council concurs that over the winter
to review the fee schedules. Most
ordinances state that fines can be
up to $500. Discussion on multiple
cars across the street of the Lindsey
home and will cause issues. Dis-
cussion on NO Parking sign up on
that street. Council concurs that is a
good idea. Auditor Update: Discus-
sion on Water Shut-offs. Pancake
Breakfast Proceeds -$382 was col-
lected for the School. Council con-
curs the City should earmark for
flagpoles as a symbol of our govern-
ment. Sept Meeting Date change
due to Auditor being out for
Daughter’s wedding. Motion to hold
meeting on Monday Sept 9th-GA,
2nd-MB, MC. Other Items: Discus-
sion on 325 2nd Ave SW. Water was
shut-off at the property today. KD
states that there are piles of gar-
bage, appliances, etc. in front in the
place. It is causing rodents, feral cat
haven, etc. KD states if they are not
going to clean it the City needs to
clean it and assess the property.
Discussion on 105 3rd St SW.
Trailer needs to be updated or re-
moved. City to hire someone to take
care of the lot and assess the pro-
perty for the cost plus. Motion to Ap-
prove Expenditures-MB, 2nd-GA,
MC Ottertail 793.00, Circle
2232.00, ABM 110.85, NDIRF
783.56, Menards 59.19, NPRWD
3357.24, Enerbase 284.26,
NDNewspaper Assoc 45.99, Perkins
124.00, P&H 240.00, PnC 25.00,
NDLOC 546.00, A-1 687.50, Dak
Fire Ext 99.19, Lowes 120.00, Visa
86.46, VEC 14.00, SRT 207.13, ND
Tax Comm 706.33, FDHU 25.00,
RDFC 10558.21, Fed Dep 2101.36,
USBank 533.74, Payroll 4559.93.
Motion to Adjourn-MB, 2nd-ED, MC.
(September 13, 2019)
NOTICE TO CONTRACTORS
The North Dakota Department of
Transportation (NDDOT) will receive
bids for the construction of the fol-
lowing project(s):
Job No.: 3
Project No(s).: HEU-4-999(038)
Length: 0.001
Type: PEDESTRIAN CROSSING
IMPROVEMENTS
County(s): WARD Co
Location: MINOT, 3RD ST SE &
3RD AVE SE AND 13TH ST &
BURDICK EXPY
Job No.: 13
Project No(s).: TAC-0051(031)
Length: 0.420
Type: SIDEWALKS, CURB &
GUTTER, AND INCIDENTALS
County(s): WARD Co
Location: SURREY, 5TH ST SW
FROM 4TH AVE SW TO
PLEASANT AVE S & PLEASANT
AVE FROM 5TH ST SW TO 3RD
ST SE
Bids will be received via the Bid Ex-
press on-line bidding exchange at
www.bidx.com until 09:30AM, Oc-
tober 11, 2019. Bids will be opened
at that time at the NDDOT building
on the capitol grounds in Bismarck
and the bid results will be distributed
and posted online at
https://www.dot.nd.gov/business/bidinfo.htm
approximately 30 minutes after bids
are opened.
The proposal forms, plans, and
specifications are available on the
NDDOT website at
http://www.dot.nd.gov and may be
inspected at the Construction Ser-
vices Division, 608 East Boulevard
Avenue, Bismarck, North Dakota.
All bidders not currently prequalified
with NDDOT must submit a
Contractor’s Prequalification State-
ment (SFN 9384) to the Department
at least ten (10) business days prior
to the bid opening. The form can be
found on the NDDOT website. On-
line prequalification is also available.
NDDOT reserves the right to reject
any and all proposals, waive techni-
calities, or to accept such as may be
determined in the best interests of
the state.
For disability/language assistance,
call 701-328-2978.
Requested by:
Ronald J Henke, Interim Director
North Dakota Department of Tran-
sportation
(September 13, 2019)
NOTICE TO CREDITORS
Probate No. 51-2019-PR-00108
IN DISTRICT COURT, NORTH
CENTRAL JUDICIAL DISTRICT
In the Matter of the Estate of Jerica
Irmen
NOTICE IS HEREBY GIVEN that
the undersigned has been appointed
Personal Representative of the
above Estate. All persons having
claims against the said deceased
are required to present their claims
within three months after the date of
the first publication of this Notice or
said claims will be forever barred.
Claims must either be presented to
Daniel Holwegner, Personal
Representative of the Estate of Jeri-
ca Irmen, c/o Olson & Burns P.C.,
P.O. Box 1180, Minot, ND
58702-1180, or filed with the Court.
Dated this 9th day of September,
2019.
/s/Daniel Holwegner
Daniel Holwegner
Jessica L. Merchant (ID 06169)
OLSON & BURNS P.C.
P. O. Box 1180
Minot, ND 58702-1180
(701) 839-1740
jmerchant@srt.com
Attorneys for Personal
Representative
(September 13-20-27, 2019)
SUMMONS
Civil No. 51-2019-CV-01397
STATE OF NORTH DAKOTA, IN
DISTRICT COURT, WARD COUN-
TY, NORTH DAKOTA
American Bank Center,
Plaintiff
vs.
Kenneth Malsom,
Defendant.
THE STATE OF NORTH DAKOTA
TO THE ABOVE NAMED DEFEN-
DANT: YOU ARE HEREBY SUM-
MONED And required to appear and
defend against the Complaint in this
action, a copy of which is herewith
served upon you by serving upon
the undersigned an Answer or other
proper response within twenty-one
(21) days after the service of this
Summons upon you, exclusive of
the day of service. If you fail to do
so, Judgment by Default will be tak-
en against you for the relief demand-
ed in the Complaint.
Dated this 3rd day of June, 2019.
/s/Richard P. Olson
Richard P. Olson (Bar ID: #03183)
Attorneys for American Bank Center
17 First Avenue SE
P. O. Box 1180
Minot, ND 58702-1180
(701) 839-1740
rpolson@minotlaw.com
(September 13-20-27, 2019)
SUNDRE TOWNSHIP NOTICE
All land owners must have ditches
mowed to a minimum 4 inch stubble
height and a minimum 9 food mower
width between Sept. 15-Oct 1st,
2019. Sundre Township will contract
mowing for ditches not completed by
October 1, 2019 and expenses will
be levied as taxes against land own-
er.
Cari Morey, Sundre Township Clerk
(September
13-14-16-17-18-19-20, 2019)